Notice of Subsequent Events If at any time during the ninety (90) day period after the Registration Statement becomes effective, any rumor, publication or event relating to or affecting the Company shall occur as a result of which in your opinion the market price of the Company Shares has been or is likely to be materially affected (regardless of whether such rumor, publication or event necessitates a supplement to or amendment of the Prospectus), the Company will, after written notice from you advising the Company to the effect set forth above, forthwith prepare, consult with you concerning the substance of and disseminate a press release or other public statement, reasonably satisfactory to you, responding to or commenting on such rumor, publication or event.
Landlord Default If Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement or any obligation of Landlord, if any, under any agreement affecting the Leased Property, the performance of which is not Tenant’s obligation pursuant to this Agreement, and any such default shall continue for a period of thirty (30) days after Notice thereof from Tenant to Landlord and any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct the same, Tenant may declare the occurrence of a “Landlord Default” by a second Notice to Landlord and to such Facility Mortgagee. Thereafter, Tenant may forthwith cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys’ fees and court costs) incurred by Tenant in curing the same, together with interest thereon (to the extent permitted by law) from the date Landlord receives Tenant’s invoice until paid, at the Overdue Rate. Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof. If Tenant and Landlord shall fail, in good faith, to resolve any such dispute within ten (10) days after Landlord’s Notice of dispute, either may submit the matter for resolution in accordance with Article 22.
Subsequent Events If, at any time on or after an Applicable Time but prior to the related Settlement Date, any event occurs as a result of which the Registration Statement or Prospectus would include any untrue statement of a material fact or omit to state any material fact necessary to make the statements therein in the light of the circumstances under which they were made or the circumstances then prevailing not misleading, the Company will (i) notify promptly the Manager so that any use of the Registration Statement or Prospectus may cease until such are amended or supplemented; (ii) amend or supplement the Registration Statement or Prospectus to correct such statement or omission; and (iii) supply any amendment or supplement to the Manager in such quantities as the Manager may reasonably request.
Not to Prevent Events of Default The failure to make a payment on account of principal of, premium, if any, or interest on the Notes by reason of any provision of this Article Ten will not be construed as preventing the occurrence of an Event of Default.
Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):
(i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord;
(ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed;
(iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord;
(iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed;
(v) Construction of any Change Requests;
(vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible);
(vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein;
(viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord;
(ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or
(x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.
Lease Events of Default The following events shall constitute Lease Events of Default hereunder (whether any such event shall be voluntary or involuntary or come about or be effected by operation of law or pursuant to or in compliance with any judgment, decree or order of any court or any order, rule or regulation of any administrative or governmental body) and each such Lease Event of Default shall be deemed to exist and continue so long as, but only as long as, it shall not have been remedied:
(a) Lessee shall fail to (i) make or (ii) be deemed by virtue of the last sentence of Section 3.5 hereof to have made any payment of Basic Rent, Early Purchase Price, any other purchase price to be paid by Lessee for any Units pursuant to this Lease or the Participation Agreement, Stipulated Loss Amount or Termination Amount (x) in the case of any such payment that is required to be made on the Basic Term Expiration Date or on any date within 30 days before the Basic Term Expiration Date, when due, and (y) in the case of any other such payment, within 10 Business Days after the same shall have become due; provided, however, that so long as any Equipment Notes remain outstanding, failure to make (or be deemed to have made) any portion of Basic Rent on any Rent Payment Date shall not be a Lease Event of Default so long as the amounts applied under Section 3.4, clause (4), of the Collateral Agency Agreement are sufficient to make the distributions required under such clause (4) with respect to the obligations owed under this Lease; provided, further, that in the event that the Special Equity Buy-Out has been consummated, failure to make any payment of Basic Rent, Early Purchase Price, any other purchase price to be paid by Lessee for any Units pursuant to this Lease or the Participation Agreement, Stipulated Loss Amount or Termination Amount (to the extent such amount constitutes an Accumulated Equity Deficiency Amount to be applied under Section 3.4, clause 9 of the Collateral Agency Agreement) shall, after receipt by Lessee of written notice of such failure from Lessor or Owner Participant, be a Lease Event of Default; or
