Common use of Notice by Successful Respondent Clause in Contracts

Notice by Successful Respondent. Without limiting its obligations under this Agreement, Successful Respondent shall expeditiously notify DIR when it becomes aware that an act or omission of DIR or DIR Customer personnel or a DIR Contractor shall cause, or has caused, a problem or delay in providing the Services, and shall work with DIR, the DIR Customers, and the DIR Contractor to prevent or circumvent such problem or delay. Successful Respondent shall cooperate with DIR, the DIR Customers, and DIR Contractors to resolve differences and conflicts arising between the Services and other activities undertaken by DIR, the DIR Customers and DIR Contractors.

Notice by Successful Respondent. Without limiting its obligations under this Agreement, Successful Respondent shall expeditiously notify DIR when it becomes aware that an act or omission of DIR or DIR Customer personnel or a DIR Contractor shall cause, or has caused, a problem or delay in providing the Services, and shall use commercially reasonable efforts to work with DIR, the DIR Customers, Customers and the DIR Contractor to prevent or circumvent such problem or delay. Successful Respondent shall cooperate with DIR, the DIR Customers, Customers and DIR Contractors to resolve differences and conflicts arising between the Services and other activities undertaken by DIR, the DIR Customers and DIR Contractors.

Notice by Successful Respondent. Without limiting its obligations under this Agreement, Successful Respondent shall expeditiously notify DIR when it becomes aware that an act or omission of DIR or DIR DCS Customer personnel or a DIR Contractor shall cause, or has caused, a problem or delay in providing the Services, and shall work with DIR, the DIR Customers, and the DIR Contractor to prevent or circumvent such problem or delay. Successful Respondent shall cooperate with DIR, the DIR Customers, and DIR Contractors to resolve differences and conflicts arising between the Services and other activities undertaken by DIR, the DIR Customers and DIR Contractors.