Procurement of the Site (i) The Authority Representative, the Contractor and Authority’s Engineer shall, within 10 (ten) days of the date of this Agreement, inspect the Site and prepare a detailed memorandum containing an inventory of the Site including the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site (hereinafter referred to as the “Handover Memorandum”). Subject to the provisions of Clause 8.2 (iii), the Handover Memorandum shall have appended thereto an appendix (the “Appendix”) specifying in reasonable detail those parts of the Site to which vacant access and Right of Way has not been given to the Contractor along with details of hindrances in the Construction Zone. For sake of clarity the Handover Memorandum shall clearly specify the parts of Site where work can be executed. Signing of the Handover Memorandum, in three counterparts (each of which shall constitute an original), by the authorized representatives of the Authority, Contractor and Authority’s Engineer shall be deemed to constitute a valid evidence of giving the Right of Way to the Contractor for discharging its obligations under and in accordance with the provisions of this Agreement and for no other purpose whatsoever. (ii) Whenever the Authority is ready to hand over any part or parts of the Site included in the Appendix, it shall inform the Contractor, by notice, of the proposed date and time such of hand over. The Authority Representative and the Contractor shall, on the date so notified, inspect the specified parts of the Site, and prepare a memorandum containing an inventory of the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site so handed over. The signing of the memorandum, in three (3) counterparts (each of which shall constitute an original), by the authorised representatives of the Parties shall be deemed to constitute a valid evidence of giving the relevant Right of Way to the Contractor. If the contractor fails to join for site inspection or disputes the parts of the site available for work, the Authority’s Engineer shall decide the parts of the site where work can be executed and notify to both the parties within 3 days of the proposed date of inspection. The parties agree that such notification of the Authority’s Engineer as mentioned hereinabove shall be final and binding on the parties. (iii) The Authority shall provide the Right of Way to the Contractor in respect of all land included in the Appendix by the date specified in Schedule-A for those parts of the Site referred to therein, and in the event of delay for any reason other than Force Majeure or breach of this Agreement by the Contractor, it shall pay to the Contractor, Damages in a sum calculated in accordance with Clause 8.3. The Contractor agrees that it shall not be entitled to claim any other damages on account of any such delay by the Authority. (iv) Notwithstanding anything to the contrary contained in this Clause 8.2, the Authority shall specify the parts of the Site, if any, for which Right of Way shall be provided to the Contractor on the dates specified in Schedule-A. Such parts shall also be included in the Appendix prepared in pursuance of Clause 8.2 (i). (v) The Authority further acknowledges and agrees that prior to the Appointed Date, it shall have procured issuance of the statutory notification under Applicable Laws for vesting of all the land comprising the Project in the Authority and has taken possession of area for Construction Zone for at least 90% (ninety per cent) of the total length of the Project Highway. The Parties also acknowledge and agree that the conditions specified in this Clause 8.2 (iii) shall not be modified or waived by either Party. (vi) For the avoidance of doubt, the Parties expressly agree that the Appendix shall in no event contain sections of the Project Highway the cumulative length of which exceeds 10% (ten percent) of the total length of the Project Highway. (vii) Pursuant to signing of Handover Memorandum under clause 8.2 (i), Contractor shall submit to the Authority’s Engineer, a monthly land possession report till expiry of 180 (one hundred and eighty) days from Appointed Date, in respect of those parts of the site to which vacant access and right of way was not given to the contractor and included in Appendix to the memorandum signed under clause 8.2 (i), duly specifying the part of the site, if any, for which the right of way is yet to be handed over.
MANAGEMENT OF THE BUSINESS Pursuant to Section 00-00-000 of the Act, and as stated in its Articles, the Company’s day to day affairs are managed by the Member. The Member is responsible for the daily operations of the business.
Management of the Company The Company's business and affairs shall be conducted and managed by the Member(s) in accordance with this Agreement and the laws of the State of the Formation. Single-Member (Applies ONLY if Single-Member): The Member(s) of the Company has sole authority and power to act for or on behalf of the Company, to do any act that would be binding on the Company or incur any expenditures on behalf of the Company. The Member(s) shall not be liable for the debts, obligations, or liabilities of the Company, including under a judgment, decree, or order of a court. The Company is organized as a “member-managed” limited liability company. The Member(s) is designated as the initial managing Member(s). Multi-Member (Applies ONLY if Multi-Member): Except as expressly provided elsewhere in this Agreement, all decisions respecting the management, operation, and control of the business and affairs of the Company and all determinations made in accordance with this Agreement shall be made by the affirmative vote or consent of Member(s) holding a majority of the Members’ Percentage Interests. Notwithstanding any other provision of this Agreement, the Member shall not, without the prior written consent of the unanimous vote or consent of the Member(s), sell, exchange, lease, assign or otherwise transfer all or substantially all of the assets of the Company; sell, exchange, lease (other than space leases in the ordinary course of business), assign or transfer the Company’s assets; mortgage, pledge or encumber the Company’s assets other than is expressly authorized by this Agreement; prepay, refinance, modify, extend or consolidate any existing mortgages or encumbrances; borrow money on behalf of the Company; lend any Company funds or other assets to any person or entity; establish any reserves for working capital repairs, replacements, improvements or any other purpose; confess a judgment against the Company; settle, compromise or release, discharge or pay any claim, demand or debt, including claims for insurance; approve a merger or consolidation of the Company with or into any other limited liability company, corporation, partnership or other entity; or change the nature or character of the business of the Company. The Member(s) shall receive such sums for compensation as Member(s) of the Company as may be determined from time to time by the affirmative vote or consent of Member(s) holding a majority of the Member(s)’ Percentage Interests.
