Limitation on Claims No claim seeking an adjustment in the billing for any service, transaction, or charge under this Agreement, including any of the appendices, schedules or attachments to this Agreement, may be asserted with respect to a week or month, if more than one year has elapsed
(a) since the first date upon which an invoice was rendered for that week or month, or (b) since the date upon which a changed or modified invoice was rendered for that week or month. The Party responsible for issuing an invoice may not, of its own initiative, issue a changed or modified invoice if more than one year has elapsed since the first date upon which an invoice was rendered for a week or month. A changed or modified invoice may be issued more than one year after the first date upon which an invoice was rendered for a week or month in order to correct for or address a timely-raised claim seeking an adjustment in the billing for any service, transaction, or charge under this Agreement.
Indemnification and Limitation on Liability 1. Seller agrees to indemnify and hold harmless JPMS and its directors, officers, employees and affiliates from and against all claims, losses, damages and liabilities (including without limitation, any legal or other expenses reasonably incurred in connection with defending or investigating any such action or claim) arising out of or attributable to JPMS’s actions taken or not taken in compliance with this Sales Plan or arising out of or attributable to any breach by Seller of this Sales Plan (including Seller’s representations and warranties hereunder) or any violation by Seller of applicable laws or regulations. This indemnification shall survive termination of this Sales Plan. Notwithstanding the foregoing, Seller shall have no indemnification obligation to the extent any claims, losses, damages or liabilities are due to the gross negligence, recklessness or willful misconduct of JPMS or any other indemnified person.
2. Notwithstanding any other provision hereof, JPMS shall not be liable to Seller for: (a) special, indirect, punitive, exemplary or consequential damages, or incidental losses or damages of any kind, even if advised of the possibility of such losses or damages or if such losses or damages could have been reasonably foreseen; or (b) any failure to perform or to cease performance or any delay in performance that results from a cause or circumstance that is beyond its reasonable control, including but not limited to failure of electronic or mechanical equipment, strikes, failure of common carrier or utility systems, severe weather, market disruptions or other causes commonly known as “acts of God”.
Compensation and Limitation of Liability 14 Section 1.
Exclusion and Limitation of Liability 10.1 SUPPLIER DOES NOT EXCLUDE OR LIMIT ITS LIABILITY (IF ANY) TO BUYER FOR ANY MATTER FOR WHICH IT WOULD BE ILLEGAL FOR SUPPLIER TO EXCLUDE OR LIMIT OR TO ATTEMPT TO EXCLUDE OR LIMIT ITS LIABILITY.
10.2 OTHER THAN ANY LIABILITY OF SUPPLIER ARISING UNDER CLAUSE 10.1, WHICH SHALL NOT BE LIMITED, AND WITHOUT PREJUDICE TO THE OTHER PROVISIONS OF THIS CLAUSE 10 (EXCLUSION AND LIMITATION OF LIABILITY), SUPPLIER'S AGGREGATE LIABILITY AS DEFINED IN PART D (DEFINITIONS AND INTERPRETATION) UNDER EACH CONTRACT WILL BE LIMITED TO AN AMOUNT EQUAL TO THE GREATER OF 115% OF THE AMOUNT PAID BY BUYER TO SUPPLIER UNDER THAT CONTRACT OR $10,000.00.
