Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.
Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.
Maximum Liability The provisions of this Loan Guaranty are severable, and in any action or proceeding involving any state corporate law, or any state, federal or foreign bankruptcy, insolvency, reorganization or other law affecting the rights of creditors generally, if the obligations of any Loan Guarantor under this Loan Guaranty would otherwise be held or determined to be avoidable, invalid or unenforceable on account of the amount of such Loan Guarantor’s liability under this Loan Guaranty, then, notwithstanding any other provision of this Loan Guaranty to the contrary, the amount of such liability shall, without any further action by the Loan Guarantors or the Lenders, be automatically limited and reduced to the highest amount that is valid and enforceable as determined in such action or proceeding (such highest amount determined hereunder being the relevant Loan Guarantor’s “Maximum Liability”. This Section with respect to the Maximum Liability of each Loan Guarantor is intended solely to preserve the rights of the Lenders to the maximum extent not subject to avoidance under applicable law, and no Loan Guarantor nor any other person or entity shall have any right or claim under this Section with respect to such Maximum Liability, except to the extent necessary so that the obligations of any Loan Guarantor hereunder shall not be rendered voidable under applicable law. Each Loan Guarantor agrees that the Guaranteed Obligations may at any time and from time to time exceed the Maximum Liability of each Loan Guarantor without impairing this Loan Guaranty or affecting the rights and remedies of the Lenders hereunder, provided that, nothing in this sentence shall be construed to increase any Loan Guarantor’s obligations hereunder beyond its Maximum Liability.
Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.
Liability for Damages Nothing in this Section shall preclude the Borrower or any Lender from asserting against any LC Issuing Bank any claim for direct (but not consequential) damages suffered by the Borrower or such Lender to the extent, but only to the extent, caused by (A) the willful misconduct or gross negligence of such LC Issuing Bank in determining whether a request presented under any Letter of Credit issued by it complied with the terms thereof or (B) such LC Issuing Bank's failure to pay under any such Letter of Credit after the presentation to it of a request strictly complying with the terms and conditions thereof.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
Delivery Delay The delivery of any certificate representing the Restricted Stock or other RS Property may be postponed by the Company for such period as may be required for it to comply with any applicable federal or state securities law, or any national securities exchange listing requirements and the Company is not obligated to issue or deliver any securities if, in the opinion of counsel for the Company, the issuance of such Shares shall constitute a violation by the Participant or the Company of any provisions of any law or of any regulations of any governmental authority or any national securities exchange.
Compensation for Buy-In on Failure to Timely Deliver Warrant ADSs Upon Exercise In addition to any other rights available to the Holder, if the Company fails to cause the Depositary to deliver to the Holder the Warrant ADSs in accordance with the provisions of Section 2(d)(i) above pursuant to an exercise on or before the Warrant ADS Delivery Date, and if after such date the Holder is required by its broker to purchase (in an open market transaction or otherwise) or the Holder’s brokerage firm otherwise purchases, ADSs to deliver in satisfaction of a sale by the Holder of the Warrant ADSs which the Holder anticipated receiving upon such exercise (a “Buy-In”), then the Company shall (A) pay in cash to the Holder the amount, if any, by which (x) the Holder’s total purchase price (including brokerage commissions, if any) for the ADSs so purchased exceeds (y) the amount obtained by multiplying (1) the number of Warrant ADSs that the Company was required to deliver to the Holder in connection with the exercise at issue times (2) the price at which the sell order giving rise to such purchase obligation was executed, and (B) at the option of the Holder, either reinstate the portion of the Warrant and equivalent number of Warrant ADSs for which such exercise was not honored (in which case such exercise shall be deemed rescinded) or deliver to the Holder the number of ADSs that would have been issued had the Company timely complied with its exercise and delivery obligations hereunder. For example, if the Holder purchases ADSs having a total purchase price of $11,000 to cover a Buy-In with respect to an attempted exercise of ADSs with an aggregate sale price giving rise to such purchase obligation of $10,000, under clause (A) of the immediately preceding sentence the Company shall be required to pay the Holder $1,000. The Holder shall provide the Company written notice indicating the amounts payable to the Holder in respect of the Buy-In and, upon request of the Company, evidence of the amount of such loss. Nothing herein shall limit a Xxxxxx’s right to pursue any other remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief with respect to the Company’s failure to timely deliver ADSs upon exercise of the Warrant as required pursuant to the terms hereof.
Effect of Failure or Delay in Requesting Compensation Failure or delay on the part of any Lender or the Issuing Bank to demand compensation pursuant to this Section 5.01 shall not constitute a waiver of such Lender’s or the Issuing Bank’s right to demand such compensation; provided that the Borrower shall not be required to compensate a Lender or the Issuing Bank pursuant to this Section 5.01 for any increased costs or reductions incurred more than 180 days prior to the date that such Lender or the Issuing Bank, as the case may be, notifies the Borrower of the Change in Law giving rise to such increased costs or reductions and of such Lender’s or the Issuing Bank’s intention to claim compensation therefor; provided further that, if the Change in Law giving rise to such increased costs or reductions is retroactive, then the 180-day period referred to above shall be extended to include the period of retroactive effect thereof.
Liability for Deficiency If any sale or other disposition of Collateral by Secured Party or any other action of Secured Party hereunder results in reduction of the Obligations, such action will not release Debtor from its liability to Secured Party for any unpaid Obligations, including costs, charges and expenses incurred in the liquidation of Collateral, together with interest thereon, and the same shall be immediately due and payable to Secured Party at Secured Party's address set forth in the opening paragraph hereof.
