LIMITATION OF LIABILITY AND REMEDIES Esri will use commercially reasonable efforts to provide corrections or workaround solutions for any problem or issue reported and determined to be in the Software or the documentation at no cost to Licensee for the term of this Agreement. While it is Esri's goal to provide an acceptable resolution for incoming problems/issues and incidents, Esri cannot predict a resolution time and is unable to guarantee that all problems or issues can be resolved or addressed. EXCEPT FOR THE ABOVE EXPRESS LIMITED WARRANTY, ESRI DISCLAIMS ALL OTHER WARRANTIES OF ANY KIND, EITHER EXPRESS OR IMPLIED, INCLUDING, BUT NOT LIMITED TO, THE IMPLIED WARRANTIES OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, NONINTERFERENCE, SYSTEM INTEGRATION, AND NONINFRINGEMENT. ESRI DOES NOT WARRANT THAT THE SOFTWARE OR DOCUMENTATION WILL MEET LICENSEE'S NEEDS, OR THAT LICENSEE'S OPERATION OF THE SAME WILL BE UNINTERRUPTED OR ERROR FREE, OR THAT ALL NONCONFORMITIES CAN OR WILL BE CORRECTED. If Esri fails to fulfill its obligations under this Agreement, Licensee's sole and exclusive remedy is the right to terminate this Agreement immediately for the affected Software. IN NO EVENT SHALL ESRI BE LIABLE TO LICENSEE FOR COSTS OF PROCUREMENT OF SUBSTITUTE GOODS OR SERVICES; LOST PROFITS; LOST SALES OR BUSINESS EXPENDITURES; INVESTMENTS; OR COMMITMENTS IN CONNECTION WITH ANY BUSINESS, LOSS OF ANY GOODWILL, OR FOR ANY INDIRECT, SPECIAL, INCIDENTAL, OR CONSEQUENTIAL DAMAGES ARISING OUT OF OR RELATED TO THIS AGREEMENT OR USE OF THE SOFTWARE OR DOCUMENTATION, HOWEVER CAUSED, ON ANY THEORY OF LIABILITY, AND WHETHER OR NOT ESRI HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGE. THESE LIMITATIONS SHALL APPLY NOTWITHSTANDING ANY FAILURE OF ESSENTIAL PURPOSE OF ANY LIMITED REMEDY.
Limitation of Liabilities IN NO EVENT WILL LICENSOR BE LIABLE FOR ANY LOSS OF PROFITS, LOSS OF USE, BUSINESS INTERRUPTION, LOSS OF DATA, COST OF COVER OR INDIRECT, SPECIAL, INCIDENTAL OR CONSEQUENTIAL DAMAGES OF ANY KIND, WHETHER ALLEGED AS A BREACH OF CONTRACT OR TORTIOUS CONDUCT, INCLUDING NEGLIGENCE, EVEN IF LICENSOR HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES. IN NO EVENT SHALL LICENSOR BE LIABLE TO LICENSEE OR ANY SUBLICENSEE OR ANY OTHER ENTITY FOR ANY DAMAGES OR LOSS CAUSED BY DELAY IN DELIVERY OR FURNISHING OF DATA USING THE INTELLECTUAL PROPERTY. IN ADDITION, LICENSOR SHALL NOT BE LIABLE FOR DAMAGES OF ANY KIND WHATSOEVER IN EXCESS OF TWO MILLION FIVE HUNDRED THOUSAND DOLLARS ($2,500,000.00). THE FOREGOING LIMITATIONS SHALL NOT APPLY TO (I) INDEMNIFICATION OBLIGATIONS; (II) ANY CLAIMS FOR PERSONAL INJURY OR DEATH, OR DAMAGE TO PROPERTY; OR (III) ANY CLAIMS BASED UPON LICENSOR'S GROSS NEGLIGENCE OR WILLFUL MISCONDUCT; OR (IV) BREACHES OF THE CONFIDENTIALITY OBLIGATIONS.
Limitation of Liability No provision hereof, in the absence of any affirmative action by the Holder to exercise this Warrant to purchase Warrant Shares, and no enumeration herein of the rights or privileges of the Holder, shall give rise to any liability of the Holder for the purchase price of any Common Stock or as a stockholder of the Company, whether such liability is asserted by the Company or by creditors of the Company.
