No Defaults or Restrictions Neither the execution and delivery of the Transaction Documents nor compliance with their respective terms and conditions will (whether with or without the giving of notice or lapse of time or both) (i) violate, conflict with or result in a breach of, or constitute a default under: (1) the Charter or Bylaws of the Company; (2) any of the terms, obligations, covenants, conditions or provisions of any corporate restriction or of any contract, agreement, indenture, mortgage, deed of trust, pledge, bank loan or credit agreement, or any other agreement or instrument to which the Company or Bank, as applicable, is now a party or by which it or any of its properties may be bound or affected; (3) any judgment, order, writ, injunction, decree or demand of any court, arbitrator, grand jury, or Governmental Agency applicable to the Company or the Bank; or (4) any statute, rule or regulation applicable to the Company, except, in the case of items (2), (3) or (4), for such violations and conflicts that would not reasonably be expected to have, singularly or in the aggregate, a Material Adverse Effect on the Company and its Subsidiaries taken as a whole, or (ii) result in the creation or imposition of any lien, charge or encumbrance of any nature whatsoever upon any property or asset of the Company. Neither the Company nor the Bank is in default in the performance, observance or fulfillment of any of the terms, obligations, covenants, conditions or provisions contained in any indenture or other agreement creating, evidencing or securing Indebtedness of any kind or pursuant to which any such Indebtedness is issued, or any other agreement or instrument to which the Company or the Bank, as applicable, is a party or by which the Company or the Bank, as applicable, or any of its properties may be bound or affected, except, in each case, only such defaults that would not reasonably be expected to have, singularly or in the aggregate, a Material Adverse Effect on the Company.
No Defaults; Violations No material default exists in the due performance and observance of any term, covenant or condition of any material license, contract, indenture, mortgage, deed of trust, note, loan or credit agreement, or any other agreement or instrument evidencing an obligation for borrowed money, or any other material agreement or instrument to which the Company is a party or by which the Company may be bound or to which any of the properties or assets of the Company is subject. The Company is not in violation of any term or provision of its Charter or by-laws, or in violation of any franchise, license, permit, applicable law, rule, regulation, judgment or decree of any Governmental Entity.
Absence of Defaults and Conflicts Resulting from Transaction The execution, delivery and performance of this Agreement, and the sale of the Securities, will not result in a breach or violation of any of the terms and provisions of, or constitute a default or a Debt Repayment Triggering Event (as defined below) under, or result in the imposition of any lien, charge or encumbrance upon any property or assets of the Company or any of its subsidiaries pursuant to, (A) the charter, by-laws or similar organizational documents of the Company or any of its subsidiaries, (B) any statute, rule, regulation or order of any governmental agency or body or any court, domestic or foreign, having jurisdiction over the Company or any of its subsidiaries or any of their properties, or (C) any agreement or instrument to which the Company or any of its subsidiaries is a party or by which the Company or any of its subsidiaries is bound or to which any of the properties of the Company or any of its subsidiaries is subject except, in the case of clauses (B) and (C) above, any breach, violation, default, lien, charge or encumbrance that would not, individually or in the aggregate, reasonably be expected to have a Material Adverse Effect; a “Debt Repayment Triggering Event” means any event or condition that gives, or with the giving of notice or lapse of time would give, the holder of any note, debenture, or other evidence of indebtedness (or any person acting on such holder’s behalf) the right to require the repurchase, redemption or repayment of all or a portion of such indebtedness by the Company or any of its subsidiaries.
Age Restrictions Drivers must be 21 years of age or over.
