Notice by Successful Respondent. Without limiting its obligations under this CTSA, Successful Respondent shall expeditiously notify DIR when it becomes aware that an act or omission of DIR or Customer personnel or a DIR Contractor shall cause, or has caused, a problem or delay in providing the Services, and shall work with DIR, the Customers, and the DIR Contractor to prevent or circumvent such problem or delay. Successful Respondent shall cooperate with DIR, the Customers, and DIR Contractors to resolve differences and conflicts arising between the Services and other activities undertaken by DIR, the Customers and DIR Contractors.
Appears in 5 contracts
Samples: Communications Technology Services Agreement, Communications Technology Services Agreement, Communications Technology Services Agreement