Tenant’s Remedies/Limitation of Liability Landlord shall not be in default hereunder unless Landlord fails to perform any of its obligations hereunder within 30 days after written notice from Tenant specifying such failure (unless such performance will, due to the nature of the obligation, require a period of time in excess of 30 days, then after such period of time as is reasonably necessary). Upon any default by Landlord, Tenant shall give notice by registered or certified mail to any Holder of a Mortgage covering the Premises and to any landlord of any lease of property in or on which the Premises are located and Tenant shall offer such Holder and/or landlord a reasonable opportunity to cure the default, including time to obtain possession of the Project by power of sale or a judicial action if such should prove necessary to effect a cure; provided Landlord shall have furnished to Tenant in writing the names and addresses of all such persons who are to receive such notices. All obligations of Landlord hereunder shall be construed as covenants, not conditions; and, except as may be otherwise expressly provided in this Lease, Tenant may not terminate this Lease for breach of Landlord’s obligations hereunder. All obligations of Landlord under this Lease will be binding upon Landlord only during the period of its ownership of the Premises and not thereafter. The term “Landlord” in this Lease shall mean only the owner for the time being of the Premises. Upon the transfer by such owner of its interest in the Premises, such owner shall thereupon be released and discharged from all obligations of Landlord thereafter accruing, but such obligations shall be binding during the Term upon each new owner for the duration of such owner’s ownership.
INDEMNITIES AND LIMITATION OF LIABILITY 16.1. In addition to the indemnification provisions contained in this Agreement, Principal agrees to indemnify, defend and hold harmless Custodian and its affiliates providing services under this Agreement, including their respective officers, directors, agents and employees from all taxes, charges, expenses, assessments, claims and liabilities including, without limitation, reasonable attorneys' fees and disbursements and liabilities ("Claims") arising directly or indirectly from any action or omission to act which Custodian takes in connection with the provision of services to Principal. Neither Custodian, nor any of its affiliates, shall be indemnified against any liability (or any expenses incident to such liability) caused by Custodian’s or its affiliates' own willful misfeasance, bad faith, gross negligence or reckless disregard in the performance of Custodian's or its affiliates' activities under this Agreement. The provisions of this Paragraph 15 shall survive termination of this Agreement.
16.2. In all cases, Custodian’s liability under this Agreement shall be limited to the resulting direct loss, if any, incurred by Principal. Under no circumstances shall Custodian be liable for any incidental, consequential, indirect, punitive, or special damage which Principal may incur or suffer in connection with this Agreement.
Limitation of Liability of JCM JCM shall not be liable for any error of judgment or mistake of law or for any loss arising out of any investment or for any act or omission taken with respect to the Trust, except for willful misfeasance, bad faith or gross negligence in the performance of its duties, or by reason of reckless disregard of its obligations and duties hereunder and except to the extent otherwise provided by law. As used in this Section 14, "JCM" shall include any affiliate of JCM performing services for the Trust contemplated hereunder and directors, officers and employees of JCM and such affiliates.
Exclusion and Limitation of Liability 10.1 SUPPLIER DOES NOT EXCLUDE OR LIMIT ITS LIABILITY (IF ANY) TO BUYER FOR ANY MATTER FOR WHICH IT WOULD BE ILLEGAL FOR SUPPLIER TO EXCLUDE OR LIMIT OR TO ATTEMPT TO EXCLUDE OR LIMIT ITS LIABILITY.
10.2 OTHER THAN ANY LIABILITY OF SUPPLIER ARISING UNDER CLAUSE 10.1, WHICH SHALL NOT BE LIMITED, AND WITHOUT PREJUDICE TO THE OTHER PROVISIONS OF THIS CLAUSE 10 (EXCLUSION AND LIMITATION OF LIABILITY), SUPPLIER'S AGGREGATE LIABILITY AS DEFINED IN PART D (DEFINITIONS AND INTERPRETATION) UNDER EACH CONTRACT WILL BE LIMITED TO AN AMOUNT EQUAL TO THE GREATER OF 115% OF THE AMOUNT PAID BY BUYER TO SUPPLIER UNDER THAT CONTRACT OR $10,000.00.
