ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals.
§ 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project.
§ 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project.
§ 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project.
§ 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9.
§ 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage.
§ 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage.
§ 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages
Engineers Responsibility The Engineer shall be responsible for the accuracy of its work and shall promptly make necessary revisions or corrections resulting from its errors, omissions, or negligent acts without compensation. The Engineer will not be relieved of the responsibility for subsequent correction of any such errors or omissions or for clarification of any ambiguities until after the construction phase of the project has been completed.
Tenant’s Responsibility (a) Except to the extent contributed to by a Landlord Party and except for those matters listed in Section 9.5(a) for which the Landlord shall be responsible, the Tenant shall be solely responsible and liable for any work required by any governmental authority having jurisdiction with respect to any Contaminants on, in or under the Premises during the Term of the Lease. Except (i) as caused by or contributed to by a Landlord Party, and (ii) for those matters listed in Section 9.5(a), the Tenant shall indemnify, defend (utilizing counsel satisfactory to the Landlord) and hold harmless the Landlord and the Landlord’s respective officers, directors, beneficiaries, shareholders, partners, agents and employees from all Claims arising out of or in any way connected with any Release of any Contaminants that occurs during the Term of this Lease, at, in, on, from, under, or about the Premises or the Building, or which arises at any time from the Tenant’s use or occupancy of the Premises, or from the Tenant’s failure to provide all information, make all submissions, and take steps required by all authorities under Environmental Law.
(b) Upon the occurrence of any material Release of a Contaminant at the Premises and upon the Tenant becoming aware of such Release, the Tenant shall immediately give written notice to the Landlord. In any event, the Tenant shall immediately take all steps required by Environmental Law to remedy or otherwise address the situation giving rise to any Release.
(c) If any work is required in accordance with this section 9.2 the Tenant shall prepare all necessary studies, plans and proposals and submit them to the Landlord for approval, which approved shall not be unreasonably withheld, provide all bonds and other security required by any lawful governmental authorities and carry out the work required. In carrying out such work, the Tenant shall keep the Landlord fully informed of the progress of the work. If the Landlord has reasonable grounds for believing that the Tenant will not promptly or properly carry out such work, the Landlord may, in its sole discretion, elect to carry out all such work, or any part of it, and if the Landlord does so, the Tenant shall pay for all costs in connection therewith, within thirty (30) days after the Landlord has incurred the costs and made written demand to the Tenant.
(d) The Tenant covenants, acknowledges and agrees that its obligations and liabilities under this Section shall survive the expiration or earlier termination of this Lease.
Limitation of Responsibility Notwithstanding any other provisions ---------------------------- hereof, Committee Members shall be liable to the parties only for actions constituting bad faith, gross negligence or breach of an express provision of this Agreement (so long as such breach remains uncured after ten (10) days of receiving notice of the nature of such breach). In all other respects, Committee Members shall not be liable for negligence or mistakes of judgment.
Landlord’s Responsibility During the term of this Lease, Landlord shall maintain in good condition and repair, and replace as necessary, the roof, exterior walls, foundation and structural frame of the Building and the parking and landscaped areas, the costs of which shall be included in Operating Expenses; provided, however, that to the extent any of the foregoing items require repair because of the negligence, misuse, or default of Tenant, its employees, agents, customers or invitees, Landlord shall make such repairs solely at Tenant's expense.
CONTRACTOR'S RESPONSIBILITY 1.1. The Basic Services to be performed by CONTRACTOR hereunder is the Citywide Landscape Maintenance.
1.2. The CONTRACTOR agrees to obtain and maintain throughout the period of this Agreement all such licenses as are required to do business in the State of Florida, the City of Naples, and in Xxxxxxx County, Florida, including, but not limited to, all licenses required by the respective state boards and other governmental agencies responsible for regulating and licensing the professional services to be provided and performed by the CONTRACTOR pursuant to this Agreement.
1.3. The CONTRACTOR agrees that, when the services to be provided hereunder relate to a professional service which, under Florida Statutes, requires a license, certificate of authorization or other form of legal entitlement to practice such services, it shall employ and/or retain only qualified personnel to provide such services.
