NOTICE OF DELAYS. Except as otherwise provided under this Contract, when either party has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this Contract, that party shall, within one (1) business day, give notice thereof, including all relevant information with respect thereto, to the other party.
NOTICE OF DELAYS. 21 Except as otherwise provided under this Agreement, when either party has 22 knowledge that any actual or potential situation is delaying or threatens to 23 delay the timely performance of this Agreement, that party shall, within one 24 (1) business day, give notice thereof, including all relevant information with 25 respect thereto, to the other party.
NOTICE OF DELAYS. 4 Except as otherwise provided under this Agreement, when either party has 5 knowledge that any actual or potential situation is delaying or threatens to 6 delay the timely performance of this Agreement, that party shall, within one 7 (1) business day, give notice thereof, including all relevant information with 8 respect thereto, to the other party.
NOTICE OF DELAYS. Except as otherwise provided under this Master Agreement, when either party has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this Master Agreement, that party shall, within one (1) business day, give notice thereof, including all relevant information with respect thereto, to the other party.
NOTICE OF DELAYS. Except as otherwise expressly provided herein, when either Party has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this Contract, that party shall, within five (5) days, give notice thereof, including all relevant information with respect thereto, to the other party.
NOTICE OF DELAYS. Within seven (7) days after commencement of any delay on account of which the BUILDER claims that it is entitled under this CONTRACT to an extension of the DELIVERY DATE of the VESSEL, excluding delays due to arbitration, the BUILDER shall advise the BUYER in writing or by e-mail or facsimile of the date such delay commenced, the reasons thereof and, if possible, its estimated duration of the probable delay in the delivery of the VESSEL, and shall supply the BUYER if reasonably available with evidence to justify the delay claimed. Within seven (7) days after such cause of delay ends, the BUILDER shall likewise advise the BUYER in writing or by e-mail or facsimile of the date that such cause of delay ended, and also, shall specify the period of time by which the BUILDER claims the DELIVERY DATE should be extended by reason of such delay. Failure of the BUYER to object to the BUILDER’s notification of any claim for extension of the date for delivery of the VESSEL within seven (7) days after receipt by the BUYER of such notification shall be deemed to be a waiver by the BUYER of its right to object to such extension of the DELIVERY DATE. Failure of the BUILDER to give notice of any relevant delay event in accordance with this paragraph 2 shall be deemed a waiver of the BUILDER’s right to postpone the DELIVERY DATE under this Article VIII in respect of such relevant delay event.
NOTICE OF DELAYS. Within two (2) weeks from the date of commencement of any delay on account of which the BUILDER claims that it is entitled under this CONTRACT to an extension of the DELIVERY DATE of the VESSEL, excluding delays due to arbitration, the BUILDER shall advise the BUYER by email or facsimile of the date such delay commenced, the reasons thereof and, if possible, its estimated duration of the probable delay in the delivery of the VESSEL, and shall supply the BUYER if reasonably available with evidence to justify the delay claimed. Failure of the BUILDER to issue a notification and/or claim for an extension of the DELIVERY DATE within two (2) weeks as aforesaid, shall be deemed to be a waiver by the BUILDER of its right to seek such extension. Within one (1) week after such delay ends, the BUILDER shall likewise advise the BUYER by email or facsimile of the date that such delay ended, and also, shall specify the period of time by which the BUILDER claims the DELIVERY DATE should be extended by reason of such delay. Failure of the BUYER to object to the BUILDER's notification of any claim for extension of the DELIVERY DATE within one (1) week after receipt by the BUYER of such notification shall be deemed to be a waiver by the BUYER of its right to object to such extension.
NOTICE OF DELAYS. Except as otherwise provided herein, when either party to this Contract has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this Contract, that party shall, within three (3) working days, give a written notice thereof, including all relevant information with respect thereto, to the other party.
NOTICE OF DELAYS. Except as otherwise provided under this Agreement, when either party has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this Agreement, that party shall, within one
NOTICE OF DELAYS. When either Party has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of any provisions of this Grant Agreement, that Party shall, within three (3) business days, give written notice, including relevant information, to the other Party.