10.3 EXCEPT AS PROVIDED IN CLAUSE 10.1, SUPPLIER WILL BE UNDER NO LIABILITY AS DEFINED IN PART D (DEFINITIONS AND INTERPRETATION) TO BUYER WHATSOEVER IN RESPECT OF
10.3.1 ANY CLAIM ARISING OUT OF AN EVENTWHICH IS CAUSED, OR CONTRIBUTED TO, BY THE GOODS AND SUCH EVENT OCCURS AFTER THE COMMENCEMENT OF THE LAUNCH PROCEDURE OF THE VEHICLE CARRYING SUCH GOODS INTO SPACE;
10.3.2 PURE ECONOMIC LOSS, LOSS OF PROFITS, LOSS OF BUSINESS, LOSS OF REVENUE, LOSS OF CONTRACTS, LOSS OF GOODWILL, LOSS OF ANTICIPATED EARNINGS OR SAVINGS (WHETHER DIRECT, INDIRECT, INCIDENTAL OR CONSEQUENTIAL) OR
10.3.3 LOSS OF USE OR VALUE OR DAMAGE OF ANY DATA OR EQUIPMENT (INCLUDING SOFTWARE), WASTED MANAGEMENT, OPERATION OR OTHER TIME (WHETHER DIRECT, INDIRECT, INCIDENTAL OR CONSEQUENTIAL) OR
10.3.4 ANY SPECIAL, INDIRECT, PUNITIVE, INCIDENTAL OR CONSEQUENTIAL LOSS, IN EACH CASE HOWSOEVER CAUSED ARISING OUT OF OR IN CONNECTION WITH:
10.3.5 ANY OF THE WORKS, OR THE MANUFACTURE OR SALE OR SUPPLY, OR FAILURE OR DELAY IN SUPPLY, OF THE WORKS BY SUPPLIER OR ON THE PART OF SUPPLIER’S EMPLOYEES, AGENTS OR SUBCONTRACTORS;
10.3.6 ANY BREACH BY SUPPLIER OF ANY OF THE EXPRESS OR IMPLIED TERMS OF THE CONTRACT;
10.3.7 ANY USE MADE OR RESALE BY BUYER OF ANY OF THE WORKS, OR OF ANY PRODUCT INCORPORATING ANY OF THE WORKS; OR
10.3.8 ANY STATEMENT MADE OR NOT MADE, OR ADVICE GIVEN OR NOT GIVEN, BY OR ON BEHALF OF SUPPLIER.
10.4 EXCEPT AS EXPRESSLY SET OUT IN THE CONTRACT, SUPPLIER HEREBY EXCLUDES TO THE FULLEST EXTENT PERMISSIBLE IN LAW, ALL CONDITIONS, WARRANTIES AND STIPULATIONS, EXPRESS (OTHER THAN THOSE SET OUT IN THE CONTRACT) OR IMPLIED, STATUTORY, CUSTOMARY OR OTHERWISE WHICH, BUT FOR SUCH EXCLUSION, WOULD OR MIGHT SUBSIST IN FAVOR OF BUYER, INCLUDING, WITHOUT LIMITATION, ANY WARRANTY OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE.
10.5 EACH OF SUPPLIER’S EMPLOYEES, AGENTS AND SUBCONTRACTORS MAY RELY UPON AND ENFORCE THE EXCLUSIONS AND RESTRICTIONS OF LIABILITY IN THE CONTRACT IN THAT PERSON’S OWN NAME AND FOR THAT PERSON’S OWN BENEFIT, AS IF THE WORDS “ITS EMPLOYEES, AGENTS AND SUBCONTRACTORS” FOLLOWED THE WORD SUPPLIER WHEREVER IT APPEARS IN THOSE CLAUSES SAVE FOR EACH REFERENCE IN CLAUSE10.3.5.
10.6 BUYER ACKNOWLEDGES THAT THE ABOVE PROVISIONS OF THIS CLAUSE 10 (EXCLUSION AND LIMITATION OF LIABILITY) ARE REASONABLE AND REFLECTED IN THE PRICE WHICH WOULD BE HIGHER WITHOUT THOSE PROVISIONS, AND BUYER WILL ACCEPT SUCH RISK AND/OR INSURE ACCORDINGLY.
10.7 BUYER IS SOLELY RESPONSIBLE AND LIABLE FOR THE PROPER LEGAL DISPOSAL OF ALL MATERIALS PURCHASED FROM SUPPLIER AT THE END-OF- LIFE CYCLE OF SUCH MATERIALS.
