The Authority As to the Authority, the following section shall survive discharge: Section 2.3 (right to conduct audit).
Obligations of the Authority (i) The Authority shall, at its own cost and expense, undertake, comply with and perform all its obligations set out in this Agreement or arising hereunder.
(ii) The Authority shall be responsible for the correctness of the Scope of the Project, Project Facilities, Specifications and Standards and the criteria for testing of the completed Works.
(iii) The Authority shall, upon submission of the Performance Security as per the RFP by the Contractor, shall provide to the Contractor:
(a) No less than 90% (ninety per cent) of the required Right of Way of the Construction Zone of total length of the Project Highway within a period of 30 (thirty) days from the date of this Agreement, which shall be in contiguous stretches of length not less than 1( One) kilometre.
(b) approval of the general arrangement drawings (the “GAD”) from railway authorities to enable the Contractor to construct road over- bridges/ under- bridges at level crossings on the Project Highway in accordance with the Specifications and Standards, and subject to the terms and conditions specified in such approval, within a period of 60 (sixty) days from the Appointed Date, and reimbursement of all the costs and expenses paid by the Contractor to the railway authorities for and in respect of the road over- bridges/ under bridges; and7
(c) all environmental clearances as required under Clause 4.3.8
(iv) Delay in providing the Right of Way or approval of GAD by railway authorities, as the case may be, in accordance with the provisions of Clause 3.1 (iii) shall entitle the Contractor to Damages in a sum calculated in accordance with the provisions of Clause 8.3 of this Agreement and Time Extension in accordance with the provisions of Clause 10.5 of this Agreement. For the avoidance of doubt, the Parties agree that the Damages for delay in approval of GAD by the railway authorities for a particular road over-bridge/ under-bridge shall be deemed to be equal to the Damages payable under the provisions of Clause 8.3 for delay in providing Right of Way for a length of 2 (two) kilometre for each such road over-bridge/ under-bridge.
of the Act The Company will comply with the Act, the Rules and Regulations and the Securities Exchange Act of 1934 and the rules and regulations thereunder in connection with the offering and issuance of the Units.
Overriding powers of the Authority (i) If in the reasonable opinion of the Authority, the Contractor is in material breach of its obligations under this Agreement and, in particular, the Maintenance Requirements, and such breach is causing or likely to cause material hardship or danger to the Users and pedestrians, the Authority may, without prejudice to any of its rights under this Agreement including Termination thereof, by notice require the Contractor to take reasonable measures immediately for rectifying or removing such hardship or danger, as the case may be.
(ii) In the event that the Contractor, upon notice under Clause 14.9 (i), fails to rectify or remove any hardship or danger within a reasonable period, the Authority may exercise overriding powers under this Clause 14.9 (ii) and take over the performance of any or all the obligations of the Contractor to the extent deemed necessary by it for rectifying or removing such hardship or danger; provided that the exercise of such overriding powers by the Authority shall be of no greater scope and of no longer duration than is reasonably required hereunder; provided further that any costs and expenses incurred by the Authority in discharge of its obligations hereunder shall be recovered by the Authority from the Contractor, and the Authority shall be entitled to deduct any such costs and expenses incurred from the payments due to the Contractor under Clause 19.7 for the performance of its Maintenance obligations.
(iii) In the event of a national emergency, civil commotion or any other circumstances specified in Clause 21.3, the Authority may take over the performance of any or all the obligations of the Contractor to the extent deemed necessary by it, and exercise such control over the Project Highway or give such directions to the Contractor as may be deemed necessary; provided that the exercise of such overriding powers by the Authority shall be of no greater scope and of no longer duration than is reasonably required in the circumstances which caused the exercise of such overriding power by the Authority. For the avoidance of doubt, it is agreed that the consequences of such action shall be dealt in accordance with the provisions of Article 21. It is also agreed that the Contractor shall comply with such instructions as the Authority may issue in pursuance of the provisions of this Clause 14.9 (iii), and shall provide assistance and cooperation to the Authority, on a best effort basis, for performance of its obligations hereunder.
Committee Authority The Committee shall have all discretion, power, and authority to interpret the Plan and this Agreement and to adopt such rules for the administration, interpretation and application of the Plan as are consistent therewith. All actions taken and all interpretations and determinations made by the Committee in good faith shall be final and binding upon the Employee, the Company and all other interested persons, and shall be given the maximum deference permitted by law. No member of the Committee shall be personally liable for any action, determination or interpretation made in good faith with respect to the Plan or this Agreement.
Power of the Authority to undertake works (i) In the event the Parties are unable to agree to the proposed Change of Scope Orders in accordance with Clause 13.2, the Authority may, after giving notice to the Contractor and considering its reply thereto, award such Works or services to any person or agency on the basis of open competitive bidding. It is also agreed that the Contractor shall provide assistance and cooperation to the person or agency who undertakes the works or services hereunder. The Contractor shall not be responsible for rectification of any Defects, but the Contractor shall carry out maintenance of such works after completion of Defect Liability Period of work by other person or agency during the remaining period of this agreement without any extra payment.
(ii) The Works undertaken in accordance with this Clause 13.5 shall conform to the Specifications and Standards and shall be carried out in a manner that minimises the disruption in operation of the Project Highway. The provisions of this Agreement, insofar as they relate to Works and Tests, shall apply mutatis mutandis to the Works carried out under this Clause 13.5.
Authority of the Arbitrator i. It is the intent of both parties to this Collective Agreement that no grievance shall be defeated merely because of a technical error in processing the grievance through the grievance procedure. To this end an arbitrator shall have the power to allow all necessary amendments to the grievance and the power to waive formal procedural irregularities in the processing of a grievance in order to determine the real matter in dispute and to render a decision according to equitable principles and the justice of the case.
ii. The arbitrator shall not have jurisdiction to alter or change the provisions of the Collective Agreement or to substitute new ones.
iii. The provisions of this article do not override the provisions of the B.C.
Due Authority The execution and delivery by the Company of this Warrant and the performance of all obligations of the Company hereunder, including the issuance to Warrantholder of the Warrant Shares issuable hereunder, have been duly authorized by all necessary corporate action on the part of the Company. This Agreement: (i) does not violate the Company’s Charter or Bylaws; (ii) does not contravene any law or governmental rule, regulation or order applicable to the Company; and (iii) does not and will not contravene any provision of, or constitute a default under, any indenture, mortgage, contract or other instrument to which the Company is a party or by which it is bound. This Agreement constitutes a legal, valid and binding agreement of the Company, enforceable in accordance with its terms.
Power and Authority; Due Authorization The Servicer has all necessary power and authority to (i) execute and deliver this Agreement and the other Transaction Documents to which it is a party and (ii) perform its obligations under this Agreement and the other Transaction Documents to which it is a party and the execution, delivery and performance of, and the consummation of the transactions provided for in, this Agreement and the other Transaction Documents to which it is a party have been duly authorized by the Servicer by all necessary action.
Power and Authority; Due Authorization; Execution and Delivery The execution and delivery by such Seller Party of this Agreement and each other Transaction Document to which it is a party, and the performance of its obligations hereunder and thereunder and, in the case of Seller, Seller’s use of the proceeds of Purchases made hereunder, are within its powers and authority, corporate or otherwise, and have been duly authorized by all necessary action, corporate or otherwise, on its part. This Agreement and each other Transaction Document to which such Seller Party is a party has been duly executed and delivered by such Seller Party.