(b) Lessee shall fail to (i) make or (ii) be deemed by virtue of payments made by the Collateral Agent to have made any payment of Supplemental Rent, including indemnity or tax indemnity payments, but not including Stipulated Loss Amount, Termination Amount, Early Purchase Price, or any other purchase price to be paid by Lessee for any Units pursuant to this Lease or the Participation Agreement (x) in the case of any such payment that is required to be on the Basic Term Expiration Date or on any date within 30 days before the Basic Term Expiration Date, when due, and (y) in the case of any other such payment, after the same shall have become due and such failure shall continue unremedied for 30 days after receipt by Lessee of written notice of such failure from Lessor, Policy Provider, Owner Participant or the Indenture Trustee; provided, however, that so long as any Equipment Notes remain outstanding, failure to make (or be deemed to have made) payment of any of the amounts referred to in or to be applied pursuant to clauses (5) through (15) of Section 3.4 of the Collateral Agency Agreement shall not be a Lease Event of Default; or
(c) Lessee shall fail to maintain in effect the insurance required by Section 12 or Section 6.4 of the Collateral Agency Agreement and such failure shall not have been waived as provided for therein; or
(d) Lessee shall use or permit the use of the Units or the Pledged Units or any portion thereof in a way which is not permitted by this Lease (with respect to the Units) or the Collateral Agency Agreement (with respect to the Pledged Units), provided that such unauthorized use shall not constitute a Lease Event of Default for a period of 45 days after Lessee's obtaining actual knowledge thereof so long as (i) such unauthorized use is not the result of any willful action of Lessee and (ii) such unauthorized use is capable of being cured and Lessee diligently pursues such cure throughout such 45-day period; or Lessee shall make or permit any unauthorized assignment or transfer of this Lease in violation of Section 18.2; or
(e) TILC (or any successor thereto in its capacity as Administrator or Servicer, as applicable) shall have defaulted in any material respect in the performance of any of its obligations under the Administrative Services Agreement or the Servicing Agreement or a default shall occur under Section 6(a) of the Account Administration Agreement, and, in each case, Lessee shall have failed to exercise its rights thereunder in respect of such default for a period of 30 days after receipt by Lessee of written notice from Lessor, Owner Participant, Policy Provider or the Indenture Trustee, demanding that such action be taken; or
(f) Any representation or warranty made by Lessee in any Lessee Agreement or any representation or warranty made by TILC in any Operative Agreement to which any such Person is a party, in each case, other than the Tax Indemnity Agreement, is untrue or incorrect in any material respect as of the date of making thereof and such untruth or incorrectness shall continue to be material and unremedied for a period of 30 days after receipt of notice from Lessor, Owner Participant, Indenture Trustee or the Policy Provider; provided that, if such untruth or incorrectness is capable of being remedied, no such untruth or incorrectness shall constitute a Lease Event of Default hereunder for a period of 120 days after receipt of notice from Lessor, Owner Participant, the Indenture Trustee or the Policy Provider so long as Lessee, TILC or TRMI, as the case may be, is diligently proceeding to remedy such untruth or incorrectness and shall in fact remedy such untruth or incorrectness within such period; provided that such untrue or incorrect representation or warranty shall be deemed to be remediable or remedied only after all adverse consequences thereof if any, can be and have been remedied as applicable; or
(g) Lessee or the General Partner shall (i) commence a voluntary case or other proceeding seeking liquidation, reorganization or other relief with respect to itself or its debts under any bankruptcy, insolvency or other similar law now or hereafter in effect, or seeking the appointment of a trustee, receiver, liquidator, custodian or other similar official of it or any substantial part of its property, or (ii) consent to any such relief or to the appointment of or taking possession by any such official in any voluntary case or other proceeding commenced against it, or (iii) admit in writing its inability to pay its debts generally as they come due, or (iv) make a general assignment for the benefit of creditors, or (v) take any corporate or partnership action to authorize any of the foregoing; or
(h) An involuntary case or other proceeding shall be commenced against Lessee or the General Partner seeking liquidation, reorganization or other relief with respect to it or its debts under any bankruptcy, insolvency or other similar law now or hereafter in effect, or seeking the appointment of a trustee, receiver, liquidator, custodian or other similar official of it or any substantial part of its property, and such involuntary case or other proceeding shall remain undismissed and unstayed for a period of 60 days; or
