Cost Overruns In the event that the costs and expenses incurred by Borrower in completing any work which is the subject of this Agreement exceed the respective amounts allocated by Lender for such items of expense, Borrower shall be responsible for the payment (from sources other than the Property Reserves) of such excess costs and expenses.
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shal] submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the genera] conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over- Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (1), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease. 4.2.2
Project Costs The Project costs are true and accurate estimates of the costs necessary to complete the Improvements in a good and workmanlike manner according to the Plans and Specifications presented by Borrower to Lender, and Borrower shall take all steps necessary to prevent the actual cost of the Improvements from exceeding the Project costs.
Increased cost claims (a) A Finance Party intending to make a claim pursuant to Clause 14.1 (Increased costs) shall notify the Facility Agent of the event giving rise to the claim, following which the Facility Agent shall promptly notify the Company.
Approved Budget The Manager shall use its commercially reasonable efforts to prepare and deliver to the Company a revised budget that has been approved by the Board of Directors (the “Approved Budget”) by December 31 of the preceding Fiscal Year. However, the Company acknowledges that the Approved Budget is only an estimate of the performance of the Vessels and the Manager makes no assurance, representation or warranty that the actual performance of the Vessels in the applicable Fiscal Year will correspond to the estimates contained in the Approved Budget for such Fiscal Year. The Parties acknowledge that any projections contained in the Approved Budget are subject to and may be affected by changes in financial, economic and other conditions and circumstances beyond the control of the Parties.
Direct Costs Insert the major cost elements. For each element, consider the application of the paragraph entitled “Costs Requiring Prior Approval” on page 1 of these instructions.
Projected Operating Budget Furnish Agent and Lenders, no later than February 15 of each Borrower’s fiscal years commencing with fiscal year 2021, a month by month and annual projected operating budget and cash flow of Borrowers on a Consolidated Basis for such fiscal year (including an income statement for each month and a balance sheet as at the end of the last month in each fiscal quarter), such projections to be accompanied by a certificate signed by the Chief Financial Officer or Vice President of Finance of each Borrower to the effect that such projections have been prepared on the basis of sound financial planning practice consistent with past budgets and financial statements and that such officer has no reason to question the reasonableness of any material assumptions on which such projections were prepared.
Attorneys’ Fees and Cost of Collection In the event any suit, action or arbitration is filed by either party against the other to interpret or enforce any of the Transaction Documents, the unsuccessful party to such action agrees to pay to the prevailing party all costs and expenses, including attorneys’ fees incurred therein, including the same with respect to an appeal. The “prevailing party” shall be the party in whose favor a judgment is entered, regardless of whether judgment is entered on all claims asserted by such party and regardless of the amount of the judgment; or where, due to the assertion of counterclaims, judgments are entered in favor of and against both parties, then the arbitrator shall determine the “prevailing party” by taking into account the relative dollar amounts of the judgments or, if the judgments involve nonmonetary relief, the relative importance and value of such relief. Nothing herein shall restrict or impair an arbitrator’s or a court’s power to award fees and expenses for frivolous or bad faith pleading. If (i) the Note is placed in the hands of an attorney for collection or enforcement prior to commencing arbitration or legal proceedings, or is collected or enforced through any arbitration or legal proceeding, or Investor otherwise takes action to collect amounts due under the Note or to enforce the provisions of the Note, or (ii) there occurs any bankruptcy, reorganization, receivership of Company or other proceedings affecting Company’s creditors’ rights and involving a claim under the Note; then Company shall pay the costs incurred by Investor for such collection, enforcement or action or in connection with such bankruptcy, reorganization, receivership or other proceeding, including, without limitation, attorneys’ fees, expenses, deposition costs, and disbursements.
Annual Budget (a) The Company and its Subsidiaries shall be operated in accordance with an annual budget, as it may be annually updated from time to time pursuant to this Section 3 (the “Annual Budget”). The initial Annual Budget for the period beginning on the Effective Date and ending on December 31, 2018, including the related variances, is attached hereto as Schedule B-1 (the “Initial Annual Budget”). For each Fiscal Year thereafter, the Asset Manager shall be responsible for preparing and submitting to the Company Board for approval as a Major Decision in accordance with the terms of the Company LLC Agreement a proposed updated Annual Budget, including the related variances. The Annual Budget shall be prepared by the Asset Manager in accordance with the protocols (including the preparation of the back-up materials on the timetable set forth therein) set forth on Schedule B-2 hereto (the “Budget Development Protocols”). The Annual Budget for each Fiscal Year shall be prepared with the same detail and line items as set forth in the Initial Annual Budget and such other detail as the members of the Company Board appointed by the Preferred Partners in accordance with Section 4.3(c) of the Parent LP Agreement (the “Preferred Board Members”) may reasonably request. In connection with the review of a proposed Annual Budget, the Preferred Board Members may reasonably request additional information regarding the materials supporting the proposed Annual Budget or such other information as is necessary or desirable to enable review of such proposed Annual Budget, and the Asset Manager shall provide such requested information. The Preferred Board Members shall consent to or reject the proposed Annual Budget, or request additional information (as provided for above), within ten (10) Business Days following (i) receipt of such proposed Annual Budget or (ii) receipt of all additional information that is, in the determination of the Preferred Board Members, necessary or desirable to enable review of such proposed Annual Budget. The Asset Manager shall comply with the Budget Development Protocols regarding the Preliminary Budget for each Fiscal Year. The Annual Budget shall be prepared and submitted annually by the Asset Manager no later than December 10, 2018 for the next Fiscal Year and thereafter by December 10 of each year with respect to the following Fiscal Year. The Annual Budget for each Fiscal Year shall include use of the pre-funded reserve amounts as shown on Schedule B-3 hereto for the four Fiscal Quarters comprising such Fiscal Year. In connection with the submission of the Annual Budget, the Asset Manager shall also prepare and submit to the Company Board an annual business plan for Parent and its Subsidiaries, including a responsible five-year operations forecast, including the operating metrics set forth on Schedule B-4 hereto (the “Annual Plan”). The Preferred Board Members, or their designated representatives, shall be provided reasonable access to all information, data, reports, models and analyses relied on in developing the Annual Plan (including, for the avoidance of doubt, all financial and silvicultural assumptions, constraints, supporting stand level data, merchantable timber volumes, pre-merchantable acres by species and age class, and acres by land classification).
Variances From Operating Budget Furnish Agent, concurrently with the delivery of the financial statements referred to in Section 9.7 and each monthly report, a written report summarizing all material variances from budgets submitted by Borrowers pursuant to Section 9.12 and a discussion and analysis by management with respect to such variances.