10.3 EXCEPT AS PROVIDED IN CLAUSE 10.1, SUPPLIER WILL BE UNDER NO LIABILITY AS DEFINED IN PART D (DEFINITIONS AND INTERPRETATION) TO BUYER WHATSOEVER IN RESPECT OF
10.3.1 ANY CLAIM ARISING OUT OF AN EVENTWHICH IS CAUSED, OR CONTRIBUTED TO, BY THE GOODS AND SUCH EVENT OCCURS AFTER THE COMMENCEMENT OF THE LAUNCH PROCEDURE OF THE VEHICLE CARRYING SUCH GOODS INTO SPACE;
10.3.2 PURE ECONOMIC LOSS, LOSS OF PROFITS, LOSS OF BUSINESS, LOSS OF REVENUE, LOSS OF CONTRACTS, LOSS OF GOODWILL, LOSS OF ANTICIPATED EARNINGS OR SAVINGS (WHETHER DIRECT, INDIRECT, INCIDENTAL OR CONSEQUENTIAL) OR
10.3.3 LOSS OF USE OR VALUE OR DAMAGE OF ANY DATA OR EQUIPMENT (INCLUDING SOFTWARE), WASTED MANAGEMENT, OPERATION OR OTHER TIME (WHETHER DIRECT, INDIRECT, INCIDENTAL OR CONSEQUENTIAL) OR
10.3.4 ANY SPECIAL, INDIRECT, PUNITIVE, INCIDENTAL OR CONSEQUENTIAL LOSS, IN EACH CASE HOWSOEVER CAUSED ARISING OUT OF OR IN CONNECTION WITH:
10.3.5 ANY OF THE WORKS, OR THE MANUFACTURE OR SALE OR SUPPLY, OR FAILURE OR DELAY IN SUPPLY, OF THE WORKS BY SUPPLIER OR ON THE PART OF SUPPLIER’S EMPLOYEES, AGENTS OR SUBCONTRACTORS;
10.3.6 ANY BREACH BY SUPPLIER OF ANY OF THE EXPRESS OR IMPLIED TERMS OF THE CONTRACT;
10.3.7 ANY USE MADE OR RESALE BY BUYER OF ANY OF THE WORKS, OR OF ANY PRODUCT INCORPORATING ANY OF THE WORKS; OR
10.3.8 ANY STATEMENT MADE OR NOT MADE, OR ADVICE GIVEN OR NOT GIVEN, BY OR ON BEHALF OF SUPPLIER.
10.4 EXCEPT AS EXPRESSLY SET OUT IN THE CONTRACT, SUPPLIER HEREBY EXCLUDES TO THE FULLEST EXTENT PERMISSIBLE IN LAW, ALL CONDITIONS, WARRANTIES AND STIPULATIONS, EXPRESS (OTHER THAN THOSE SET OUT IN THE CONTRACT) OR IMPLIED, STATUTORY, CUSTOMARY OR OTHERWISE WHICH, BUT FOR SUCH EXCLUSION, WOULD OR MIGHT SUBSIST IN FAVOR OF BUYER, INCLUDING, WITHOUT LIMITATION, ANY WARRANTY OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE.
10.5 EACH OF SUPPLIER’S EMPLOYEES, AGENTS AND SUBCONTRACTORS MAY RELY UPON AND ENFORCE THE EXCLUSIONS AND RESTRICTIONS OF LIABILITY IN THE CONTRACT IN THAT PERSON’S OWN NAME AND FOR THAT PERSON’S OWN BENEFIT, AS IF THE WORDS “ITS EMPLOYEES, AGENTS AND SUBCONTRACTORS” FOLLOWED THE WORD SUPPLIER WHEREVER IT APPEARS IN THOSE CLAUSES SAVE FOR EACH REFERENCE IN CLAUSE10.3.5.
10.6 BUYER ACKNOWLEDGES THAT THE ABOVE PROVISIONS OF THIS CLAUSE 10 (EXCLUSION AND LIMITATION OF LIABILITY) ARE REASONABLE AND REFLECTED IN THE PRICE WHICH WOULD BE HIGHER WITHOUT THOSE PROVISIONS, AND BUYER WILL ACCEPT SUCH RISK AND/OR INSURE ACCORDINGLY.