(i) Lessee shall fail to observe or perform any other of the covenants or agreements to be observed or performed by Lessee under any Lessee Agreement or any certificate and such failure shall continue unremedied for 30 days after notice from Lessor, Owner Participant, Policy Provider or the Indenture Trustee to Lessee, specifying the failure and demanding the same to be remedied; provided that, if such failure is capable of being remedied, and the remedy requires an action other than, or in addition to, the payment of money, no such failure (other than one relating to the payment of such money) shall constitute a Lease Event of Default hereunder for a period of 150 days after receipt of such notice so long as Lessee is diligently proceeding to remedy such failure and shall in fact remedy such failure within such period; or
(j) A Manager Default shall have occurred and be continuing under the Management Agreement, and Lessee shall have failed to exercise its rights under the Management Agreement in respect of such Manager Default for a period of 30 days after receipt by Lessee of written notice from Lessor, Owner Participant or the Indenture Trustee demanding that such action be taken; or
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Tenant Default (a) Any of the following occurrences or acts shall constitute an “Event of Default” (herein so called) under this Lease: if (i) Tenant shall fail to pay any scheduled installment of Fixed Rent or Additional Rent when due and such failure shall continue uncured for a period of ten (10) days after Landlord notifies Tenant in writing of such failure (each an “Installment Default Notice”); or if, within a twelve (12) month period following delivery of not less than two (2) Installment Default Notices by Landlord, Tenant shall fail to pay any scheduled installment of Fixed Rent or Additional Rent when due and such failure shall continue uncured for a period of five (5) days or (ii) Tenant shall default in the payment when due of any installment of Additional Rent payable hereunder and such default shall continue for ten (10) days after notice of such default is sent to Tenant by Landlord (or Lender); or (iii) the failure by Tenant to maintain insurance as required under this Lease; or (iv) Tenant shall default in fulfilling any of the other covenants, agreements or obligations of this Lease, and such default shall continue for more than thirty (30) days after written notice thereof from Landlord (or Lender) specifying such default, provided, that if Tenant has commenced to cure a default described in subparagraph (iv) above within said thirty (30) days, and thereafter is in good faith diligently prosecuting same to completion and such default is of a nature such that it cannot be cured within such thirty (30) day period, said thirty (30) day period shall be extended, for a reasonable time (not to exceed an additional ninety (90) days) or, with respect to a breach of Tenant’s obligations under Section 40 of this Part II, such longer period as may reasonably be necessary to cure such default so long as (A) Tenant delivers to Landlord a certificate of a qualified environmental remediation specialist that such default could not be cured within such one hundred eighty (180) days but is curable, and (B) Tenant is in good faith diligently prosecuting such cure to completion) where, due to the nature of a default, it is unable to be completely cured within thirty (30) days; or (v) any execution or attachment shall be issued against Tenant or any of its property whereby the Premises shall be taken or occupied or attempted to be taken or occupied by someone other than Tenant, and the same shall not be bonded, dismissed, or discharged as promptly as possible under the circumstances; or (vi) Tenant or Guarantor (A) shall make any assignment or other similar act for the benefit of creditors, (B) shall file a petition or take any other action seeking relief under any state or federal insolvency or bankruptcy Laws, or (C) shall have an involuntary petition or any other action filed against either of them under any state or federal insolvency or bankruptcy Laws which petition or other action is not vacated or dismissed within sixty (60) days after the commencement thereof; or (vii) the estate or interest of Tenant in the Premises shall be levied upon or attached in any proceeding and such estate or interest is about to be sold or transferred and such process shall not be vacated or discharged within sixty (60) days after such levy or attachment; or (viii) the Guarantor’s guaranty of Tenant’s obligations under this Lease is terminated for any reason, or the Guarantor asserts in any pleading or judicial or administrative proceeding that such guaranty is void or unenforceable or that Guarantor is not liable thereunder; or (ix) any material representation or warranty made by Tenant or Guarantor to Landlord or the Lender herein or in any document delivered pursuant to this Lease is misleading or false in material respect when made, or (x) a default beyond applicable notice and cure periods shall occur in the fulfillment of any of the covenants, agreements or obligations of the tenant under any of the Related Leases and the premises demised thereby are then owned by the entity that is Landlord on the Lease Commencement Date or by one of its Affiliates.
