The Authority As to the Authority, the following section shall survive discharge: Section 2.3 (right to conduct audit).
Power of the Authority to undertake works (i) In the event the Parties are unable to agree to the proposed Change of Scope Orders in accordance with Clause 13.2, the Authority may, after giving notice to the Contractor and considering its reply thereto, award such Works or services to any person or agency on the basis of open competitive bidding. It is also agreed that the Contractor shall provide assistance and cooperation to the person or agency who undertakes the works or services hereunder. The Contractor shall not be responsible for rectification of any Defects, but the Contractor shall carry out maintenance of such works after completion of Defect Liability Period of work by other person or agency during the remaining period of this agreement without any extra payment.
(ii) The Works undertaken in accordance with this Clause 13.5 shall conform to the Specifications and Standards and shall be carried out in a manner that minimises the disruption in operation of the Project Highway. The provisions of this Agreement, insofar as they relate to Works and Tests, shall apply mutatis mutandis to the Works carried out under this Clause 13.5.
Power and Authority; Due Authorization; Execution and Delivery The execution and delivery by such Seller Party of this Agreement and each other Transaction Document to which it is a party, and the performance of its obligations hereunder and thereunder and, in the case of Seller, Seller’s use of the proceeds of Purchases made hereunder, are within its powers and authority, corporate or otherwise, and have been duly authorized by all necessary action, corporate or otherwise, on its part. This Agreement and each other Transaction Document to which such Seller Party is a party has been duly executed and delivered by such Seller Party.
Obligations of the Authority (i) The Authority shall, at its own cost and expense, undertake, comply with and perform all its obligations set out in this Agreement or arising hereunder.
(ii) The Authority shall be responsible for the correctness of the Scope of the Project, Project Facilities, Specifications and Standards and the criteria for testing of the completed Works.
(iii) The Authority shall, upon submission of the Performance Security as per the RFP by the Contractor, shall provide to the Contractor:
(a) No less than 90% (ninety per cent) of the required Right of Way of the Construction Zone of total length of the Project Highway within a period of 30 (thirty) days from the date of this Agreement, which shall be in contiguous stretches of length not less than 1( One) kilometre.
(b) approval of the general arrangement drawings (the “GAD”) from railway authorities to enable the Contractor to construct road over- bridges/ under- bridges at level crossings on the Project Highway in accordance with the Specifications and Standards, and subject to the terms and conditions specified in such approval, within a period of 60 (sixty) days from the Appointed Date, and reimbursement of all the costs and expenses paid by the Contractor to the railway authorities for and in respect of the road over- bridges/ under bridges; and7
(c) all environmental clearances as required under Clause 4.3.8
(iv) Delay in providing the Right of Way or approval of GAD by railway authorities, as the case may be, in accordance with the provisions of Clause 3.1 (iii) shall entitle the Contractor to Damages in a sum calculated in accordance with the provisions of Clause 8.3 of this Agreement and Time Extension in accordance with the provisions of Clause 10.5 of this Agreement. For the avoidance of doubt, the Parties agree that the Damages for delay in approval of GAD by the railway authorities for a particular road over-bridge/ under-bridge shall be deemed to be equal to the Damages payable under the provisions of Clause 8.3 for delay in providing Right of Way for a length of 2 (two) kilometre for each such road over-bridge/ under-bridge.
Power and Authority; Authorization; Execution and Delivery; Binding Obligation The Purchaser has the power and authority to execute, deliver and perform its obligations under this Agreement. This Agreement has been duly authorized, executed and delivered by the Purchaser and constitutes the legal, valid and binding obligation of the Purchaser, enforceable against the Purchaser in accordance with its terms, except as such enforceability may be limited by insolvency, bankruptcy, reorganization or other laws relating to or affecting the enforcement of creditors’ rights and by general equitable principles.
No License Granted Confidant acknowledges and agrees that all rights in and to Confidential Information are and shall remain the sole property of City, and Confidant agrees that it shall not contest or challenge any of City’s rights in or to any Confidential Information. Nothing in this Agreement obligates, or shall be deemed to obligate, City to provide, disclose, or deliver any Confidential Information.
Where the Academy Trust acquires assets for a nil consideration or at an under value it shall be treated for the purpose of this Agreement as having incurred expenditure equal to the market value of those assets at the time that they were acquired. This provision shall not apply to assets transferred to the Academy Trust at nil or nominal consideration and which were previously used for the purposes of an Academy and/or were transferred from an LA, the value of which assets shall be disregarded.
Xxxxxx of the Arbitrator It shall be the function of the arbitrator, and he/she shall be empowered, except as his/her powers are limited below, after due investigation, to make a decision in cases of alleged violation of the specific articles and sections of this Agreement.
1. The arbitrator shall have no power to add to, subtract from, disregard, alter, or modify any of the terms of this Agreement.
2. The arbitrator shall have no power to rule on any of the following:
a. Actions taken by the Employer with respect to probationary employees including, but not limited to, discipline and discharge.
b. Any claim or complaint for which there is another remedial procedure or forum established by law or by regulation having the force of law.
c. Any matter involving the content of an employee evaluation.
3. He/she shall have no power to change any practice, policy, or rule of the Employer nor to substitute his/her judgment for that of the Employer as to the reasonableness of any such practice, policy, rule, or any action taken by the Employer. His/her power shall be limited to deciding whether the Employer has violated the express articles or sections of this Agreement; and he/she shall not imply obligations and conditions binding upon the Employer from this Agreement, it being understood that any matter not specifically set forth herein remains within the reserved rights of the Employer.
4. He/she shall have no power to decide any question which, under this Agreement, is within the responsibility of management to decide. In rendering a decision, an arbitrator shall give due regard to the responsibility of management and shall so construe the Agreement that there will be no interference with such responsibilities, except as they may be specifically conditioned by this Agreement.
5. If either party disputes the arbitrability of any grievance under the terms of this Agreement, the arbitrator shall first determine the arbitrability of said dispute. By stipulation of the parties, the Arbitrator shall have the authority to concurrently hear both the jurisdictional issues and the merits of the dispute in the same proceeding. Should the Arbitrator determine that he/she is without jurisdiction to rule, the matter shall be dismissed without decision on the merits. Submission of jurisdictional issues to the Arbitrator shall not be regarded as a waiver by either party of its right to institute civil litigation contesting either the authority of the Arbitrator or any award allegedly rendered in excess of such authority.
6. There shall be no appeal from the arbitrator’s decision if within the scope of his/her authority as set forth above. It shall be final and binding on the Association, its members, the employee or employees involved and the Employer. Any litigation to vacate or enforce the Arbitrator’s decision must be initiated within six (6) months of the issuance of the Opinion and Award.
7. The fees and expenses of the arbitrator shall be shared equally by the Association and the Employer.
Signature Authority Contractor represents and warrants that the individual signing this Contract Affirmations document is authorized to sign on behalf of Contractor and to bind the Contractor.
CONDUCT OF THE AUCTION Conduct of the auction and increments of bidding are at the discretion of the Auctioneer. The Auctioneer's decision is final in the event of a dispute over any matter. The Auctioneer reserves the right to accept bids in any increments he deems to be in the best interest of his client, and reserves the right to waive any previously announced requirements. Bid rigging and bid suppression schemes are violations of the Xxxxxxx Antitrust Act and are deemed illegal and punishable as a federal felony.