Management of Business (a) No Limited Partner or Assignee (other than the General Partner, any of its Affiliates or any officer, director, employee, agent or trustee of the General Partner, the Partnership or any of their Affiliates, in their capacity as such) shall take part in the operation, management or control (within the meaning of the Act) of the Partnership’s business, transact any business in the Partnership’s name or have the power to sign documents for or otherwise bind the Partnership. (b) The transaction of any such business by the General Partner, any of its Affiliates or any officer, director, employee, partner, agent or trustee of the General Partner, the Partnership or any of their Affiliates, in their capacity as such, shall not affect, impair or eliminate the limitations on the liability of the Limited Partners or Assignees under this Agreement.
Management of Company 5.1.1 The Members, within the authority granted by the Act and the terms of this Agreement shall have the complete power and authority to manage and operate the Company and make all decisions affecting its business and affairs. 5.1.2 Except as otherwise provided in this Agreement, all decisions and documents relating to the management and operation of the Company shall be made and executed by a Majority in Interest of the Members. 5.1.3 Third parties dealing with the Company shall be entitled to rely conclusively upon the power and authority of a Majority in Interest of the Members to manage and operate the business and affairs of the Company.
Management of Property (a) Borrower shall manage the Property or cause the Property to be managed in a manner which is consistent with the Approved Manager Standard. All Space Leases shall provide for rental rates comparable to then existing local market rates and terms and conditions which constitute good and prudent business practice and are consistent with prevailing market terms and conditions, and shall be arms-length transactions. All Space Leases entered into after the date hereof shall provide that they are subordinate to this Security Instrument and that the lessees thereunder attorn to Lender. Borrower shall deliver copies of all Leases, amendments, modifications and renewals thereof to Lender. All proposed Leases for the Property shall be subject to the prior written approval of Lender, not to be unreasonably withheld, conditioned or delayed, provided, however that Borrower may enter into new leases with unrelated third parties without obtaining the prior consent of Lender provided that: (i) the proposed leases conform with the requirements of this Section 7.02; (ii) the proposed Space Lease is not a Major Space Lease and the space to be leased pursuant to such proposed lease together with any space leased or to be leased to an Affiliate of the tenant thereunder does not exceed 10,000 square feet; and (iii) the term of the proposed lease inclusive of all extensions and renewals, does not exceed ten (10) years. (b) Borrower (i) shall or shall cause Operating Tenant to observe and perform all of its material obligations under the Leases pursuant to applicable Legal Requirements and shall not do or permit to be done anything to impair the value of the Major Space Leases as security for the Debt; (ii) shall promptly send copies to Lender of all notices of default which Borrower shall receive under the Major Space Leases; (iii) shall, consistent with the Approved Manager Standard, enforce all of the terms, covenants and conditions contained in the Leases to be observed or performed; (iv) shall not collect any of the Rents under the Major Space Leases more than one (1) month in advance (except that Borrower may collect in advance such security deposits as are permitted pursuant to applicable Legal Requirements and are commercially reasonable in the prevailing market); (v) shall not execute any other assignment of lessor’s interest in the Leases or the Rents except as otherwise expressly permitted pursuant to this Security Instrument; (vi) shall not cancel or terminate any of the Leases or accept a surrender thereof in any manner inconsistent with the Approved Manager Standard; (vii) shall not convey, transfer or suffer or permit a conveyance or transfer of all or any part of the Premises or the Improvements or of any interest therein so as to effect a merger of the estates and rights of, or a termination or diminution of the obligations of, lessees thereunder; (viii) shall not alter, modify or change the terms of any guaranty of any Major Space Lease or cancel or terminate any such guaranty in a manner inconsistent with the Approved Manager Standard; (ix) shall, in accordance with the Approved Manager Standard, make all reasonable efforts to seek lessees for space as it becomes vacant and enter into Leases in accordance with the terms hereof; (x) shall not cancel or terminate or materially modify, alter or amend any Major Space Lease or Property Agreement without Lender’s consent, which consent will not be unreasonably withheld or delayed; and (xi) shall, without limitation to any other provision hereof, execute and deliver at the request of Lender all such further assurances, confirmations and assignments in connection with the Property as are required herein and as Lender shall from time to time reasonably require. (c) All security deposits shall be held in accordance with all Legal Requirements. Following the occurrence and during the continuance of any Event of Default, Borrower shall, upon Lender’s