(b) If an Event of Default shall have occurred and be continuing, Landlord shall be entitled to all remedies available at law or in equity. Without limiting the foregoing, Landlord shall have the right to give Tenant notice of Landlord’s termination of the Term of this Lease. Upon the giving of such notice, the Term of this Lease and the estate hereby granted shall expire and terminate on such date as fully and completely and with the same effect as if such date were the date herein fixed for the expiration of the Term of this Lease, and all rights of Tenant hereunder shall expire and terminate, but Tenant shall remain liable as hereinafter provided.
(c) If an Event of Default shall have occurred and be continuing, Landlord shall have the immediate right, whether or not the Term of this Lease shall have been terminated pursuant to Section 23(b) of this Part II, to re-enter and repossess the Premises and the right to remove all persons and property therefrom by summary proceedings, ejectment, any other legal action or in any lawful manner Landlord determines to be necessary or desirable. Landlord shall be under no liability by reason of any such reentry, repossession or removal. No such re-entry, repossession or removal shall be construed as an election by Landlord to terminate this Lease unless a notice of such termination is given to Tenant pursuant to Section 23(b) of this Part II.
(d) At any time or from time to time after a re-entry, repossession or removal pursuant to Section 23(c) of this Part II, whether or not the Term of this Lease shall have been terminated pursuant to Section 23(b) of this Part II, Landlord may (but, except to the extent expressly required by any applicable Law, shall be under no obligation to) relet the Premises for the account of Tenant, in the name of Tenant or Landlord or otherwise, without notice to Tenant, for such term or terms and on such conditions and for such uses as Landlord, in its absolute discretion, may determine. Landlord may collect any rents payable by reason of such reletting. Landlord shall not be liable for any failure to relet the Premises or for any failure to collect any rent due upon any such reletting, provided, however, that Landlord agrees to use reasonable efforts to relet the Premises for such rent and upon such terms as are not unreasonable under the circumstances, and if the full rental provided herein plus the reasonable costs, expenses and damages hereafter described shall not be realized by Landlord, Tenant shall be liable for all damages sustained by Landlord, including, without limitation, deficiency in base rent and additional rent, reasonable attorney’s fees, brokerage fees, and the expenses of placing the Premises in rentable condition.
(e) No expiration or termination of the Term of this Lease pursuant to Section 23(b) of this Part II, by operation of law or otherwise, and no re-entry, repossession or removal pursuant to Section 23(c) of this Part II or otherwise, and no reletting of the Premises pursuant to Section 23(d) of this Part II or otherwise, shall relieve Tenant of its liabilities and obligations hereunder, all of which shall survive such expiration, termination, re-entry, repossession, removal or reletting.
