Review and Construction of Documents Each Party herein expressly represents and warrants to all other Parties hereto that (a) before executing this Agreement, said Party has fully informed itself of the terms, contents, conditions and effects of this Agreement; (b) said Party has relied solely and completely upon its own judgment in executing this Agreement; (c) said Party has had the opportunity to seek and has obtained the advice of its own legal, tax and business advisors before executing this Agreement; (d) said Party has acted voluntarily and of its own free will in executing this Agreement; and (e) this Agreement is the result of arm’s length negotiations conducted by and among the Parties and their respective counsel.
Initial Construction Landlord shall fully construct the base Building in accordance with the preliminary base building plans, including, without limitation, floor plans, elevations and site plan(s) (collectively, the "PBBP") and Base Building Outline Specifications attached hereto as Exhibits B-1 and B-2, respectively (all of such work being collectively referred to as the "Landlord's Work"). In the event of differences between the PBBP or the Landlord's Plans (as hereinafter defined) and the Base Building Outline Specifications, the Base Building Outline Specifications shall govern and control until the Landlord's Plans (as hereinafter defined) are prepared. A complete set of final base Building plans and construction drawings and specifications, such drawings and specifications to include a detail schedule of core base Building finish items such as, but not limited to, carpets, doors, hardware, ceiling grids/tiles, lavatory fixtures, light fixtures, window blinds, lobby finishes and paint/wall coverings (collectively, the "Landlord's Plans") shall be prepared by Landlord, at its sole cost and expense. Landlord and Tenant agree to work together with Landlord's architect, Symmes Maini and McKex Xxxociates, Inc. in order to achieve a design that meets the standard set forth below. Furthermore, Landlord agrees to use good faith and diligent efforts to deliver the Landlord's Plans to Tenant on or before May 1, 2000. Upon receipt, Tenant shall have seven (7) business days to comment upon the Landlord's Plans. Landlord and Tenant shall use reasonable efforts to reach agreement on the Landlord's Plans as soon thereafter as possible. In reaching agreement, Landlord and Tenant shall each approve portions of the Landlord's Plans that are in acceptable form and shall note their respective objections to the portions that are unacceptable to each of them so as to enable Landlord to continue construction and order materials in a timely manner. In the event that Landlord's Plans conform with the PBBP, but Tenant does not approve the Landlord's Plans within seven (7) business days of receipt thereof from Landlord, then the Outside Delivery Date (as hereinafter defined) shall be extended for a number of days equal to the number of Tenant Plan Delay Days, as such term is hereinafter defined. The number of Tenant Plan Delay Days are defined as and shall be calculated by determining the actual number of days as certified by Landlord and its architect that the Term Commencement Date was delayed by such Tenant's failure to approve the Landlord's Plans within the required seven (7) business days. Landlord agrees to provide Tenant with written notice of such determination, such notice to include reasonable detail describing the cause of the delay and the number of Tenant Plan Delay Days as certified by Landlord and its architect. If Tenant and Tenant's Architect (as hereinafter defined)
Selection of Architect/Construction Drawings Tenant shall retain an architect/space planner reasonably and mutually agreed upon by Landlord and Tenant (the “Architect”) to prepare the “Construction Drawings,” as that term is defined in this Section 3.1. The Contractor (as that term is defined in Section 4.1 of this Work Letter) shall provide design-build services from qualified, Landlord-approved mechanical, electrical and plumbing contractors for the preparation of plans and engineering working drawings related to the Improvements. Landlord hereby approves Gensler as the Architect if Tenant decides to select them. Tenant shall retain the engineering consultants designated by Landlord (the “Engineers”) to prepare all plans and engineering working drawings relating to the structural, HVAC, lifesafety, and sprinkler work in the Premises, which work is not part of the Base Building, provided that Tenant shall retain the subcontractors designated in Schedule 2 attached hereto for the fire alarm design and programming work (the “Fire Alarm Subcontractor”) and for building management systems (the “BMS Subcontractor”). Landlord hereby approves Gensler as the Engineer if Tenant decides to select them. Should Tenant choose to prepare fully engineered drawings in lieu of the design-build approach described above, then Tenant shall retain the Engineers to prepare all plans and engineering working drawings relating to the mechanical, electrical and plumbing work of the Improvements. The plans and drawings to be prepared by Architect, the design-build contractors (unless Tenant selects the fully engineered drawings approach described above), the Fire Alarm Subcontractor, the BMS Subcontractor and the Engineers hereunder shall be known collectively as the “Construction Drawings.” Landlord hereby approves Gensler and Revel to be the Architect if Tenant selects them. All Construction Drawings shall comply with the drawing format and specifications reasonably determined by Landlord, and shall be subject to Landlord’s reasonable approval. Tenant and Architect shall verify, in the field, the dimensions and conditions as shown on the relevant portions of the Base Building plans, and Tenant and Architect shall be solely responsible for the same, and Landlord shall have no responsibility in connection therewith. Landlord’s review of the Construction Drawings as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord’s review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters. Accordingly, notwithstanding that any Construction Drawings are reviewed by Landlord or its space planner, architect, engineers and consultants, and notwithstanding any advice or assistance which may be rendered to Tenant by Landlord or Landlord’s space planner, architect, engineers, and consultants, Landlord shall have no liability whatsoever in connection therewith and shall not be responsible for any omissions or errors contained in the Construction Drawings, and Tenant’s waiver and indemnity set forth in the Lease, as amended, shall specifically apply to the Construction Drawings.
