MULTIPLE BUILDINGS If the Premises are part of a group of buildings controlled by Lessor, Lessee agrees that it will abide by, keep and observe all reasonable rules and regulations which Lessor may make from time to time for the management, safety, care, and cleanliness of the grounds, the parking and unloading of vehicles and the preservation of good order, as well as for the convenience of other occupants or tenants of such other buildings and their invitees, and that Lessee will pay its fair share of common expenses incurred in connection therewith.
MULTIPLE PORTFOLIOS If Fund is comprised of more than one Portfolio:
Rent Rolls; Operating Histories The Seller has obtained a rent roll (the “Certified Rent Roll(s)”) other than with respect to hospitality properties certified by the related Mortgagor or the related guarantor(s) as accurate and complete in all material respects as of a date within 180 days of the date of origination of the related Mortgage Loan. The Seller has obtained operating histories (the “Certified Operating Histories”) with respect to each Mortgaged Property certified by the related Mortgagor or the related guarantor(s) as accurate and complete in all material respects as of a date within 180 days of the date of origination of the related Mortgage Loan. The Certified Operating Histories collectively report on operations for a period equal to (a) at least a continuous three-year period or (b) in the event the Mortgaged Property was owned, operated or constructed by the Mortgagor or an affiliate for less than three years then for such shorter period of time, it being understood that for mortgaged properties acquired with the proceeds of a Mortgage Loan, Certified Operating Histories may not have been available.
Net Operating Income For any Real Estate and for a given period, an amount equal to the sum of (a) the rents, common area reimbursements, and service and other income for such Real Estate for such period received in the ordinary course of business from tenants or licensees in occupancy paying rent (excluding pre-paid rents and revenues and security deposits except to the extent applied in satisfaction of tenants’ or licensees’ obligations for rent and any non-recurring fees, charges or amounts including, without limitation, set-up fees and termination fees) minus (b) all expenses paid or accrued and related to the ownership, operation or maintenance of such Real Estate for such period, including, but not limited to, taxes, assessments and the like, insurance, utilities, payroll costs, maintenance, repair and landscaping expenses, marketing expenses, and general and administrative expenses (including an appropriate allocation for legal, accounting, advertising, marketing and other expenses incurred in connection with such Real Estate, but specifically excluding general overhead expenses of REIT and its Subsidiaries, any property management fees and non recurring charges), minus (c) the greater of (i) actual property management expenses of such Real Estate, or (ii) an amount equal to three percent (3.0%) of the gross revenues from such Real Estate excluding straight line leveling adjustments required under GAAP and amortization of intangibles pursuant to FAS 141R, minus (d) all rents, common area reimbursements and other income for such Real Estate received from tenants or licensees in default of payment or other material obligations under their lease, or with respect to leases as to which the tenant or licensee or any guarantor thereunder is subject to any bankruptcy, reorganization, arrangement, insolvency, readjustment of debt, dissolution, liquidation or similar debtor relief proceeding.
Multiple Roles The parties expressly acknowledge and consent to Xxxxx Fargo Bank, National Association, acting in the multiple roles of the Indenture Trustee, the Custodian, the Back-Up Servicer and the Successor Servicer. Xxxxx Fargo Bank, National Association may, in such capacities, discharge its separate functions fully, without hindrance or regard to conflict of interest principles, duty of loyalty principles or other breach of fiduciary duties to the extent that any such conflict or breach arises from the performance by Xxxxx Fargo Bank, National Association of express duties set forth in this Indenture in any of such capacities, all of which defenses, claims or assertions are hereby expressly waived by the other parties hereto except in the case of negligence (other than errors in judgment) and willful misconduct by Xxxxx Fargo Bank, National Association.
Turn-Over After the occurrence and during the continuance of any Default (including the commencement and continuation of any proceeding under any Bankruptcy Law relating to any other Loan Party), each Guarantor shall, if the Administrative Agent so requests, collect, enforce and receive payments on account of the Subordinated Obligations as trustee for the Secured Parties and deliver such payments to the Administrative Agent on account of the Guaranteed Obligations (including all Post Petition Interest), together with any necessary endorsements or other instruments of transfer, but without reducing or affecting in any manner the liability of such Guarantor under the other provisions of this Guaranty.
Multiple Copies This Agreement may be executed in one or more counterparts, each of which shall be deemed an original and all of which shall together constitute one and the same instrument. The terms of this Agreement shall become binding upon each party from and after the time that he or it executed a copy hereof. In like manner, from and after the time that any party executes a consent or other document, such consent or other document shall be binding upon such parties.