(f) In the event of any expiration or termination of the Term of this Lease or re-entry or repossession of the Premises or removal of persons or property therefrom by reason of the occurrence of an Event of Default, Tenant shall pay to Landlord all Fixed Rent, Additional Rent and other sums required to be paid by Tenant, in each case together with interest thereon at the Lease Default Rate from the due date thereof to and including the date of such expiration, termination, re-entry, repossession or removal; and thereafter, Tenant shall, until the end of what would have been the Term of this Lease in the absence of such expiration, termination, re-entry, repossession or removal and whether or not the Premises shall have been relet, be liable to Landlord for, and shall pay to Landlord, as liquidated and agreed current damages: (i) all Fixed Rent, Additional Rent and other sums which would be payable under this Lease by Tenant in the absence of any such expiration, termination, re-entry, repossession or removal, less (ii) the net proceeds, if any, of any reletting effected for the account of Tenant pursuant to Section 23(d) of this Part II, after deducting from such proceeds all reasonable expenses of Landlord in connection with such reletting, including, without limitation, all repossession costs, brokerage commissions, reasonable attorneys’ fees and expenses (including, without limitation, fees and expenses of appellate proceedings), alteration costs and expenses of preparation for such reletting. Tenant shall pay such liquidated and agreed current damages on the dates on which Fixed Rent would be payable under this Lease in the absence of such expiration, termination, re-entry, repossession or removal, and Landlord shall be entitled to recover the same from Tenant on each such date. At any time after any such expiration or termination of the Term of this Lease or re-entry or repossession of the Premises or removal of persons or property thereon by reason of the occurrence of an Event of Default, whether or not Landlord shall have collected any liquidated and agreed current damages pursuant to Section 23(f) of this Part II, Landlord shall be entitled to recover from Tenant, and Tenant shall pay to Landlord on demand, as and for liquidated and agreed final damages for Tenant’s default and in lieu of all liquidated and agreed current damages beyond the date of such demand (it being agreed that it would be impracticable or extremely difficult to fix the actual damages), an amount equal to the sum of (i) the excess, if any of (A) the aggregate of all Fixed Rent and Additional Rent which would be payable under this Lease, in each case from the date of such demand (or, if it be earlier, the date to which Tenant shall have satisfied in full its obligations under Section 23(f) of this Part II to pay liquidated and agreed current damages) for what would be the then-unexpired Term of this Lease in the absence of such expiration, termination, re-entry, repossession or removal, discounted at the rate equal to the then rate on U.S. Treasury obligations of comparable maturity to such Term (the “Treasury Rate”), but in no event greater than the non-default rate of interest for the Loan (such lower rate being referred to as the “Discount Rate”) over (B) the amount of such rental loss that Tenant proves could be reasonably avoided by commercially reasonable mitigation efforts by Landlord, discounted at the Discount Rate for the same period, plus (ii) all reasonable legal fees and other costs and expenses incurred by Landlord as a result of Tenant’s default under this Lease. If any Law shall limit the amount of liquidated final damages to less than the amount above agreed upon, Landlord shall be entitled to the maximum amount allowable under such Law.
(g) Mention in this Lease of any particular remedy shall not preclude Landlord from any other remedy at law or in equity, including the right of injunction. Tenant waives any rights of redemption granted by any Laws if Tenant is evicted or dispossessed, for any cause, or if Landlord obtains possession of the Premises by reason of the violation by Tenant of any of the terms of this Lease. In addition, Tenant, on its own behalf and for its legal representatives, successors and assigns, and on behalf of all persons claiming through or under this Lease, together with creditors of all classes, and all other persons having an interest therein, does hereby waive, surrender and give up all right or privilege which it may or might have by reason of any present or future Law or decision, to redeem the Premises or have a continuance of this Lease for any part of the Term hereof after having been dispossessed or ejected therefrom by process of law or otherwise.
(h) In addition to the foregoing remedies set forth in this Section 23 and all other remedies available at law or in equity, and regardless of whether or not an Event of Default has occurred under this Lease, if Tenant has failed to perform any of its duties, obligations, covenants or agreements under this Lease, Landlord may give notice to Tenant that it has failed to perform any such duty, obligation, covenant or agreement (herein called a “Notice of Breach”) and may thereafter pursue any rights or remedies available to it at law or in equity including, without limitation, filing a suit for damages as a result of such breach or a suit for specific performance of any such duties, obligations, covenants or agreements. Any Notice of Breach delivered under this Section 23(h) or any such rights or remedies pursued by Landlord shall not be deemed to be a notice of default under any provision of this Section 23 and shall not result, with or without the passage of time, in an Event of Default existing under this Lease; provided, that the delivery of any such Notice of Breach shall not limit Landlord’s right (which right will not be exercised without the consent of Lender so long as the Premises are subject to a Mortgage which requires Lender’s consent for the exercise thereof) to subsequently deliver notice (with respect to the same event or condition which is the subject of such Notice of Breach or any other event or condition) which will declare or, with the passage of time, result in an Event of Default hereunder.
Damage or Destruction Condemnation (a) In the event of partial damage or destruction of the Property of a type which can, under the circumstances, be expected in the reasonable judgment of Seller and Buyer to be restored or repaired at a cost of $500,000 or less, then, this Contract shall be consummated on the Closing Date at the Purchase Price, and unless such damage has been repaired by Seller prior to Closing, Seller shall assign to Buyer the casualty insurance proceeds payable to Seller and business interruption proceeds applicable to the period on and after the Closing Date payable to Seller (but only to the extent such business interruption proceeds are assignable to Buyer), less any amounts expended by Seller for partial restoration and with a credit to Buyer for the amount of any deductible and/or uninsured damage.
