Notice of Completion; Copy of Record Set of Plans Within fifteen (15) days after completion of construction of the Improvements, Tenant shall cause a Notice of Completion to be recorded in the office of the Recorder of the county in which the Building is located in accordance with Section 8182 of the Civil Code of the State of California or any successor statute, and shall furnish a copy thereof to Landlord upon such recordation. If Tenant fails to do so, Landlord may execute and file the same as Tenant’s agent for such purpose, at Tenant’s sole cost and expense. At the conclusion of construction, (i) Tenant shall cause the Architect and Contractor (A) to update the Approved Working Drawings as necessary to reflect all changes made to the Approved Working Drawings during the course of construction, (B) to certify to the best of their knowledge that the “record-set” of as-built drawings are true and correct, which certification shall survive the expiration or termination of this Lease, and (C) to deliver to Landlord two (2) sets of copies of such record set of drawings within ninety (90) days following issuance of a certificate of occupancy for the Premises, and (ii) Tenant shall deliver to Landlord a copy of all warranties, guaranties, and operating manuals and information relating to the improvements, equipment, and systems in the Premises.
Procedure for Termination, Amendment, Extension or Waiver A termination of this Agreement pursuant to Section 7.01, an amendment of this Agreement pursuant to Section 7.03 or an extension or waiver of this Agreement pursuant to Section 7.04 shall, in order to be effective, require in the case of Parent, Sub or the Company, action by its Board of Directors.
Contract Negotiations Where operational requirements permit, and on reasonable notice, the Employer shall grant special leave with pay for not more than two (2) representatives of each bargaining unit for the purpose of attending contract negotiation meetings with the Employer on behalf of the Union. Such permission shall not be unreasonably withheld.
Termination Notice for Force Majeure Event If a Force Majeure Event subsists for a period of 180 (one hundred and eighty) days or more within a continuous period of 365 (three hundred and sixty five) days, either Party may in its discretion terminate this Agreement by issuing a Termination Notice to the other Party without being liable in any manner whatsoever, save as provided in this Article 34, and upon issue of such Termination Notice, this Agreement shall, notwithstanding anything to the contrary contained herein, stand terminated forthwith; provided that before issuing such Termination Notice, the Party intending to issue the Termination Notice shall inform the other Party of such intention and grant 15 (fifteen) days time to make a representation, and may after the expiry of such 15 (fifteen) days period, whether or not it is in receipt of such representation, in its sole discretion issue the Termination Notice.
Notice of Events As soon as Guarantor obtains knowledge thereof, Guarantor shall give Guarantied Party written notice of any condition or event which has resulted in (a) a material adverse change in the financial condition of Guarantor or Company or (b) any Event of Default or Potential Event of Default.
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
YOUR BILLING RIGHTS - KEEP THIS NOTICE FOR FUTURE USE This notice tells you about your rights and our responsibilities under the Fair Credit Billing Act.
CONDITIONS OF SETTLEMENT, EFFECT OF DISAPPROVAL, CANCELLATION OR TERMINATION 9.1. The Effective Date of this Settlement Agreement shall not occur unless and until each and every one of the following events occurs:
(a) This Agreement has been signed by the Parties and Class Counsel, and the individual settlement agreements with Xxxxxxxxx Xxxxx, the heirs of Xxxxx Xxxxx, Xxxxxx Xxxxxxxxx, and Xxxxxx Xxxxxxxx-Xxx have been fully executed;
(b) The Court has entered an order granting Preliminary Approval of the Agreement;
(c) The Court has entered a Final Approval Order finally approving the Agreement, or a judgment substantially consistent with this Settlement Agreement that has become final and unappealable, following Notice and a Final Approval Hearing, as provided in the Federal Rules of Civil Procedure; and
(d) In the event that the Court enters an approval order and final judgment in a form other than that provided above (“Alternative Approval Order”) to which the Parties have consented, that Alternative Approval Order has become final and unappealable.