Target Net Assets The Company agrees that the Target Business that it acquires must have a fair market value equal to at least 80% of the balance in the Trust Account at the time of signing the definitive agreement for the Business Combination with such Target Business (excluding taxes payable and the Deferred Underwriting Commissions). The fair market value of such business must be determined by the Board of Directors of the Company based upon standards generally accepted by the financial community, such as actual and potential sales, earnings, cash flow and book value. If the Board of Directors of the Company is not able to independently determine that the target business meets such fair market value requirement, the Company will obtain an opinion from an independent investment banking firm or another independent entity that commonly renders valuation opinions with respect to the satisfaction of such criteria. The Company is not required to obtain an opinion as to the fair market value if the Company’s Board of Directors independently determines that the Target Business does have sufficient fair market value.
Substantial Completion The Tenant Improvements shall be deemed to be “Substantially Completed” on the date that (i) the Tenant Improvements are essentially and satisfactorily completed in accordance with the Final Plans to the extent that the Leased Premises may be occupied by Tenant for its Approved Use, subject only to completion of minor finishing, adjustment of equipment, and other minor construction aspects (“punch list items”) which do not, in the aggregate, cause interference (other than minor inconvenience) with the use and occupancy of the Leased Premises for the Approved Use, and (ii) a certificate of occupancy, whether conditional or final, has been issued by the proper governmental authority. Landlord shall give Tenant at least 30 days prior notice (written or oral) of Landlord’s reasonable estimate of the date of Substantial Completion of the Tenant Improvements. Tenant shall schedule with Landlord a mutually acceptable date, which will not be later than 3 business days after the date of Substantial Completion (but in no event earlier than the Landlord’s estimated date of Substantial Completion), for a walk-through inspection of the Leased Premises. In such walk-through, Landlord and Tenant will mutually and reasonably agree upon a punch list, and subject to Tenant Delay, Landlord will use reasonable efforts to cause such punch list work to be completed within 30 days after such walk-through. Landlord hereby warrants to Tenant, which warranty shall survive for one year following the date of Substantial Completion of the Tenant Improvements, that (a) the materials and equipment furnished by Landlord and Landlord’s contractors in the completion of the Tenant Improvements will be of good quality and new, and (b) such materials and equipment and the work of such contractors shall be free from defects not inherent in the quality required or permitted hereunder. This warranty shall exclude damages or defects caused by Tenant, its agents, employees or contractors, improper or insufficient maintenance, improper operation or normal wear and tear under normal usage. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by November 1, 2018. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed on or before December 1, 2018, (the “Fifth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fifth Floor Substantial Completion Date that the Tenant Improvements for the Fifth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fifth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the Commencement Date and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed by February 1, 2019. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed on or before March 1, 2019, (the “Fourth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fourth Floor Substantial Completion Date that the Tenant Improvements for the Fourth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fourth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the June 1, 2019, and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Subject only to Force Majeure and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required Construction Permits by not later than June 30, 2018, if the Tenant Improvements for the Leased Premises are not Substantially Completed on or before April 1, 2019 (“Outside Completion Date”), then Tenant shall have the one-time right by not later than 10 days after the Outside Completion Date to terminate this lease by delivering written notice to Landlord, which notice shall be hand delivered to 0000 Xxxx Xxxxx Xxxxx, Xxxxxxxx, Xxxx 00000, Attention: Xxxxxx X. Xxxxx, Xx., and upon hand delivery of such termination notice to said address, this lease shall be deemed null and void and the parties shall have no further rights or obligations hereunder, except those that specifically survive the expiration or earlier termination of this lease. Landlord and Tenant acknowledge and agree that Tenant’s damages as a result of Landlord’s failure to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by not later than the Fifth Floor Substantial Completion Date or the Fourth Floor Premises to be Substantially Completed by not later than the Fourth Floor Substantial Completion Date are difficult to ascertain, that such amounts set forth above are a reasonable pre-estimate of Tenant’s probable loss as a result thereof and that such damages constitute reasonable liquidated damages for Tenant’s loss and not a penalty.
Project or Building Name and Signage Landlord shall have the right at any time to change the name of the Project or Building and to install, affix and maintain any and all signs on the exterior and on the interior of the Project or Building as Landlord may, in Landlord’s sole discretion, desire. Tenant shall not use the name of the Project or Building or use pictures or illustrations of the Project or Building in advertising or other publicity or for any purpose other than as the address of the business to be conducted by Tenant in the Premises, without the prior written consent of Landlord.