10.7 BUYER IS SOLELY RESPONSIBLE AND LIABLE FOR THE PROPER LEGAL DISPOSAL OF ALL MATERIALS PURCHASED FROM SUPPLIER AT THE END-OF- LIFE CYCLE OF SUCH MATERIALS.
Limitation of Liability for Claims The Declaration, a copy of which, together with all amendments thereto, is on file in the Office of the Secretary of the Commonwealth of Massachusetts, provides that the name "Investors Fund Series" refers to the Trustees under the Declaration collectively as Trustees and not as individuals or personally, and that no shareholder of the Fund, or Trustee, officer, employee or agent of the Trust, shall be subject to claims against or obligations of the Trust or of the Fund to any extent whatsoever, but that the Trust estate only shall be liable. You are hereby expressly put on notice of the limitation of liability as set forth in the Declaration and you agree that the obligations assumed by the Trust on behalf of the Fund pursuant to this Agreement shall be limited in all cases to the Fund and its assets, and you shall not seek satisfaction of any such obligation from the shareholders or any shareholder of the Fund or any other series of the Trust, or from any Trustee, officer, employee or agent of the Trust. You understand that the rights and obligations of each Fund, or series, under the Declaration are separate and distinct from those of any and all other series.
Indemnification and Limitation of Liability (a) In the absence of willful misfeasance, bad faith, gross negligence or reckless disregard of obligations or duties hereunder on the part of FSSC and its trustees, officers, employees, agents and representatives, the Funds agree to indemnify FSSC and its trustees, officers, employees, agents and representatives against any and all claims, demands, liabilities and reasonable expenses (including attorneys’ fees), related to or otherwise connected with (i) any breach by the Funds of any provision of this Agreement; or (ii) any action by a Fund’s Shareholder against FSSC.
(b) FSSC shall not be liable for any error of judgment or mistake of law or for any loss suffered by any Fund in connection with the matters to which this Agreement relates, except a loss resulting from willful misfeasance, bad faith or gross negligence on its part in the performance of its duties or from reckless disregard by it of its obligations and duties under this Agreement. In no event shall FSSC be liable for indirect or consequential damages.
(c) Any person, even though also an officer, trustee, partner, employee or agent of FSSC, who may be or become an officer, employee or agent of any Fund or a member of a Fund's Board, shall be deemed, when rendering services to such Fund or acting on any business of such Fund (other than services or business in connection with the duties of FSSC hereunder) to be rendering such services to or acting solely for such Fund and not as an officer, trustee, partner, employee or agent or one under the control or direction of FSSC even though paid by FSSC.
(d) FSSC is expressly put on notice of the limitation of liability as set forth in the Declaration of Trust of each Fund that is a Massachusetts business trust and agrees that the obligations assumed by each such Fund pursuant to this Agreement shall be limited in any case to such Fund and its assets and that FSSC shall not seek satisfaction of any such obligations from the Shareholders of such Fund, the Trustees, Officers, Employees or Agents of such Fund, or any of them.
(e) The provisions of this Section shall survive the termination of this Agreement.
Indemnification Limitation of Liability This Section 10 shall survive the termination of this Agreement.
a. The Participant hereby agrees to indemnify and hold harmless the Distributor, Trust, Funds, Transfer Agent and their respective subsidiaries, Affiliated Persons, directors, officers, employees and agents, and each person, if any, who controls such persons within the meaning of Section 15 of the 1933 Act (each a “Participant-Indemnified Party”) from and against any loss, liability, cost and expense (including reasonable attorneys’ fees, collectively “Losses”) incurred by such Participant-Indemnified Party as a result of (i) any breach by the Participant of any provision of this Agreement; (ii) any failure on the part of the Participant to perform any of its obligations set forth in this Agreement; (iii) any failure by the Participant to comply with applicable Law; (iv) representations by any Distributor-Indemnified Party or any Participant Client about the Shares or any Participant-Indemnified Party (including the Trust and/or Fund(s)) that is not included in the Trust’s then-current Prospectus; (v) any untrue statement or alleged untrue statement of a material fact contained in any Section 8.b Materials or any alleged omission to state therein a material fact required to be stated therein or necessary to make the statements therein, in light of the circumstances under which they were made, not misleading to the extent that such statement or omission relates to the Shares or any Participant-Indemnified Party unless, in either case, such representation, statement or omission was included by the Participant at the written direction of the Trust or the Distributor or taken verbatim (in context and without omission) from the Prospectus or marketing material approved by the Distributor and the Trust; and (vi) actions of such Participant-Indemnified Party in reliance upon any instructions issued to the Trust, the Distributor or the Transfer Agent reasonably believed by any of them to be genuine and to have been given by the Participant or an Authorized Person. The foregoing shall not apply to any Losses incurred by any Participant-Indemnified Party arising out of any Participant-Indemnified Party’s own fraud, bad faith, willful misconduct, gross negligence or reckless disregard of its duties hereunder.