request, if permitted by applicable Legal Requirements, turn over the security deposits (and any interest thereon) to Lender to be held by Lender in accordance with the terms of the Leases and all Legal Requirements. (d) If requested by Lender, Borrower shall furnish, or shall cause the applicable lessee to furnish, to Lender financial data and/or financial statements in accordance with Regulation AB for any lessee of the Property if, in connection with a Securitization, Lender expects there to be, with respect to such lessee or any group of affiliated lessees, a concentration within all of the mortgage loans included or expected to be included, as applicable, in such Securitization such that such lessee or group of affiliated lessees would constitute a Significant Obligor; provided, however, that in the event the related Space Lease does not require the related lessee to provide the foregoing information, Borrower shall use commercially reasonable efforts to cause the applicable lessee to furnish such information. (e) Borrower covenants and agrees with Lender that (i) the Property will be managed at all times by an Approved Manager pursuant to the management agreement approved by Lender (the “Management Agreement”), such approval not to be unreasonably withheld or delayed, (ii) after Borrower has knowledge of a fifty percent (50%) or more change in control of the ownership of Manager, Borrower will promptly give Lender notice thereof (a “Manager Control Notice”) and (iii) the Management Agreement may be terminated by Lender at any time (A) for cause to the extent provided in the Management Agreement (including, but not limited to, Manager’s gross negligence, misappropriation of funds, willful misconduct or fraud) following the occurrence of an Event of Default of the type set forth in Section 13.01(a) through (c), or (B) to the extent provided in the Management Agreement, following the receipt of a Manager Control Notice and a substitute Approved Manager shall be appointed by Borrower. Notwithstanding the foregoing, transfers of publicly traded stock of Manager on a national stock exchange or on the NASDAQ Stock Market in the normal course of business and not in connection with a tender offer or sale of Manager or substantially all of the assets of Manager shall not require the giving of a Manager Control Notice. Borrower may from time to time appoint a successor manager to manage the Property, provided that any such successor manager shall be an Approved Manager. Borrower further covenants and agrees that Borrower shall require Manager (or any successor managers) to maintain at all times during the term of the Loan worker’s compensation insurance as required by Governmental Authorities. (f) Borrower shall not enter into any new or replacement Franchise Agreement without obtaining the prior written consent of Lender, such consent not to be unreasonably withheld, conditioned or delayed (provided that any Franchise Agreement which is on a form in all material respects (including, without limitation, all fees due thereunder) the same as the form of any Franchise Agreement which is contained in the uniform franchise offering circular for any Approved Franchisor shall be deemed an acceptable form), and shall (i) pay or shall cause to be paid all sums required to be paid by Borrower under any Franchise Agreement and Operating Lease, (ii) diligently perform and observe all of the material terms, covenants and conditions of any Franchise Agreement on the part of Borrower to be performed and observed to the end that all things shall be done which are necessary to keep unimpaired the rights of Borrower under any Franchise Agreement and Operating Lease, (iii) promptly notify Lender of the giving of any notice to Borrower of any material default by Borrower in the performance or observance of any of the terms, covenants or conditions of and Franchise Agreement or Operating Lease on the part of Borrower to be performed and observed and deliver to Lender a true copy of each such notice, and (iv) promptly deliver to Lender a copy of each financial statement, business plan, capital expenditures plan, report and estimate received by it under the Franchise Agreement or the Management Agreement or the Operating Lease. Borrower shall not, without the prior consent of the Lender, such consent not to be unreasonably withheld, conditioned or delayed, surrender any Franchise Agreement or Operating Lease or terminate or cancel any Franchise Agreement or modify, change, supplement, alter or amend any Franchise Agreement or Operating Lease, in any material respect, either orally or in writing, and Borrower hereby assigns to Lender as further security for the payment of the Debt and for the performance and observance of the terms, covenants and conditions of this Security Instrument, all the rights, privileges and prerogatives of Borrower to surrender any Franchise Agreement or Operating Lease or to terminate, cancel, modify, change, supplement, alter or amend any Franchise Agreement or Operating Lease in any respect, and any such surrender of any Franchise Agreement or termination, cancellation, modification, change, supplement, alteration or amendment of any Franchise Agreement or Operating Lease without the prior consent of Lender shall be void and of no force and effect, provided, however, Borrower may terminate any Franchise Agreement if Borrower enters into a new Franchise Agreement with an Approved Franchisor pursuant to a Franchise Agreement which