(b) In the event that the Property shall have been damaged by fire or casualty, the cost of repair or restoration of which would, in the reasonable judgment of Seller and Buyer, exceed the sum of $500,000, then unless Seller has previously repaired or restored the Property to its former condition, at Buyer’s election, Seller shall either (i) pay over or assign to Buyer, on delivery of the Deed all casualty insurance proceeds payable to Seller and business interruption proceeds applicable to the period on and after the Closing Date payable to Seller (but only to the extent such business interruption proceeds are assignable to Buyer), less any amounts reasonably expended by Seller for partial restoration, with a credit to Buyer for the amount of any deductible and/or uninsured damage, or (ii) direct Escrow Agent to return the Deposit to Buyer in which case, except for the Surviving Obligation, all other obligations of the parties hereto shall cease and this Contract shall terminate and be without further recourse or remedy to the parties hereto. Notwithstanding the foregoing, if Buyer elects to proceed with the transaction under clause (i) of this paragraph (b), in no event shall Seller be obligated to incur any out of pocket cost above $500,000 (whether attributable to a casualty being uninsured, underinsured or to any deductible).
(c) If all or part of the Property is taken by condemnation, eminent domain or by agreement in lieu thereof, or any proceeding to acquire, take or condemn all or part of the Property is threatened or commenced, Buyer may either terminate this Contract (in which event Buyer shall be entitled to a return of the Deposit and accrued interest thereon, if any, and, except for the Surviving Obligations, all other obligations of the parties hereto shall cease and this Contract shall terminate and be without further recourse or remedy to the parties hereto) or close title to the Property in accordance with the terms hereof, without reduction in the Purchase Price, together with an assignment of Seller's rights to any award paid or payable by or on behalf of the condemning authority. If Seller has received payments from the condemning authority and if Buyer elects to close title to the Property, Seller shall credit the amount of said payment against the Purchase Price at the Closing.
Adjustment Events In the event the General Partner (i) declares or pays a dividend on any Class of its outstanding REIT Shares in REIT Shares or makes a distribution to all holders of any Class of its outstanding REIT Shares in REIT Shares, (ii) subdivides any Class of its outstanding REIT Shares, or (iii) combines any Class of its outstanding REIT Shares into a smaller number of REIT Shares with respect to any Class of REIT Shares, then a corresponding adjustment to the number of outstanding Partnership Units of the applicable Class necessary to maintain the proportionate relationship between the number of outstanding Partnership Units of such Class to the number of outstanding REIT Shares of such Class shall automatically be made. Additionally, in the event that any other entity shall become General Partner pursuant to any merger, consolidation or combination of the General Partner with or into another entity (the “Successor Entity”), the number of outstanding Partnership Units of each Class shall be adjusted by multiplying such number by the number of shares of the Successor Entity into which one REIT Share of such Class is converted pursuant to such merger, consolidation or combination, determined as of the date of such merger, consolidation or combination. Any adjustment to the number of outstanding Partnership Units of any Class shall become effective immediately after the effective date of such event retroactive to the record date, if any, for such event; provided, however, that if the General Partner receives a Notice of Redemption after the record date, but prior to the effective date of such dividend, distribution, subdivision or combination, or such merger, consolidation or combination, the number of outstanding Partnership Units of any Class shall be determined as if the General Partner had received the Notice of Redemption immediately prior to the record date for such dividend, distribution, subdivision or combination or such merger, consolidation or combination. If the General Partner takes any other action affecting the REIT Shares other than actions specifically described above and, in the opinion of the General Partner such action would require an adjustment to the number of Partnership Units to maintain the proportionate relationship between the number of outstanding Partnership Units to the number of outstanding REIT Shares, the General Partner shall have the right to make such adjustment to the number of Partnership Units, to the extent permitted by law, in such manner and at such time as the General Partner, in its sole discretion, may determine to be appropriate under the circumstances.