Use Restrictions (a) Company will not do or attempt to do, and Company will not permit any other person or entity to do or attempt to do, any of the following, directly or indirectly: (i) use any Proprietary Item for any purpose, at any location or in any manner not specifically authorized by this Agreement; (ii) make or retain any copy of any Proprietary Item except as specifically authorized by this Agreement; (iii) create, recreate or obtain the source code for any Proprietary Item; (iv) refer to or otherwise use any Proprietary Item as part of any effort to develop other software, programs, applications, interfaces or functionalities or to compete with BNYM or a Third Party Provider; (v) modify, adapt, translate or create derivative works based upon any Proprietary Item, or combine or merge any Proprietary Item or part thereof with or into any other product or service not provided for in this Agreement and not authorized in writing by BNYM; (vi) remove, erase or tamper with any copyright or other proprietary notice printed or stamped on, affixed to, or encoded or recorded in any Proprietary Item, or fail to preserve all copyright and other proprietary notices in any copy of any Proprietary Item made by Company; (vii) sell, transfer, assign or otherwise convey in any manner any ownership interest or Intellectual Property Right of BNYM, or market, license, sublicense, distribute or otherwise grant, or subcontract or delegate to any other person, including outsourcers, vendors, consultants, joint venturers and partners, any right to access or use any Proprietary Item, whether on Company’s behalf or otherwise; (viii) subcontract for or delegate the performance of any act or function involved in accessing or using any Proprietary Item, whether on Company’s behalf or otherwise; (ix) reverse engineer, re-engineer, decrypt, disassemble, decompile, decipher, reconstruct, re-orient or modify the circuit design, algorithms, logic, source code, object code or program code or any other properties, attributes, features or constituent parts of any Proprietary Item; (x) take any action that would challenge, contest, impair or otherwise adversely effect an ownership interest or Intellectual Property Right of BNYM; (xi) use any Proprietary Item to provide remote processing, network processing, network communications, a service bureau or time sharing operation, or services similar to any of the foregoing to any person or entity, whether on a fee basis or otherwise; (xii) allow Harmful Code into any Proprietary Item, as applicable, or into any interface or other software or program provided by it to BNYM, through Company’s systems or personnel or Company’s use of the Licensed Services or Company’s activities in connection with this Agreement. (b) Company shall, promptly after becoming aware of such, notify BNYM of any facts, circumstances or events regarding its or a Permitted User’s use of the Licensed System that are reasonably likely to constitute or result in a breach of this Section 2.12, and take all reasonable steps requested by BNYM to prevent, control, remediate or remedy any such facts, circumstances or events or any future occurrence of such facts, circumstances or events.
EVENTS OF DEFAULTS AND CONSEQUENCES 9.1 Subject to the Force Majeure clause, the Promoter shall be considered under a condition of Default, in the following events: (i) Promoter fails to provide ready to move in possession of the [Apartment/Plot] to the Allottee within the time period specified in para 7.1 or fails to complete the project within the stipulated time disclosed at the time of registration of the project with the Authority. For the purpose of this para, 'ready to move in possession' shall mean that the apartment shall be in a habitable condition which is complete in all respects including the provision of all specifications, amenities and facilities, as agreed to between the parties, and for which occupation certificate and completion certificate, as the case may be, has been issued by the competent authority; (ii) Discontinuance of the Promoter’s business as a developer on account of suspension or revocation of his registration under the provisions of the Act or the rules or regulations made the re under. 9.2 In case of Default by Promoter under the conditions listed above, Allottee is entitled to the following: (i) Stop making further payments to Promoter as demanded by the Promoter. If the Allottee stops making payments, the Promoter shall correct the situation by completing the construction milestones and only thereafter the Allottee be required to make the next payment without any interest; or (ii) The Allottee shall have the option of terminating the Agreement in which case the Promoter shall be liable to refund the entire money paid by the Allottee under any head whatsoever towards the purchase of the apartment, along with interest at the rate prescribed in the Rules within forty-five days of receiving the termination notice: Provided that where an Allottee does not intend to withdraw from the project or terminate the Agreement, he shall be paid, by the promoter, interest at the rate prescribed in the Rules, for every month of delay till the handing over of the possession of the [Apartment/Plot], which shall be paid by the promoter to the allottee within forty-five days of it becoming due. 9.3 The Allottee shall be considered under a condition of Default, on the occurrence of the following events: (i) In case the Allottee fails to make payments for consecutive demands made by the Promoter as per the Payment Plan annexed hereto, despite having been issued notice in that regard the allottee shall be liable to pay interest to the promoter on the unpaid amount at the rate prescribed in the Rules; (ii) In case of Default by Allottee under the condition listed above continues for a period beyond consecutive months after notice from the Promoter in this regard, the Promoter may cancel the allotment of the [Apartment/Plot] in favour of the Allottee and refund the money paid to him by the allottee by deducting the booking amount and the interest liabilities and this Agreement shall thereupon stand terminated. Provided that the promoter shall intimate the allottee about such termination at least thirty days prior to such termination.
