Placement of EPP probes Probes for measuring EPP parameters shall be placed inside or close to Registrars points of access to the Internet across the different geographic regions; care shall be taken not to deploy probes behind high propagation-‐delay links, such as satellite links.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Meteorological Data Reporting Requirement (Applicable to wind generation facilities only)
Contractor Sales Reporting Vendor Management Fee Contractor Reports Cooperative Master Contract Sales Reporting. Contractor shall report total Cooperative Master Contract sales quarterly to Enterprise Services, as set forth below. Cooperative Master Contract Sales Reporting System. Contractor shall report quarterly Cooperative Master Contract sales in Enterprise Services’ Cooperative Master Contract Sales Reporting System. Enterprise Services will provide Contractor with a login password and a vendor number. The password and vendor number will be provided to the Sales Reporting Representative(s) listed on Contractor’s Bidder Profile. Data. Each sales report must identify every authorized Purchaser by name as it is known to Enterprise Services and its total combined sales amount invoiced during the reporting period (i.e., sales of an entire agency or political subdivision, not its individual subsections). The “Miscellaneous” option may be used only with prior approval by Enterprise Services. Upon request, Contractor shall provide contact information for all authorized Purchasers specified herein during the term of the Cooperative Master Contract. If there are no Cooperative Master Contract sales during the reporting period, Contractor must report zero sales. Due dates for Cooperative Master Contract Sales Reporting. Quarterly Cooperative Master Contract Sales Reports must be submitted electronically by the following deadlines for all Cooperative Master Contract sales invoiced during the applicable calendar quarter: Vendor Management Fee. Contractor shall pay to Enterprise Services a vendor management fee (“VMF”) of 1.5 percent on the purchase price for all Cooperative Master Contract sales (the purchase price is the total invoice price less applicable sales tax). The sum owed by Contractor to Enterprise Services as a result of the VMF is calculated as follows: Amount owed to Enterprise Services = Total Cooperative Master Contract sales invoiced (not including sales tax) x .015. The VMF must be rolled into Contractor’s current pricing. The VMF must not be shown as a separate line item on any invoice unless specifically requested and approved by Enterprise Services. Enterprise Services will invoice Contractor quarterly based on Cooperative Master Contract sales reported by Contractor. Contractor is not to remit payment until Contractor receives an invoice from Enterprise Services. Contractor’s VMF payment to Enterprise Services must reference this Cooperative Master Contract number, the year and quarter for which the VMF is being remitted, and Contractor’s name as set forth in this Cooperative Master Contract, if not already included on the face of the check. Contractor’s failure to report accurate total net Cooperative Master Contract sales, to submit a timely Cooperative Master Contract sales report, or to remit timely payment of the VMF to Enterprise Services, may be cause for Enterprise Services to suspend Contractor or terminate this Cooperative Master Contract or exercise remedies provided by law. Without limiting any other available remedies, the parties agree that Contractor’s failure to remit to Enterprise Services timely payment of the VMF shall obligate Contractor to pay to Enterprise Services, to offset the administrative and transaction costs incurred by the State to identify, process, and collect such sums, the sum of $200.00 or twenty-five percent (25%) of the outstanding amount, whichever is greater, or the maximum allowed by law, if less. Enterprise Services reserves the right, upon thirty (30) calendar days advance written notice, to increase, reduce, or eliminate the VMF for subsequent purchases, and reserves the right to renegotiate Cooperative Master Contract pricing with Contractor when any subsequent adjustment of the VMF might justify a change in pricing. Annual Cooperative Master Contract Sales Report. Contractor shall provide to Enterprise Services a detailed annual Cooperative Master Contract sales report. Such report shall include, at a minimum: the Goods/Services sold (including, as applicable, item number or other identifier), per unit quantities sold, items and volumes purchased by Purchaser, shipment/delivery locations by Purchaser, and Cooperative Master Contract price. This report must be provided in an electronic format that can be read by Microsoft (MS) Excel. Such report is due within thirty (30) calendar days of the annual anniversary of the effective date of this Cooperative Master Contract.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Your Billing Rights: Keep this Document for Future Use This notice tells you about your rights and our responsibilities under the Fair Credit Billing Act.
Infrastructure Vulnerability Scanning Supplier will scan its internal environments (e.g., servers, network devices, etc.) related to Deliverables monthly and external environments related to Deliverables weekly. Supplier will have a defined process to address any findings but will ensure that any high-risk vulnerabilities are addressed within 30 days.
Mail Order Catalog Warnings In the event that, the Settling Entity prints new catalogs and sells units of the Products via mail order through such catalogs to California consumers or through its customers, the Settling Entity shall provide a warning for each unit of such Product both on the label in accordance with subsection 2.4 above, and in the catalog in a manner that clearly associates the warning with the specific Product being purchased. Any warning provided in a mail order catalog shall be in the same type size or larger than other consumer information conveyed for such Product within the catalog and shall be located on the same display page of the item. The catalog warning may use the Short-Form Warning content described in subsection 2.3(b) if the language provided on the Product label also uses the Short-Form Warning.
Quality- and Cost-Based Selection Except as ADB may otherwise agree, the Borrower shall apply quality- and cost-based selection for selecting and engaging consulting services.
Adverse Weather Shall be only weather that satisfies all of the following conditions: (1) unusually severe precipitation, sleet, snow, hail, or extreme temperature or air conditions in excess of the norm for the location and time of year it occurred based on the closest weather station data averaged over the past five years, (2) that is unanticipated and would cause unsafe work conditions and/or is unsuitable for scheduled work that should not be performed during inclement weather (i.e., exterior finishes), and (3) at the Project.