Exclusions and Limitations of Liability TO THE MAXIMUM EXTENT PERMITTED UNDER APPLICABLE LAW, (a) NONE OF THE 8x8 PARTIES SHALL BE LIABLE UNDER THE AGREEMENT FOR ANY INCIDENTAL, CONSEQUENTIAL, SPECIAL, PUNITIVE, EXEMPLARY, OR COVER DAMAGES; LOSS OF PROFITS, REVENUES, OR GOODWILL; OR LOSS OR INTERRUPTION OF BUSINESS, WHETHER FROM BREACH OR REPUDIATION OF CONTRACT, BREACH OF WARRANTY, NEGLIGENCE, TORT, STRICT LIABILITY, OR OTHERWISE AND (b) THE MAXIMUM LIABILITY OF THE 8x8 PARTIES UNDER THE AGREEMENT, WHETHER ARISING FROM A THEORY OR CLAIM OF BREACH OR REPUDIATION OF CONTRACT, BREACH OF WARRANTY, NEGLIGENCE, TORT, STATUTORY DUTY, OR OTHERWISE, SHALL IN NO CASE EXCEED THE TOTAL AMOUNT OF SERVICE FEES PAYABLE UNDER THE AGREEMENT FOR THE TWELVE- (12-) MONTH PERIOD PRECEDING THE FIRST INCIDENT OUT OF WHICH THE LIABILITY AROSE. THE FOREGOING EXCLUSION AND LIMITATION SHALL APPLY REGARDLESS OF WHETHER EITHER PARTY WAS ADVISED OF THE POSSIBILITY OF SUCH DAMAGES OR THE FAILURE OF THE ESSENTIAL PURPOSE OF ANY LIMITED REMEDY, AND ON A CUMULATIVE (RATHER THAN PER-INCIDENT) BASIS. CUSTOMER ACKNOWLEDGES AND AGREES THAT THE PRICING AND OTHER TERMS UNDER THE AGREEMENT ARE BASED ON THE FOREGOING EXCLUSION AND LIMITATION.
Indemnification and Limitation of Liability (a) In the absence of willful misfeasance, bad faith, gross negligence or reckless disregard of obligations or duties hereunder on the part of FSSC and its trustees, officers, employees, agents and representatives, the Funds agree to indemnify FSSC and its trustees, officers, employees, agents and representatives against any and all claims, demands, liabilities and reasonable expenses (including attorneys’ fees), related to or otherwise connected with (i) any breach by the Funds of any provision of this Agreement; or (ii) any action by a Fund’s Shareholder against FSSC.
(b) FSSC shall not be liable for any error of judgment or mistake of law or for any loss suffered by any Fund in connection with the matters to which this Agreement relates, except a loss resulting from willful misfeasance, bad faith or gross negligence on its part in the performance of its duties or from reckless disregard by it of its obligations and duties under this Agreement. In no event shall FSSC be liable for indirect or consequential damages.
(c) Any person, even though also an officer, trustee, partner, employee or agent of FSSC, who may be or become an officer, employee or agent of any Fund or a member of a Fund's Board, shall be deemed, when rendering services to such Fund or acting on any business of such Fund (other than services or business in connection with the duties of FSSC hereunder) to be rendering such services to or acting solely for such Fund and not as an officer, trustee, partner, employee or agent or one under the control or direction of FSSC even though paid by FSSC.
(d) FSSC is expressly put on notice of the limitation of liability as set forth in the Declaration of Trust of each Fund that is a Massachusetts business trust and agrees that the obligations assumed by each such Fund pursuant to this Agreement shall be limited in any case to such Fund and its assets and that FSSC shall not seek satisfaction of any such obligations from the Shareholders of such Fund, the Trustees, Officers, Employees or Agents of such Fund, or any of them.
(e) The provisions of this Section shall survive the termination of this Agreement.
RETENTION AND LIMIT The Reinsurer will accept a fixed proportion of [up to 30%] of the Company's loss on the first $1,000,000 on behalf of the Company under each and every Policy subject to this Agreement, as follows: [4/1/02 to 3/31/03 10%, 4/1/03 to 12/31/06 15%].