is reasonably acceptable to Lender. Notwithstanding the foregoing, Borrower may renew or replace any Operating Lease, provided such renewal or replacement shall be upon the same terms and conditions as the Operating Lease being renewed or replaced, except rent payable thereunder may be adjusted to the extent necessary to comply with the then-current requirements of the Code for real estate investment trusts. If Borrower shall default in the performance or observance of any material term, covenant or condition of any Franchise Agreement or Operating Lease on the part of Borrower to be performed or observed, then, without limiting the generality of the other provisions of this Security Instrument, and without waiving or releasing Borrower from any of its obligations hereunder, Lender shall have the right, but shall be under no obligation, to pay any sums and to perform any act or take any action as may be appropriate to cause all the terms, covenants and conditions of any Franchise Agreement or Operating Lease on the part of Borrower to be performed or observed to be promptly performed or observed on behalf of Borrower, to the end that the rights of Borrower in, to and under any Franchise Agreement and Operating Lease shall be kept unimpaired and free from default. Lender and any Person designated by Lender shall have, and are hereby granted, the right to enter upon the Property at any time and from time to time for the purpose of taking any such action. If the franchisor under any Franchise Agreement or lessee under an Operating Lease shall deliver to Lender a copy of any notice sent to Borrower of default under any Franchise Agreement or Operating Lease, as applicable, such notice shall constitute full protection to Lender for any action to be taken by Lender in good faith, in reliance thereon. Borrower shall, from time to time, use its best efforts to obtain from the franchisor or lessee under any Franchise Agreement such certificates of estoppel with respect to compliance by Borrower with the terms of any Franchise Agreement as may be requested by Lender. Borrower shall exercise each individual option, if any, to extend or renew the term of any Franchise Agreement within four (4) months of the last day upon which any such option may be exercised, unless Lender consents to the non-renewal of such Franchise Agreement in writing, and Borrower hereby expressly authorizes and appoints Lender its attorney-in-fact to exercise any such option in the name of and upon behalf of Borrower, which power of attorney shall be irrevocable and shall be deemed to be coupled with an interest, provided, however, that Lender shall not exercise such power of attorney unless and until Borrower fails to take the actions required herein.
Security Management The Contractor shall comply with the requirements of the DOD 5200.1-M and the DD Form 254. Security of the Contractor’s electronic media shall be in accordance with the above documents. Effective Program Security shall require the Contractor to address Information Security and Operations Security enabled by the Security Classification Guides. The Contractor’s facility must be able to handle and store material up to the Classification Level as referenced in Attachment J-01, DD Form 254.
Management of Change a. The parties to this Collective Agreement accept that change in the health service is necessary in order to ensure the efficient and effective delivery of health services. They recognise a mutual interest in ensuring that health services are provided efficiently and effectively, and that each has a contribution to make in this regard. b. Regular consultation between the employer, its midwives and the union is essential on matters of mutual concern and interest. Effective communication between the parties will allow for: • improved decision making; • greater co-operation between employer and midwives; and • a more harmonious, effective, efficient, safe and productive workplace.
Patch Management All workstations, laptops and other systems that process and/or 20 store PHI COUNTY discloses to CONTRACTOR or CONTRACTOR creates, receives, maintains, or 21 transmits on behalf of COUNTY must have critical security patches applied, with system reboot if 22 necessary. There must be a documented patch management process which determines installation 23 timeframe based on risk assessment and vendor recommendations. At a maximum, all applicable 24 patches must be installed within thirty (30) calendar or business days of vendor release. Applications 25 and systems that cannot be patched due to operational reasons must have compensatory controls 26 implemented to minimize risk, where possible.
Management and Operation of Business Section 7.1 Management 47 Section 7.2 Certificate of Limited Partnership 48 Section 7.3 Restrictions on Managing General Partner’s Authority 49 Section 7.4 Reimbursement of the Managing General Partner 49 Section 7.5 Outside Activities 50 Section 7.6 Loans from the Managing General Partner; Loans or Contributions from the Partnership; Contracts with Affiliates; Certain Restrictions on the Managing General Partner 51 Section 7.7 Indemnification 53 Section 7.8 Liability of Indemnitees 54 Section 7.9 Resolution of Conflicts of Interest 55 Section 7.10 Other Matters Concerning the Managing General Partner 57 Section 7.11 Purchase or Sale of Partnership Securities 57 Section 7.12 Registration Rights of the Managing General Partner and its Affiliates 57 Section 7.13 Reliance by Third Parties 59