Conflict; Construction of Documents; Reliance In the event of any conflict between the provisions of this Agreement and any of the other Loan Documents, the provisions of this Agreement shall control. The parties hereto acknowledge that they were represented by competent counsel in connection with the negotiation, drafting and execution of the Loan Documents and that such Loan Documents shall not be subject to the principle of construing their meaning against the party which drafted same. Borrower acknowledges that, with respect to the Loan, Borrower shall rely solely on its own judgment and advisors in entering into the Loan without relying in any manner on any statements, representations or recommendations of Lender or any parent, subsidiary or Affiliate of Lender. Lender shall not be subject to any limitation whatsoever in the exercise of any rights or remedies available to it under any of the Loan Documents or any other agreements or instruments which govern the Loan by virtue of the ownership by it or any parent, subsidiary or Affiliate of Lender of any equity interest any of them may acquire in Borrower, and Borrower hereby irrevocably waives the right to raise any defense or take any action on the basis of the foregoing with respect to Lender’s exercise of any such rights or remedies. Borrower acknowledges that Lender engages in the business of real estate financings and other real estate transactions and investments which may be viewed as adverse to or competitive with the business of Borrower or its Affiliates.
Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the internal laws of the State of New York.
Amendments; Construction The Administrator may amend the terms of this Restricted Share Agreement prospectively or retroactively at any time, but no such amendment shall impair the rights of the Participant hereunder without his or her consent. To the extent the terms of Section 12 above conflict with any prior agreement between the parties related to such subject matter, the more restrictive provision shall be deemed to apply. Headings to Sections of this Restricted Share Agreement are intended for convenience of reference only, are not part of this Restricted Share Agreement and shall have no effect on the interpretation hereof.
Neutral Construction The parties to this Agreement agree that this Agreement was negotiated fairly between them at arm's length and that the final terms of this Agreement are the product of the parties' negotiations. Each party represents and warrants that it has sought and received legal counsel of its own choosing with regard to the contents of this Agreement and the rights and obligations affected hereby. The parties agree that this Agreement shall be deemed to have been jointly and equally drafting by them, and that the provisions of this Agreement therefore should not be construed against a party or parties on the grounds that such party or parties drafted or was more responsible for the drafting of any such provision(s).
Complete Agreement; Construction This Agreement, including the Schedules hereto, shall constitute the entire agreement between the Parties with respect to the subject matter hereof and shall supersede all previous negotiations, commitments and writings with respect to such subject matter. In the event of any inconsistency between this Agreement and any Schedule, the Schedule shall prevail. The rights and remedies of the Parties herein provided shall be cumulative and in addition to any other or further remedies provided by law or equity.
No Responsibility for Advances, Creditworthiness, Collateral, Recitals, Etc [Intentionally Omitted. See Sections 7.03 and 7.04 of the Credit Agreement for these provisions.]
Covenants and Conditions; Construction of Agreement All provisions of this Lease to be observed or performed by Lessee are both covenants and conditions. In construing this Lease, all headings and titles are for the convenience of the Parties only and shall not be considered a part of this Lease. Whenever required by the context, the singular shall include the plural and vice versa. This Lease shall not be construed as if prepared by one of the Parties, but rather according to its fair meaning as a whole, as if both Parties had prepared it.