Compensation and Limitation of Liability of Trustees Compensation ------------
Section 1. The Trustees as such shall be entitled to reasonable ---------- compensation from the Trust; they may fix the amount of their compensation. Nothing herein shall in any way prevent the employment of any Trustee for advisory, management, legal, accounting, investment banking, underwriting, brokerage or other services and payment for the same by the Trust. Limitation of Liability -----------------------
Section 2. The Trustees shall not be responsible or liable in any event ---------- for any neglect or wrongdoing of any officer, agent, employee, adviser, sub- adviser, manager or principal underwriter of the Trust, nor shall any Trustee be responsible for the act or omission of any other Trustee, but nothing herein contained shall protect any Trustee against any liability to which he or she would otherwise be subject by reason of willful misfeasance, bad faith, gross negligence or reckless disregard of the duties involved in the conduct of his or her office. Every note, bond, contract, instrument, certificate, Share or undertaking and every other act or thing whatsoever executed or done by or on behalf of the Trust or the Trustees or any of them in connection with the Trust shall be conclusively deemed to have been executed or done only in or with respect to their or his or her capacity as Trustees or Trustee, and such Trustees or Trustee shall not be personally liable thereon.
Exclusions and Limitations The aforementioned “Limited Warranty” does not apply to any Products which have been subjected to
a) Failure to pay the purchase price towards Peimar or its subsidiaries which have put the modules on the market provided that (i), the payment was due and (ii) the Buyer who has obtained the modules from Peimar or one of its distributors (Direct Customer) is not entitled to withhold the purchase price or parts of the purchase price. Xxxxxx must inform the Buyer about the non- payment and provide the name and the full address of the Direct Customer which has failed to pay the modules. In case that Xxxxxx can reject the claim under this warranty based on this provision, the Buyer can deposit the amount not paid in order to trigger the warranty claims;
b) Failure to comply with Xxxxxx’s installation manual applicable during the Validity of this Limited Warranty pursuant to Sec 10;
c) Service by service technicians who are not qualified under the relevant law and/or applicable regulations at the place of installation;
d) The Product's type, nameplate or module serial number is changed, erased or made illegible (other than by any act or omission of Peimar);
e) The Product’s installation on mobile units (except photovoltaic tracking system), such as vehicles, ships or offshore-structures;
f) Exposure to voltage in excess to the maximum system voltage or power surges;
g) Defective components in the construction on which the module is mounted;
h) exposure to mold discoloration or similar external effects;
i) exposure to any of the following: extreme thermal or environmental conditions or rapid changes in such conditions, corrosion, oxidation, unauthorized modifications or connections, unauthorized opening, servicing by use of unauthorized spare parts, accident, force of nature (such as lightning strike, earthquake), influence from chemical products or other acts beyond Peimar’s reasonable control (including damage by fire, flood, etc.);
INDEMNITIES AND LIMITATION OF LIABILITY 16.1. In addition to the indemnification provisions contained in this Agreement, Principal agrees to indemnify, defend and hold harmless Custodian and its affiliates providing services under this Agreement, including their respective officers, directors, agents and employees from all taxes, charges, expenses, assessments, claims and liabilities including, without limitation, reasonable attorneys' fees and disbursements and liabilities ("Claims") arising directly or indirectly from any action or omission to act which Custodian takes in connection with the provision of services to Principal. Neither Custodian, nor any of its affiliates, shall be indemnified against any liability (or any expenses incident to such liability) caused by Custodian’s or its affiliates' own willful misfeasance, bad faith, gross negligence or reckless disregard in the performance of Custodian's or its affiliates' activities under this Agreement. The provisions of this Paragraph 15 shall survive termination of this Agreement.
16.2. In all cases, Custodian’s liability under this Agreement shall be limited to the resulting direct loss, if any, incurred by Principal. Under no circumstances shall Custodian be liable for any incidental, consequential, indirect, punitive, or special damage which Principal may incur or suffer in connection with this Agreement.
