No Relief for Apparent Errors or Omissions Sample Clauses

No Relief for Apparent Errors or Omissions. Contractor shall not take unfair advantage of any apparent error or omission which may be found in the Contract Documents for a Project, and Owner and the Architect for such Project shall be entitled to make such corrections therein and interpretations thereof as may be necessary for fulfillment of the intent of the Contract Documents for such Project. Omissions from the Drawings or Specifications for a Project, or missing description of details of Work for a Project which are manifestly necessary to carry out the intent of the Contract Documents for such Project shall not relieve Contractor from performing such omitted or missing described Work and shall be performed as fully as if set forth in full in the Contract Documents for such Project without adjustment of the Contract Sum for such Project.
Sample 1
AutoNDA by SimpleDocs

Related to No Relief for Apparent Errors or Omissions

  • Delays or Omissions No delay or omission to exercise any right, power or remedy accruing to any party under this Agreement, upon any breach or default of any other party under this Agreement, shall impair any such right, power or remedy of such non-breaching or non-defaulting party nor shall it be construed to be a waiver of any such breach or default, or an acquiescence therein, or of or in any similar breach or default thereafter occurring; nor shall any waiver of any single breach or default be deemed a waiver of any other breach or default theretofore or thereafter occurring. Any waiver, permit, consent or approval of any kind or character on the part of any party of any breach or default under this Agreement, or any waiver on the part of any party of any provisions or conditions of this Agreement, must be in writing and shall be effective only to the extent specifically set forth in such writing. All remedies, either under this Agreement or by law or otherwise afforded to any party, shall be cumulative and not alternative.

  • Errors/Omissions The Engineer shall make revisions to the work authorized in this contract which are necessary to correct errors or omissions appearing therein, when required to do so by the State. No additional compensation shall be paid for this work.

  • No Warranty In executing and delivering this Lease, Tenant has not relied on any representations, including, but not limited to, any representation as to the amount of any item comprising Additional Rent or the amount of the Additional Rent in the aggregate or that Landlord is furnishing the same services to other tenants, at all, on the same level or on the same basis, or any warranty or any statement of Landlord which is not set forth herein or in one or more of the exhibits attached hereto.

  • Acts or Omissions Vendor shall indemnify and hold harmless the State of Texas and Customers, AND/OR THEIR OFFICERS, AGENTS, EMPLOYEES, REPRESENTATIVES, CONTRACTORS, ASSIGNEES, AND/OR DESIGNEES FROM ANY AND ALL LIABILITY, ACTIONS, CLAIMS, DEMANDS, OR SUITS, AND ALL RELATED COSTS, ATTORNEY FEES, AND EXPENSES arising out of, or resulting from any acts or omissions of the Vendor or its agents, employees, subcontractors, Order Fulfillers, or suppliers of subcontractors in the execution or performance of the Contract and any Purchase Orders issued under the Contract. THE DEFENSE SHALL BE COORDINATED BY VENDOR WITH THE OFFICE OF THE ATTORNEY GENERAL WHEN TEXAS STATE AGENCIES ARE NAMED DEFENDANTS IN ANY LAWSUIT AND VENDOR MAY NOT AGREE TO ANY SETTLEMENT WITHOUT FIRST OBTAINING THE CONCURRENCE FROM THE OFFICE OF THE ATTORNEY GENERAL. VENDOR AND THE CUSTOMER AGREE TO FURNISH TIMELY WRITTEN NOTICE TO EACH OTHER OF ANY SUCH CLAIM.

  • Liability for Acts or Omissions of Third Parties Neither BellSouth nor Mpower shall be liable for any act or omission of another telecommunications company providing a portion of the services provided under this Agreement.

  • No Warranties By providing Confidential Information, no Party makes any warranties or representations as to its accuracy or completeness. In addition, by supplying Confidential Information, no Party obligates itself to provide any particular information or Confidential Information to the other Parties nor to enter into any further agreements or proceed with any other relationship or joint venture.

  • Disclaimer of Other Warranties EXCEPT AS OTHERWISE EXPRESSLY ------------------------------ PROVIDED HEREIN, THE SALE OF THE EQUIPMENT IS HEREBY MADE ON AN "AS-IS WHERE-IS" BASIS. SELLER MAKES NO REPRESENTATIONS OR WARRANTIES, EXPRESSED OR IMPLIED, WITH RESPECT TO (i) THE EQUIPMENT, INCLUDING, WITHOUT LIMITATION OF THE FOREGOING, ITS SELECTION, QUALITY, DESIGN, CAPACITY, CONDITION, MERCHANTABILITY OR ITS FITNESS FOR USE OR FOR ANY PARTICULAR PURPOSE AND FREEDOM FROM CLAIMS OF COPYRIGHT OR PATENT INFRINGEMENT OR ABSENCE OF OBLIGATIONS BASED ON STRICT LIABILITY IN TORT OR NEGLIGENCE, (ii) THE FREEDOM OF THE EQUIPMENT (OR ANY PART OR PORTION THEREOF) FROM ANY LATENT OR OTHER DEFECT (WHETHER OR NOT DISCOVERABLE), (iii)THE COMPLIANCE OF ANY OF THE EQUIPMENT (OR ANY PART OR PORTION THEREOF) WITH ANY APPLICABLE LAWS OR REGULATIONS, (iv) THE CREDITWORTHINESS OF EACH LESSEE OR ANY OTHER PERSON UNDER THE LEASES AND THE TRANSACTION DOCUMENTS, (v) THE COLLECTIBILITY OF ANY AMOUNT UNDER THE LEASES AND ANY OF THE TRANSACTION DOCUMENTS, (vi) THE TAX CHARACTERIZATION OF THE LEASES, OR (vii) THE DUE AUTHORIZATION, EXECUTION AND DELIVERY BY, OR THE ENFORCEABILITY AGAINST, ANY PERSON WHO IS OR HAS BEEN A PARTY TO THE LEASES AND ANY OF THE TRANSACTION DOCUMENTS (WITH THE EXCEPTION OF THE SELLER) AND SELLER HEREBY DISCLAIMS ALL SUCH REPRESENTATIONS AND WARRANTIES.