b. The Distributor hereby agrees to indemnify and hold harmless the Participant, its respective subsidiaries, Affiliated Persons, directors, officers, employees and agents, and each person, if any, who controls such persons within the meaning of Section 15 of the 1933 Act (each a “Distributor-Indemnified Party”) from and against any Losses incurred by such Distributor-Indemnified Party as a result of (i) any breach by the Distributor of any provision of this Agreement; (ii) any failure on the part of the Distributor to perform any of its obligations set forth in this Agreement; (iii) any failure by the Distributor to comply with applicable Law; (iv) any untrue statement or alleged untrue statement of a material fact contained in the Prospectus or any alleged omission to state therein a material fact required to be stated therein or necessary to make the statements therein, in light of the circumstances under which they were made, not misleading, other than any statement made or omitted in reliance upon information provided to the Distributor, the Trust or any other person on behalf of the Trust or the Fund by a Distributor-Indemnified Party in writing and (v) actions of such Distributor-Indemnified Party in reliance upon any instructions reasonably believed by the Participant to be genuine and to have been given by the Distributor. The foregoing shall not apply to any Losses incurred by any Distributor-Indemnified Party arising out of any Distributor-Indemnified Party’s own fraud, bad faith, willful misconduct, gross negligence or reckless disregard of its duties hereunder.
c. Notwithstanding anything to the contrary in this Agreement, the Distributor, the Transfer Agent and the Fund will not indemnify the Participant for any violations of the U.S. federal or state securities laws (or other applicable Law) committed by the Participant through its failure to deliver a Prospectus in connection with the offer or sale of Shares and for any oral or written representation or warranty by Participant that is not contained in the Prospectus.
d. Notwithstanding anything to the contrary in this Agreement, none of the Participant, Distributor, Trust or Transfer Agent shall be liable to each other for any Losses under this Agreement arising out of (i) mistakes or errors in data provided in connection with Orders, except for data provided by the other or (ii) mistakes or errors by or out of interruptions or delays of communications with a service provider to the Trust.
e. Each of the Participant, Distributor and Transfer Agent undertakes to perform such duties and only such duties as are expressly set forth herein, or expressly incorporated herein by reference, and no implied covenants or obligations shall be read into this Agreement.
f. In the absence of fraud, bad faith, gross negligence, willful misconduct, or reckless disregard on its part, neither the Distributor nor the Transfer Agent, whether acting directly or through agents or attorneys, shall be liable for any action taken or omitted, or for any error of judgment made, in the performance of their duties hereunder.
g. In no event shall any Party be liable for special, indirect or consequential loss or damage of any kind whatsoever (including but not limited to lost profits), even if advised of the likelihood of such loss or damage and regardless of the form of action. In no event shall any Party be liable under this Agreement to another Party for the acts or omissions of the CNS Clearing Process, DTC, NSCC, the Custodian or any securities depository, clearing corporation, exchange or communications service.
h. None of the Distributor, the Transfer Agent or the Trust shall be liable for any failure or delay in the performance of its obligations or those of its agents under this Agreement arising out of or caused, directly or indirectly, by circumstances beyond its reasonable control, including without limitation: acts of God; earthquakes; extreme weather events, including blizzards, hurricanes, tornados thunder storms, fires and floods; wars; civil or military disturbances; blackouts; terrorism; breakdowns in communications systems; riots; loss or malfunction of utilities or computer or internet services; labor disputes; acts of any civil, military or governmental authority.
i. Neither the Transfer Agent nor the Distributor shall be required to advance, expend or risk its own funds or otherwise incur or become exposed to financial liability in the performance of its duties hereunder.