1.4. CONTRACTOR agrees to employ and designate, in writing, within five (5) calendar days after receiving its Notice to Proceed, a qualified licensed professional to serve as the CONTRACTOR's project manager (hereinafter referred to as the "Project Manager"). The Project Manager shall be authorized and responsible to act on behalf of the CONTRACTOR with respect to directing, coordinating and administering all aspects of the services to be provided and performed under this Agreement.
1.5. The CONTRACTOR has represented to the OWNER that it has expertise in the type of professional services that will be required for the Project. The CONTRACTOR agrees that all services to be provided by CONTRACTOR pursuant to this Agreement shall be subject to the OWNER's review and approval and shall be in accordance with the generally accepted standards of professional practice in the State of Florida, as well as in accordance with all published laws, statutes, ordinances, codes, rules, regulations and requirements of any governmental agencies which regulate or have jurisdiction over the Project or the services to be provided and performed by CONTRACTOR hereunder. In the event of any conflicts in these requirements, the CONTRACTOR shall notify the OWNER of such conflict and utilize its best professional judgment to advise OWNER regarding resolution of the conflict.
1.6. CONTRACTOR agrees not to divulge, furnish or make available to any third person, firm or organization, without OWNER's prior written consent, or unless incident to the proper performance of the CONTRACTOR's obligations hereunder, or in the course of judicial or legislative proceedings where such information has been properly subpoenaed, any non-public information concerning the services to be rendered by CONTRACTOR hereunder, and CONTRACTOR shall require all of its employees, agents, subconsultants and subcontractors to comply with the provisions of this paragraph.
Tenant’s Responsibilities Except as expressly provided in Paragraph 10.1 above, Tenant shall, at its sole cost, maintain the entire Premises and every part thereof, including without limitation, windows, skylights, window frames, plate glass, freight docks, doors and related hardware, interior walls and partitions, and the electrical, plumbing, lighting, heating and air conditioning systems in good order, condition and repair. Tenant shall deliver to Landlord, every six (6) months during the Lease Term, a certificate of maintenance or its equivalent, signed by a licensed HVAC repair and maintenance contractor and stating that the heating and air conditioning systems servicing the Premises have been inspected, serviced and are in good order, condition and repair. Tenant's failure to deliver said certificate or its equivalent within thirty (30) days following written notice from Landlord that said certificate is past due shall be a Default by Tenant. If Tenant fails to make repairs or perform maintenance work required of Tenant hereunder within fifteen (15) days after notice from Landlord specifying the need for such repairs or maintenance work, Landlord or Landlord's agents may, in addition to all other rights and remedies available hereunder or by law and without waiving any alternative remedies, enter into the Premises and make such repairs and/or perform such maintenance work. If Landlord makes such repairs and/or performs such maintenance work, Tenant shall reimburse Landlord upon demand and as Additional Rent, for the cost of such repairs and/or maintenance work. Landlord shall have no liability to Tenant for any damage, inconvenience or interference with the use of the Premises by Tenant or Tenant's agents as a result of Landlord performing any such repairs or maintenance (unless such damage, inconvenience or interference is caused by the gross negligence or willful misconduct of Landlord or its agents, employees or contractors); provided, however, under no circumstances shall Landlord be liable to Tenant for claims of lost profits, loss of business or lost income. Tenant shall reimburse Landlord, on demand and as Additional Rent, for the cost of damage to the Premises and/or Common Area caused by Tenant or Tenant's agents, employees or contractors. Tenant expressly waives the benefits of any statute now or hereafter in effect (including without limitation the provisions of subsection 1 of Section 1932, Section 1941 and Section 1942 of the California Civil Code and any similar law, statute or ordinance now or hereafter in effect) which would otherwise afford Tenant the right to make repairs at Landlord's expense (or to deduct the cost of such repairs from Rentals due hereunder) or to terminate this Lease because of Landlord's failure to keep the Premises in good and sanitary order.