  • No Warranty Regarding Goods or Services as Applicable We are not responsible for the quality, safety, legality, or any other aspect of any goods or services you purchase with the Card. Arbitration Any claim, dispute, or controversy (“Claim”) arising out of or relating in any way to: i) this Agreement; ii) the Card; iii) your acquisition of the Card; iv) your use of the Card; v) the amount of available funds in the Card Account; vi) advertisements, promotions or oral or written statements related to the Card, as well as goods or services purchased with the Card; vii) the benefits and services related to the Card; or viii) transactions on the Card, no matter how described, pleaded or styled, shall be FINALLY and EXCLUSIVELY resolved by binding individual arbitration conducted by the American Arbitration Association (“AAA”) under its Consumer Arbitration Rules. This arbitration agreement is made pursuant to a transaction involving interstate commerce, and shall be governed by the Federal Arbitration Act (9 U.S.C. 1-16). We will pay the initial filing fee to commence arbitration and any arbitration hearing that you attend shall take place in the federal judicial district of your residence. ARBITRATION OF YOUR CLAIM IS MANDATORY AND BINDING. NEITHER PARTY WILL HAVE THE RIGHT TO LITIGATE THAT CLAIM THROUGH A COURT. IN ARBITRATION, NEITHER PARTY WILL HAVE THE RIGHT TO A JURY TRIAL OR TO ENGAGE IN DISCOVERY, EXCEPT AS PROVIDED FOR IN THE AAA CODE OF PROCEDURE. For a copy of the procedures, to file a Claim or for other information about this organization, contact it at: AAA, 000 Xxxxxxx Xxxxxx, Xxx Xxxx, XX 00000, or at xxx.xxx.xxx. All determinations as to the scope, interpretation, enforceability and validity of this Agreement shall be made final exclusively by the arbitrator, which award shall be binding and final. Judgment on the arbitration award may be entered in any court having jurisdiction. NO CLASS ACTION, OR OTHER REPRESENTATIVE ACTION OR PRIVATE ATTORNEY GENERAL ACTION OR JOINDER OR CONSOLIDATION OF ANY CLAIM WITH A CLAIM OF ANOTHER PERSON OR CLASS OF CLAIMANTS SHALL BE ALLOWABLE. This arbitration provision shall survive: i) the termination of the Agreement; ii) the bankruptcy of any party; iii) any transfer, sale or assignment of the Card, or any amounts owed on the Card, to any other person or entity; or iv) expiration of the Card. If any portion of this arbitration provision is deemed invalid or unenforceable, the remaining portions shall remain in force. IF YOU DO NOT AGREE TO THE TERMS OF THIS ARBITRATION AGREEMENT, DO NOT ACTIVATE OR USE THE CARD. CALL 0-000-000-0000 TO CANCEL THE CARD AND MAKE ALTERNATE ARRANGEMENTS TO RECEIVE THE FUNDS ASSOCIATED WITH THE CARD ACCOUNT.

  • Professional Liability (Errors & Omissions Insurance with limits of not less than $1,000,000 each occurrence, $2,000,000 aggregate. Such insurance will cover all professional services rendered by or on behalf of PROVIDER and its subcontractors under this Agreement. Renewal policies written on a claims- made basis will maintain the same retroactive date as in effect at the inception of this Agreement. If coverage is written on a claims-made basis, PROVIDER agrees to purchase an Extended Reporting Period Endorsement, effective for two (2) full years after the expiration or cancellation of the policy. No professional liability policy written on an occurrence form will include a sunset or similar clause that limits coverage unless such clause provides coverage for at least three (3) years after the expiration of cancellation of this Agreement.

  • Correction of Errors and Omissions; Other Liabilities (a) In the event any bookkeeping omissions or errors are discovered in preparing any pro forma statement or in completing the transfers and assumptions contemplated hereby, the parties hereto agree to correct such errors and omissions, it being understood that, as far as practicable, all adjustments will be made consistent with the judgments, methods, policies or accounting principles utilized by the Failed Bank in preparing and maintaining Accounting Records, except that adjustments made pursuant to this Section 8.2(a) are not intended to bring the Accounting Records of the Failed Bank into accordance with generally accepted accounting principles.

Time is Money Join Law Insider Premium to draft better contracts faster.