9.2. If some or all of the conditions specified in Paragraph 9.1 are not met, or in the event that this Settlement Agreement is not approved by the Court, or the settlement set forth in this Agreement is terminated or fails to become effective in accordance with its terms, then this Settlement Agreement shall be canceled and terminated subject to Paragraph 9.3, unless Class Counsel and Defendant’s Counsel mutually agree in writing to proceed with this Agreement. If any Party is in material breach of the terms hereof, any other Party, provided that it is in substantial compliance with the terms of this Agreement, may terminate this Agreement on notice to all other Parties. Notwithstanding anything herein, the Parties agree that the Court’s decision as to the amount of the Illinois Fee Award and Ohio Fee Award to Class Counsel set forth above or the incentive award to the Class Representatives, regardless of the amounts awarded, shall not prevent the Agreement from becoming effective, nor shall it be grounds for termination of the Agreement.
9.3. If this Agreement is terminated or fails to become effective for the reasons set forth in Paragraphs 6.1, 6.2, 9.1, or 9.2 above, the Parties shall be restored to their respective positions in the Action as of the date of the signing of this Agreement. In such event, any Final Approval Order or other order entered by the Court in accordance with the terms of this Agreement shall be treated as vacated, nunc pro tunc, and the Parties shall be returned to the status quo ante with respect to the Actions as if this Agreement had never been entered into, including Defendant’s right to seek to compel arbitration as to the Plaintiffs named in the Second Amended Complaint.
9.4. In the event the Settlement is terminated or fails to become effective for any reason, the Illinois Settlement Fund and Ohio Settlement Fund, together with any earnings thereon at the same rate as earned, less any taxes paid or due, less Settlement Administrative Expenses actually incurred and paid or payable from the Settlement Fund, shall be returned to Defendant or its Insurer within thirty (30) calendar days after written notification of such event in accordance with instructions provided by Defendant’s Counsel to the Settlement Administrator.
Notice to Allow Exercise by Hxxxxx If (A) the Company shall declare a dividend (or any other distribution in whatever form) on the Common Stock, (B) the Company shall declare a special nonrecurring cash dividend on or a redemption of the Common Stock, (C) the Company shall authorize the granting to all holders of the Common Stock rights or warrants to subscribe for or purchase any shares of capital stock of any class or of any rights, (D) the approval of any stockholders of the Company shall be required in connection with any reclassification of the Common Stock, any consolidation or merger to which the Company (or any of its Subsidiaries) is a party, any sale or transfer of all or substantially all of its assets, or any compulsory share exchange whereby the Common Stock is converted into other securities, cash or property, or (E) the Company shall authorize the voluntary or involuntary dissolution, liquidation or winding up of the affairs of the Company, then, in each case, the Company shall cause to be delivered by email to the Holder at its last email address as it shall appear upon the Warrant Register of the Company, at least 20 calendar days prior to the applicable record or effective date hereinafter specified, a notice stating (x) the date on which a record is to be taken for the purpose of such dividend, distribution, redemption, rights or warrants, or if a record is not to be taken, the date as of which the holders of the Common Stock of record to be entitled to such dividend, distributions, redemption, rights or warrants are to be determined or (y) the date on which such reclassification, consolidation, merger, sale, transfer or share exchange is expected to become effective or close, and the date as of which it is expected that holders of the Common Stock of record shall be entitled to exchange their shares of the Common Stock for securities, cash or other property deliverable upon such reclassification, consolidation, merger, sale, transfer or share exchange; provided that the failure to deliver such notice or any defect therein or in the delivery thereof shall not affect the validity of the corporate action required to be specified in such notice. To the extent that any notice provided in this Warrant constitutes, or contains, material, non-public information regarding the Company or any of the Subsidiaries, the Company shall simultaneously file such notice with the Commission pursuant to a Current Report on Form 8-K. The Holder shall remain entitled to exercise this Warrant during the period commencing on the date of such notice to the effective date of the event triggering such notice except as may otherwise be expressly set forth herein.
NOTICE OF DELAYS Except as otherwise provided under this Contract, when either party has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this Contract, that party shall, within one (1) business day, give notice thereof, including all relevant information with respect thereto, to the other party.
