No Damage. The Project Improvements shall not have been injured or damaged by fire, explosion, accident, flood or other casualty, unless Lender shall be satisfied that sufficient insurance proceeds will be available in the reasonable judgment of Lender to effect the satisfactory restoration of the Project Improvements and to permit the Completion of the Improvements prior to the Required Completion Date.
Appears in 7 contracts
Samples: Project Loan Agreement (Acadia Realty Trust), Project Loan Agreement (Acadia Realty Trust), Building Loan Agreement (Acadia Realty Trust)
No Damage. The Project Improvements shall not have been injured or damaged by fire, explosion, accident, flood or other casualty, unless Lender shall be satisfied that sufficient insurance proceeds will be available in the reasonable judgment of Lender to effect the satisfactory restoration of the Project Improvements and to permit the Completion of the Improvements prior to the Required Completion Date.. 2.10.5
Appears in 1 contract
Samples: Project Loan Agreement
No Damage. The Project Improvements shall not have been injured or damaged by fire, explosion, accident, flood or other casualty, unless Lender shall be satisfied that sufficient insurance proceeds will be available in the reasonable judgment of Lender to effect the 49 satisfactory restoration of the Project Improvements and to permit the Completion of the Improvements prior to the Required Completion Date.
Appears in 1 contract