Contractor Responsibility (a) The Contractor shall be responsible for the entire Performance under the Contract regardless of whether the Contractor itself performs. The Contractor shall be the sole point of contact concerning the management of the Contract, including Performance and payment issues. The Contractor is solely and completely responsible for adherence by the Contractor Parties to all applicable provisions of the Contract.
(b) The Contractor shall exercise all reasonable care to avoid damage to the State's property or to property being made ready for the State's use, and to all property adjacent to any work site. The Contractor shall promptly report any damage, regardless of cause, to the State.
CONSULTANT’S RESPONSIBILITIES In addition to all other obligations contained herein, the Consultant agrees, warrants, and represents that:
6.1 The Consultant will furnish all material, equipment, labor and supplies in such quantities and of the proper quality to professionally and timely perform the Services, except as otherwise mutually agreed by the Parties;
6.2 The Consultant shall perform the Services with the professional skill and care ordinarily provided by competent consultants practicing in the same or similar locality and under the same or similar circumstances and professional license;
6.3 The Consultant will comply with the provisions of all federal, state, and local laws, regulations, ordinances, requirements and codes which are applicable to its performance of Services;
6.4 The Consultant is not and will not be bound by any agreement and has not assumed nor will assume any obligation which would, in any way, restrict its ability to perform the Services or be inconsistent with the Services;
6.5 In performing the Services, the Consultant will not use any third party’s confidential or propriety information, or infringe the rights of another party, nor will the Consultant disclose to the Authority, or bring onto the Authority’s premises, or induce the Authority to use any third party’s confidential or proprietary information;
6.6 The Consultant does not have the authority to act for the Authority, bind the Authority in any respect, or incur any debts or liabilities in the name of or on behalf of the Authority, except as otherwise expressly authorized in writing by the Authority;
6.7 Consultant is an independent contractor for the performance of his duties under this Contract. Accordingly, the Consultant shall be responsible for payment of all taxes including federal, state and local taxes arising out of the Consultant’s activities in accordance with this Contract. Consultant is responsible for payment of the compensation, including any withholding, Social Security, or other taxes on such compensation, of any subcontractors retained by Consultant, or Consultant's employees performing Services consistent with its status as an independent contractor and in compliance with all applicable laws and regulations;
6.8 Consultant has and hereby retains full control of any supervision over the Consultant’s obligations hereunder and over any persons employed or subcontracted by the Consultant for performing Services hereunder;
6.9 Consultant will in no way be considered an agent, partner, joint venturer, or employee of Authority at any time during the Term. Consultant will not undertake to commit Authority to any course of action in relation to a third party unless expressly requested and authorized to do so by the Authority in writing.
6.10 As of the Effective Date and at all times while providing Services hereunder, the Consultant shall possess and maintain in good standing any and all licenses or other authorizations and approvals necessary to perform the Services.
Client’s Responsibilities (a) Client agrees to advise Consultant regarding Client's Project requirements and to provide all relevant information, surveys, data and previous reports accessible to Client which Consultant may reasonably require.
(b) Client shall designate a Project Representative to whom all communications from Consultant shall be directed and who shall have limited administrative authority on behalf of Client to receive and transmit information and make decisions with respect to the Project. Said representative shall not, however, have authority to bind Client as to matters of governmental policy or fiscal policy, nor to contract for additions or obligations exceeding a value which is the lesser of $5000 or 5% of the maximum contract price.
(c) Client shall examine all documents presented by Consultant, and render decisions pertaining thereto within a reasonable time. The Client's approval of any drawings, specifications, reports, documents or other materials or product furnished hereunder shall not in any way relieve Consultant of responsibility for the professional adequacy of its work.
(d) Client shall perform its obligations and render decisions within a reasonable time under the circumstances presented. Based upon the nature of Client and its requirements, a period of 14 days shall be presumed reasonable for any decision not involving policy decision or significant financial impact, when all information reasonably necessary for Client to responsibly render a decision has been furnished. A period of 46 days shall be presumed reasonable for Client to act with respect to any matter involving policy or significant financial impact. The above periods of presumed reasonableness shall be extended where information reasonably required is not within the custody or control of Client but must be procured from others.
