Legal Consequences in the Case of Faulty Exercise of the Right of Veto on the Part of the Cl
Legal Consequences in the Case of Faulty Exercise of the Right of Veto on the Part of the Cl Sample Clauses
Related to Legal Consequences in the Case of Faulty Exercise of the Right of Veto on the Part of the Cl
Limitation on Out-of-State Litigation Texas Business and Commerce Code § 272 This is a requirement of the TIPS Contract and is non-negotiable. Texas Business and Commerce Code § 272 prohibits a construction contract, or an agreement collateral to or affecting the construction contract, from containing a provision making the contract or agreement, or any conflict arising under the contract or agreement, subject to another state’s law, litigation in the courts of another state, or arbitration in another state. If included in Texas construction contracts, such provisions are voidable by a party obligated by the contract or agreement to perform the work. By submission of this proposal, Vendor acknowledges this law and if Vendor enters into a construction contract with a Texas TIPS Member under this procurement, Vendor certifies compliance.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 2
Retention or Repurchase of Assets Essential to Receiver (a) The Receiver may refuse to sell to the Assuming Institution, or the Assuming Institution agrees, at the request of the Receiver set forth in a written notice to the Assuming Institution, to assign, transfer, convey, and deliver to the Receiver all of the Assuming Institution's right, title and interest in and to, any Asset or asset essential to the Receiver as determined by the Receiver in its discretion (together with all Credit Documents evidencing or pertaining thereto), which may include any Asset or asset that the Receiver determines to be:
PROVISIONAL AGREEMENT RESULTING FROM INTERINSTITUTIONAL NEGOTIATIONS Subject: Proposal for a regulation of the European Parliament and of the Council on a Pan- European Personal Pension Product (PEPP) (COM(2017)0343 – C8-0219/2017 – 2017/0143(COD)) The interinstitutional negotiations on the aforementioned proposal for a regulation have led to a compromise. In accordance with Rule 69f(4) of the Rules of Procedure, the provisional agreement, reproduced below, is submitted as a whole to the Committee on Economic and Monetary Affairs for decision by way of a single vote. AG\1177088EN.docx PE634.848v01-00 EN United in diversity EN REGULATION (EU) 2019/... OF THE EUROPEAN PARLIAMENT AND OF THE COUNCIL of ... on a pan-European Personal Pension Product (PEPP) (Text with EEA relevance) THE EUROPEAN PARLIAMENT AND THE COUNCIL OF THE EUROPEAN UNION, Having regard to the Treaty on the Functioning of the European Union, and in particular Article 114 thereof, Having regard to the proposal from the European Commission, After transmission of the draft legislative act to the national parliaments, Having regard to the opinion of the European Economic and Social Committee1, Acting in accordance with the ordinary legislative procedure2,
City’s Right to Suspend for Convenience City may suspend all or any portion of Contractor’s performance under this Contract at its sole option and for its convenience for a reasonable period of time not to exceed six (6) months. City must first give ten (10) days’ written notice to Contractor of such suspension. City will pay to Contractor a sum equivalent to the reasonable value of the goods and/or services satisfactorily provided up to the date of suspension. City may rescind the suspension prior to or at six (6) months by providing Contractor with written notice of the rescission, at which time Contractor would be required to resume performance in compliance with the terms and provisions of this Contract. Contractor will be entitled to an extension of time to complete performance under the Contract equal to the length of the suspension unless otherwise agreed to in writing by the Parties.
Termination Consequences In the event of this agreement being determined whether by effluxion of time Notice breach or otherwise:
Waiver of Appellate and Post-Conviction Rights a. The defendant acknowledges, understands and agrees that by pleading guilty pursuant to this plea agreement he waives his right to appeal or collaterally attack a finding of guilt following the acceptance of this plea agreement, except on grounds of (1) ineffective assistance of counsel; or (2) prosecutorial misconduct.
Limited Waiver of Sovereign Immunity Ex Contractu Contractor acknowledges and agrees that Owner is an agency or instrumentality of the State of Georgia, and as such is entitled to the protection of sovereign immunity. As set forth in Article I, Section II, Paragraph IX of the 1983 Georgia Constitution, sovereign immunity is waived “as to any action ex contractu for the breach of any written contract.” Contractor specifically acknowledges the constitutional and contractual requirements that written changes, modifications, and waivers to this Contract must be specifically executed by the Owner as set forth in the Contract Documents. Accordingly, Contractor specifically acknowledges the constitutional prohibitions against claims against Owner based solely upon oral statement, course of conduct, customs of the trade, quasi-contract, quantum meruit, or O.C.G.A § 13-4-4 (mutual departure from contract terms).
No Restriction on Existing Examination and Investigative Authority That this Agreement shall in no way preclude any State Mortgage Regulator from exercising its examination or investigative authority authorized under the laws of the corresponding Participating State in the instance a determination is made wherein Respondent is found not to be adhering to the requirements of the Agreement, other than inadvertent and isolated errors that are promptly corrected by Respondent, or involving any unrelated matter not subject to the terms of this Agreement. The Parties agree that the failure of Respondent to comply with any term or condition of this Agreement with respect to a particular State shall be treated as a violation of an Order of the State and may be enforced as such. Moreover, Respondent acknowledges and agrees that this Agreement is only binding on the State Mortgage Regulators and not any other Local, State or Federal Agency, Department or Office.
Emergency Action on Imports of Particular Products Where any product is being imported in such increased quantities and under such conditions as to cause, or threaten to cause:
