Condemnation or Casualty Seller agrees to give Purchaser prompt written notice of any fire or other casualty occurring to all or any portion of the improvements at the Real Property and/or Personalty between the date hereof and the date of closing. If prior to the closing, there shall occur: (i) damage to the improvements at the Property caused by fire or other casualty which would cost 5% of the Purchase Price of the Property or more to repair based on the estimate of a reputable third party contractor chosen by Seller; or (ii) the taking or condemnation of all or any portion of the Real Property and/or the improvements as aforesaid as would materially interfere with the use thereof; then, if any of such events set forth in (i) or (ii) above occurs, Buyer or Seller, at its option, may terminate its obligations under this Agreement by written notice given to the other within seven (7) days after Buyer has received the notice referred to above or at the closing, whichever is earlier. If Buyer or Seller does not elect to terminate its obligations as aforesaid, the closing shall take place as provided herein without an abatement of the purchase price (except that Buyer shall be allowed a credit for any deductible under Seller's insurance) and there shall be assigned to the Buyer at closing, all interest of the Seller in and to any insurance proceeds or condemnation awards which may be payable to Seller on account of such occurrence. If, prior to the closing, there shall occur: (i) damage to the Property caused by fire or other casualty which would cost less than 5% of the Purchase Price of the Property based on the estimate of a reputable third party contractor chosen by Seller to which Buyer has no reasonable objection; or (ii) the taking or condemnation of all or any portion of the said Real Property and/or improvements as aforesaid which is not material to the use, thereof; then, if any of such events set forth in (i) or (ii) above occurs, Buyer shall have no right to terminate its obligations under this Agreement, but there shall be assigned to Buyer at closing all interest of Seller in and to any insurance proceeds or condemnation awards which may be payable to Seller on account of any such occurrence, and in addition, Buyer shall be allowed a credit for any deductible under Seller's insurance policy. Seller shall be responsible for maintaining fire and extended coverage insurance prior to closing as is currently in place.
Notice of Casualty Tenant shall give Landlord notice in case of a fire or accident in the Premises promptly after Tenant is aware of such event.
FIRE OR CASUALTY Tenant shall give immediate notice to Landlord in case of fire or accident or other damage or defects in or to the Apartment or the building and to any of the fixtures or equipment therein. If the Apartment or the building shall be partially damaged by fire, the damages shall be repaired by and at the expense of Landlord as soon as it can reasonably be done under the circumstances, due allowance to be taken into consideration for any delays which may arise by reason of labor troubles, inability to obtain labor or materials, Governmental orders, regulations and restrictions, delays in adjusting the insurance loss or other cause beyond Landlord’s reasonable control. If the Apartment or the building shall be damaged from such causes or from any of them to such an extent that the same cannot be repaired with reasonable diligence within a period of sixty days or if Landlord shall decide not to repair or rebuild the same or if Landlord shall decide to demolish the building or to convert it to other uses then and in any such event, Landlord may within sixty days after such damage occurs give Tenant notice of such decision and thereupon the term of the Lease shall expire upon the third day after such notice is given, and Tenant shall thereupon vacate and surrender the Apartment to Landlord forthwith, and in such case, the rent shall be paid up to and apportioned as of the date on which Tenant shall vacate and surrender the demised premises. In the event the Apartment is damaged to such an extent that it is untenantable in whole or in part, rent shall be paid up to time of such damage and shall thereafter xxxxx in proportion to the part of the Apartment which may not be usable until such time as the premises shall have been put into repair. If the Apartment or the building shall be damaged or destroyed by fire or other cause resulting from any negligent act or omission or breach of any provision of this Lease by Tenant, Tenant shall nevertheless be liable to Landlord for any damage sustained by Landlord as a result thereof and the making of any necessary repairs or rebuilding by Landlord shall not constitute a waiver of the claims of Landlord, or of its insurer by subrogation, against Tenant for such damages. Landlord and Xxxxxx agree that the agreement contained in this paragraph is an agreement made in place of the provisions of Section 227 of the Real Property Law of New York.
No Casualty No Loan Party has received any notice of, nor does any Loan Party have any knowledge of, the occurrence or pendency or contemplation of any Casualty Event affecting all or any material portion of its property.
DAMAGE OR DESTRUCTION OF PREMISES a. In the event the Premises are damaged by fire or other perils or casualty covered by fire and extended coverage insurance, Landlord may, in its sole and absolute discretion, repair or rebuild the same within a reasonable time after the event causing such damage. This Lease shall remain in full force and effect, except that Tenant shall be entitled to a proportionate reduction of the rent from the date of damage and while such repairs are being made, such proportionate reduction to be based upon the extent to which the damage and making of such repairs shall reasonably interfere with the business carried on by Tenant in the Premises as determined by Landlord. If the damage is due to the fault or neglect of Tenant or its employees, as determined by Landlord in its sole discretion, there shall be no reduction of rent. Landlord may authorize or direct construction of an alternative structure or may elect to retain any insurance proceeds received by it if Landlord deems reconstruction or construction of an alternative structure to be impractical or unreasonable in its sole discretion. b. In the event the Premises are damaged to any extent as a result of any cause other than the perils covered by fire and extended coverage insurance, Landlord shall in its sole discretion have the option to: (1.) to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage, in which case this Lease shall continue in full force and effect, but the rent shall be proportionately reduced as provided above in 11a. during the period of such repair, reconstruction or restoration, or (2.) to give notice to Tenant at any time within sixty (60) days after such damage occurs, terminating this Lease as of the date specified in such notice, which date shall be no more than thirty (30) days after the giving of such notice. In the event of giving to Tenant such notice of termination, this Lease shall terminate and all interests of Tenant in the Premises shall cease on the date so specified in such notice and Tenant shall pay the rent, as proportionately reduced, based upon the extent, if any, to which such damage interfered with the business carried on by Tenant in the Premises, up to the date of such termination. c. With regard to Landlord’s duty or option to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage as provided in 11a. and b. above, Landlord shall act promptly and with due diligence, but Landlord shall not be responsible for delays caused by factors beyond Landlord’s control, including but not limited to delays because of strikes, work slowdowns or stoppages, accidents, acts of God, failure of any governmental or other authority to act in a timely manner, or delays caused by contractors. If such delays occur, Tenant agrees that Landlord shall not be responsible for damages, nor shall Landlord be deemed to be in default under this Lease. d. Landlord shall not be required to repair any damage by fire or other casualty, or to make any repair or replacements of any leasehold improvements, fixtures, or other personal property of Tenant.
Loss or Destruction Upon receipt of evidence satisfactory to the Company of the loss, theft, destruction, or mutilation of this Warrant Certificate and, in the case of any such loss, theft or destruction, upon delivery of an indemnity agreement or bond satisfactory in form, substance and amount to the Company or, in the case of any such mutilation, upon surrender and cancellation of this Warrant Certificate, the Company at its expense will execute and deliver, in lieu thereof, a new Warrant Certificate of like tenor.
Damage or Destruction Condemnation (a) In the event of partial damage or destruction of the Property of a type which can, under the circumstances, be expected in the reasonable judgment of Seller and Buyer to be restored or repaired at a cost of $500,000 or less, then, this Contract shall be consummated on the Closing Date at the Purchase Price, and unless such damage has been repaired by Seller prior to Closing, Seller shall assign to Buyer the casualty insurance proceeds payable to Seller and business interruption proceeds applicable to the period on and after the Closing Date payable to Seller (but only to the extent such business interruption proceeds are assignable to Buyer), less any amounts expended by Seller for partial restoration and with a credit to Buyer for the amount of any deductible and/or uninsured damage. (b) In the event that the Property shall have been damaged by fire or casualty, the cost of repair or restoration of which would, in the reasonable judgment of Seller and Buyer, exceed the sum of $500,000, then unless Seller has previously repaired or restored the Property to its former condition, at Buyer’s election, Seller shall either (i) pay over or assign to Buyer, on delivery of the Deed all casualty insurance proceeds payable to Seller and business interruption proceeds applicable to the period on and after the Closing Date payable to Seller (but only to the extent such business interruption proceeds are assignable to Buyer), less any amounts reasonably expended by Seller for partial restoration, with a credit to Buyer for the amount of any deductible and/or uninsured damage, or (ii) direct Escrow Agent to return the Deposit to Buyer in which case, except for the Surviving Obligation, all other obligations of the parties hereto shall cease and this Contract shall terminate and be without further recourse or remedy to the parties hereto. Notwithstanding the foregoing, if Buyer elects to proceed with the transaction under clause (i) of this paragraph (b), in no event shall Seller be obligated to incur any out of pocket cost above $500,000 (whether attributable to a casualty being uninsured, underinsured or to any deductible). (c) If all or part of the Property is taken by condemnation, eminent domain or by agreement in lieu thereof, or any proceeding to acquire, take or condemn all or part of the Property is threatened or commenced, Buyer may either terminate this Contract (in which event Buyer shall be entitled to a return of the Deposit and accrued interest thereon, if any, and, except for the Surviving Obligations, all other obligations of the parties hereto shall cease and this Contract shall terminate and be without further recourse or remedy to the parties hereto) or close title to the Property in accordance with the terms hereof, without reduction in the Purchase Price, together with an assignment of Seller's rights to any award paid or payable by or on behalf of the condemning authority. If Seller has received payments from the condemning authority and if Buyer elects to close title to the Property, Seller shall credit the amount of said payment against the Purchase Price at the Closing.
Damage, Destruction or Condemnation (a) In the event of damage to or destruction of any portion of the Project resulting from fire or other casualty during the Term, or in the event any portion of the District is condemned or taken for any public or quasi-public use or title thereto is found to be deficient during the Term, the net proceeds of any insurance relating to such damage or destruction, the net proceeds of such condemnation or taking or the net proceeds of any realization on title insurance shall be paid into, and used in accordance with a construction escrow agreement reasonably satisfactory to the City and Developer ("Casualty Escrow"). (b) If, at any time during the Term, the Project or any part thereof shall be damaged or destroyed by a casualty (the "Damaged Facilities"), Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the Damaged Facilities as nearly as possible to their condition immediately prior to the casualty and shall be entitled to draw upon the Casualty Escrow for payment of said costs. (c) If at any time during the Term, title to the whole or substantially all of the Project which has previously been conveyed to Developer shall be taken in condemnation proceedings or by right of eminent domain, Developer, at its sole discretion, may terminate this Agreement as of the date of such taking. For purposes of this Section 6.07(c), "substantially all of the District" shall be deemed to have been taken if the City and Developer, each acting reasonably and in good faith, determine that the untaken portion of the District, including the parking improvements, cannot be practically and economically used by Developer for the purposes and at the times contemplated by this Agreement. (d) In the event of condemnation of less than the whole or substantially all of the District which has previously been conveyed to Developer during the Term, Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the remaining part of the Project, as nearly as possible, to its former condition, and shall be entitled to draw upon the Casualty Escrow for payment of said costs. (e) Nothing in this section will require the Developer to expend funds in excess of the Casualty Escrow for the repair, restoration and/or replacement of the Damaged Facilities.
Insurance; Damage to or Destruction of Collateral (a) The Credit Parties shall, at their sole cost and expense, maintain the policies of insurance described on Disclosure Schedule 3.18 as in effect on the date hereof or otherwise in form and amounts and with deductibles as is customary for similarly situated businesses and with insurers reasonably acceptable to Agent. Agent and the Lenders confirm that the form, amounts and insurers described on Disclosure Schedule 3.18 are acceptable as of the Closing Date, and shall continue to be acceptable to Agent until not less than 30 days' prior written notice by Agent to Borrower to the contrary. Such policies of insurance (or the loss payable and additional insured endorsements delivered to Agent) shall contain provisions pursuant to which the insurer agrees to provide 30 days prior written notice to Agent in the event of any non-renewal, cancellation or amendment of any such insurance policy. If any Credit Party at any time or times hereafter shall fail to obtain or maintain any of the policies of insurance required above, or to pay all premiums relating thereto, Agent may at any time or times thereafter obtain and maintain such policies of insurance and pay such premiums and take any other action with respect thereto that Agent deems advisable. Agent shall have no obligation to obtain insurance for any Credit Party or pay any premiums therefor. By doing so, Agent shall not be deemed to have waived any Default or Event of Default arising from any Credit Party's failure to maintain such insurance or pay any premiums therefor. All sums so disbursed, including reasonable attorneys' fees, court costs and other charges related thereto, shall be payable on demand by Borrower to Agent and shall be additional Obligations hereunder secured by the Collateral. (b) Agent reserves the right at any time (but not to be exercised more than once per Fiscal Year) upon (i) any material change in any Credit Party's risk profile (including any change in the product mix maintained by any Credit Party or any laws affecting the potential liability of such Credit Party), as determined by Agent in its commercially reasonable judgment, and (ii) not less than 30 days' prior written notice to Borrower, to require additional forms and limits of insurance to, in Agent's commercially reasonable judgment, adequately protect both Agent's and Lender's interests in all or any portion of the Collateral and to ensure that each Credit Party is protected by insurance in amounts and with coverage customary for its industry. If reasonably requested by Agent, each Credit Party shall deliver to Agent from time to time a report of a reputable insurance broker, reasonably satisfactory to Agent, with respect to its insurance policies. (c) Each Credit Party shall deliver to Agent, in form and substance reasonably satisfactory to Agent, endorsements to (i) all "All Risk" and business interruption insurance naming Agent, on behalf of itself and Lenders, as lender loss payee or mortgagee (as the case may be), and (ii) all general liability and other liability policies naming Agent, on behalf of itself and Lenders, as additional insured. Each Credit Party irrevocably makes, constitutes and appoints Agent (and all officers, employees or agents designated by Agent), so long as any Event of Default has occurred and is continuing or the anticipated insurance proceeds exceed $1,000,000, as such Credit Party's true and lawful agent and attorney-in-fact for the purpose of making, settling and adjusting claims under such "All Risk" policies of insurance, endorsing the name of such Credit Party on any check or other item of payment for the proceeds of such "All Risk" policies of insurance and for making all determinations and decisions with respect to such "All Risk" policies of insurance. Agent shall have no duty to exercise any rights or powers granted to it pursuant to the foregoing power-of-attorney. Borrower shall promptly notify Agent of any loss, damage, or destruction to the Collateral in (i) Borrower shall request a Revolving Credit Advance be made to Borrower in the amount requested to be released; (ii) so long as the conditions set forth in Section 2.2 have been met, Lenders shall make such Revolving Credit Advance; and (iii) in the case of insurance proceeds applied against the Revolving Loan, the Reserve established with respect to such insurance proceeds shall be reduced by the amount of such Revolving Credit Advance. To the extent not used to replace, repair, restore or rebuild the Collateral, such insurance proceeds shall be applied in accordance with Section 1.3(c).
Condemnation/Eminent Domain In the event that the Premises or any part thereof, or the whole or any part of the Building, shall be taken or appropriated by eminent domain or shall be condemned for any public or quasi-public use, or (by virtue of any such taking, appropriation or condemnation) shall suffer any damage (direct, indirect or consequential) for which Landlord or Tenant shall be entitled to compensation, then (and in any such event) this Lease and the Term hereof may be terminated at the election of Landlord by a notice in writing of its election so to terminate which shall be given by Landlord to Tenant within sixty (60) days following the date on which Landlord shall have received notice of such taking, appropriation or condemnation. In the event that a material part of the Premises or the means of access thereto shall be so taken, appropriated or condemned, and in either case, the remainder of the Premises or the mode of access thereto is, in Tenant’s reasonable judgment, unsuitable for the operation of Tenant’s business in the Premises, then (and in any such event) this Lease and the Term hereof may be terminated at the election of Tenant by a notice in writing of its election so to terminate which shall be given by Tenant to Landlord within sixty (60) days following the date on which Tenant shall have received notice of such taking, appropriation or condemnation. Upon the giving of any such notice of termination (either by Landlord or Tenant) this Lease and the Term hereof shall terminate on or retroactively as of the date on which Tenant shall be required to vacate any part of the Premises or shall be deprived of a substantial part of the means of access thereto, provided, however, that Landlord may in Landlord’s notice elect to terminate this Lease and the Term hereof retroactively as of the date on which such taking, appropriation or condemnation became legally effective. In the event of any such termination, this Lease and the Term hereof shall expire as of such effective termination date as though that were the Expiration Date as stated in Exhibit 1, and the Yearly Rent (together with Operating Costs Excess and Tax Excess) shall be apportioned as of such date. If neither party (having the right so to do) elects to terminate Landlord will, with reasonable diligence and at Landlord’s expense, restore the remainder of the Premises, or the remainder of the means of access, as nearly as practicably may be to the same condition as obtained prior to such taking, appropriation or condemnation in which event (i) the Total Rentable Area shall be equitably adjusted, (ii) a just proportion of the Yearly Rent, according to the nature and extent of the taking, appropriation or condemnation and the resulting permanent injury to the Premises and the means of access thereto, shall be permanently abated, and (iii) a just proportion of the remainder of the Yearly Rent, according to the nature and extent of the taking, appropriation or condemnation and the resultant injury sustained by the Premises and the means of access thereto, shall be abated until what remains of the Premises and the means of access thereto shall have been restored as fully as may be for permanent use and occupation by Tenant hereunder. Except for any award specifically reimbursing Tenant for moving or relocation expenses or for Tenant’s personal property, or for the unamortized value of any leasehold improvements paid for by Tenant (in excess of any Landlord contribution), there are expressly reserved to Landlord all rights to compensation and damages created, accrued or accruing by reason of any such taking, appropriation or condemnation, in implementation and in confirmation of which Tenant does hereby acknowledge that Landlord shall be entitled to receive all such compensation and damages, grant to Landlord all and whatever rights (if any) Tenant may have to such compensation and damages, and agree to execute and deliver all and whatever further instruments of assignment as Landlord may from time to time reasonably request. In the event of any taking of the Premises or any part thereof for temporary (i.e., not in excess of one (1) year) use, (i) this Lease shall be and remain unaffected thereby, and (ii) Tenant shall be entitled to receive for itself any award made to the extent allocable to the Premises in respect of such taking on account of such use, provided, that if any taking is for a period extending beyond the Term of this Lease, such award shall be apportioned between Landlord and Tenant as of the Expiration Date or earlier termination of this Lease.