Usage Restrictions Customer will not (a) make any Service or Content available to anyone other than Customer or Users, or use any Service or Content for the benefit of anyone other than Customer or its Affiliates, unless expressly stated otherwise in an Order Form or the Documentation, (b) sell, resell, license, sublicense, distribute, make available, rent or lease any Service or Content, or include any Service or Content in a service bureau or outsourcing offering, (c) use a Service or Non-Xxxxxx Application to store or transmit infringing, libelous, or otherwise unlawful or tortious material, or to store or transmit material in violation of third-party privacy rights, (d) use a Service or Non-Xxxxxx Application to store or transmit Malicious Code, (e) interfere with or disrupt the integrity or performance of any Service or third-party data contained therein, (f) attempt to gain unauthorized access to any Service or Content or its related systems or networks, (g) permit direct or indirect access to or use of any Services or Content in a way that circumvents a contractual usage limit, or use any Services to access or use any of Xxxxxx intellectual property except as permitted under this Agreement, an Order Form, or the Documentation, (h) modify, copy, or create derivative works based on a Service or any part, feature, function or user interface thereof, (i) copy Content except as permitted herein or in an Order Form or the Documentation, (j) frame or mirror any part of any Service or Content, other than framing on Customer's own intranets or otherwise for its own internal business purposes or as permitted in the Documentation, (k) except to the extent permitted by applicable law, disassemble, reverse engineer, or decompile a Service or Content or access it to (1) build a competitive product or service, (2) build a product or service using similar ideas, features, functions or graphics of the Service, (3) copy any ideas, features, functions or graphics of the Service, or (4) determine whether the Services are within the scope of any patent.
Notification of Defaults and Events of Default Each Lender hereby agrees that, upon learning of the existence of a Default or an Event of Default, it shall promptly notify the Administrative Agent thereof. The Administrative Agent hereby agrees that upon receipt of any notice under this §14.10 it shall promptly notify the other Lenders of the existence of such Default or Event of Default.
Covenants, Conditions and Restrictions This Lease is subject to the effect of (i) any covenants, conditions, restrictions, easements, mortgages or deeds of trust, ground leases, rights of way of record and any other matters or documents of record; and (ii) any zoning laws of the city, county and state where the Building is situated (collectively referred to herein as "Restrictions") and Tenant will conform to and will not violate the terms of any such Restrictions.
Additional Restrictions In addition to any other restrictions on transfer contained in this Agreement, in no event may any Transfer of a Partnership Interest by any Partner or any redemption pursuant to Section 8.6 be made without the express consent of the General Partner, in its sole and absolute discretion, (i) to any person or entity who lacks the legal right, power or capacity to own a Partnership Interest; (ii) in violation of applicable law; (iii) of any component portion of a Partnership Interest, such as the Capital Account, or rights to distributions, separate and apart from all other components of a Partnership Interest; (iv) if in the opinion of the General Partner based on the advice of legal counsel, if appropriate, such Transfer would cause a termination of the Partnership for Federal or state income tax purposes (except as a result of a redemption of all Partnership Units held by all Limited Partners); (v) if in the opinion of the General Partner based on the advice of legal counsel, if appropriate, such Transfer would cause the Partnership to cease to be classified as a partnership for Federal income tax purposes (except as a result of a redemption of all Partnership Units held by all Limited Partners); (vi) if such Transfer requires the registration of such Partnership Interest pursuant to any applicable federal or state securities laws; (vii) if such Transfer would cause the Partnership to become a “publicly traded partnership,” as such term is defined in Section 7704(b) of the Code (provided that this clause (vii) shall not be the basis for limiting or restricting in any manner the exercise of the Redemption Right under Section 8.6 unless, and only to the extent that, outside tax counsel advises the General Partner that, in the absence of such limitation or restriction, there is a significant risk that the Partnership will be treated as a “publicly traded partnership” and, by reason thereof, taxable as a corporation); (viii) if such Transfer would cause the General Partner to own 10% or more of the ownership interests of any tenant of a property held by the Partnership within the meaning of Section 856(d)(2)(B) of the Code; (ix) if such Transfer would result in the General Partner being “closely held” within the meaning of Section 856(h) of the Code; or (x) if in the opinion the General Partner based on the advice of legal counsel, if appropriate, such Transfer would adversely affect the ability of the General Partner to continue to qualify as a REIT or subject the General Partner to any additional taxes under Section 857 or Section 4981 of the Code.
