Time of the Essence Time is of the essence of this Agreement.
Time of the Essence; Computation of Time Time is of the essence for each and every provision of this Agreement. Whenever the last day for the exercise of any privilege or the discharge or any duty hereunder shall fall upon a Saturday, Sunday, or any date on which banks in New York, New York are authorized to be closed, the party having such privilege or duty may exercise such privilege or discharge such duty on the next succeeding day which is a regular business day.
Time of the Essence in This Tenant Work Letter Unless otherwise indicated, all references herein to a “number of days” shall mean and refer to calendar days. If any item requiring approval is timely disapproved by Landlord, the procedure for preparation of the document and approval thereof shall be repeated until the document is approved by Landlord.
Time of Essence Time is of the essence of this Agreement.
Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely: (a) delay in providing the Right of Way of Construction Zone, environmental clearances or approval of railway authorities, specified in Clause 3.1 (iv); (b) Change of Scope (unless an adjustment to the Scheduled Completion Date has been agreed under Article 13); (c) occurrence of a Force Majeure Event; (d) any delay, impediment or prevention caused by or attributable to the Authority, the Authority's personnel or the Authority's other contractors on the Site; and (e) any other cause or delay which entitles the Contractor to Time Extension in accordance with the provisions of this Agreement. (ii) The Contractor shall, no later than 15 (fifteen) business days from the occurrence of an event or circumstance specified in Clause 10.5 (i), inform the Authority’s Engineer by notice in writing, with a copy to the Authority, stating in reasonable detail with supporting particulars, the event or circumstances giving rise to the claim for Time Extension in accordance with the provisions of this Agreement. Provided that the period of 15 (fifteen) business days shall be calculated from the date on which the Contractor became aware, or should have become aware, of the occurrence of such an event or circumstance. Provided further that notwithstanding anything to the contrary contained in this Agreement, Time Extension shall be due and applicable only for the Works which are affected by the aforesaid events or circumstances and shall not in any manner affect the Project Completion Schedule for and in respect of the Works which are not affected hereunder. (iii) On the failure of the Contractor to issue to the Authority’s Engineer a notice in accordance with the provisions of Clause 10.5 (ii) within the time specified therein, the Contractor shall not be entitled to any Time Extension and shall forfeit its right for any such claims in future. For the avoidance of doubt, in the event of failure of the Contractor to issue notice as specified in this clause 10.5 (iii), the Authority shall be discharged from all liability in connection with the claim. (iv) The Authority’s Engineer shall, on receipt of the claim in accordance with the provisions of Clause 10.5 (ii), examine the claim expeditiously within the time frame specified herein. In the event the Authority’s Engineer requires any clarifications to examine the claim, the Authority’s Engineer shall seek the same within 15 (fifteen) days from the date of receiving the claim. The Contractor shall, on receipt of the communication of the Authority’s Engineer requesting for clarification, furnish the same to the Authority’s Engineer within 10 (ten) days thereof. The Authority’s Engineer shall, within a period of 30 (thirty) days from the date of receipt of such clarifications, forward in writing to the Contractor its determination of Time Extension. Provided that when determining each extension of time under this Clause 10.5, the Authority’s Engineer shall review previous determinations and may increase, but shall not decrease, the total Time Extension. (v) If the event or circumstance giving rise to the notice has a continuing effect: (a) a fully detailed claim shall be considered as interim; (b) the Contractor shall, no later than 10 (ten) days after the close of each month, send further interim claims specifying the accumulated delay, the extension of time claimed, and such further particulars as the Authority’s Engineer may reasonably require; and (c) the Contractor shall send a final claim within 30 (thirty) days after the effect of the event or the circumstance ceases. Upon receipt of the claim hereunder, the Authority’s Engineer shall examine the same in accordance with the provisions of Clause 10.5 (iv) within a period of 30 (thirty) days of the receipt thereof
Extension of Time; Waiver At any time prior to the Effective Time, the parties may, by action taken or authorized by their respective Boards of Directors, to the extent permitted by applicable Law, (a) extend the time for the performance of any of the obligations or acts of the other parties, (b) waive any inaccuracies in the representations and warranties of the other parties set forth in this Agreement or any document delivered pursuant hereto or (c) subject to applicable Law, waive compliance with any of the agreements or conditions of the other parties contained herein; provided, however, that after the Company Stockholder Approval has been obtained, no waiver may be made that pursuant to applicable Law requires further approval or adoption by the Stockholders without such further approval or adoption. Any agreement on the part of a party to any such waiver shall be valid only if set forth in a written instrument executed and delivered by a duly authorized officer on behalf of such party. No failure or delay of any party in exercising any right or remedy hereunder shall operate as a waiver thereof, nor shall any single or partial exercise of any such right or power, or any abandonment or discontinuance of steps to enforce such right or power, or any course of conduct, preclude any other or further exercise thereof or the exercise of any other right or power. The rights and remedies of the parties hereunder are cumulative and are not exclusive of any rights or remedies which they would otherwise have hereunder.
Conditions Precedent to the Effectiveness of this Amendment This Amendment shall become effective as of the date first written above when, and only when, each of the following conditions precedent shall have been satisfied or waived (the “Amendment No. 1 Effective Date”) by the Administrative Agent:
Conditions Precedent/Effectiveness Conditions This Amendment shall be effective upon the date of satisfaction of all of the following conditions precedent (the “Effective Date”): (a) Agent shall have received this Amendment fully executed by the Borrowers; (b) Agent shall have received updated schedule to the Loan Agreement, if any; (c) Agent shall have received a Guaranty, fully executed by the New Guarantor; (d) Agent shall have received a Pledge Agreement, fully executed by the New Guarantor; (e) Agent shall have received a copy of the Asset Transfer Agreement; (f) Agent shall have received a copy of the resolutions in form and substance reasonably satisfactory to Agent, of the board of directors or managers of New Guarantor, authorizing the execution, delivery and performance of this Amendment, the Guaranty, and any related agreements, instruments, or documents to which New Guarantor is a party, certified by the Secretary or an Assistant Secretary of New Guarantor; (g) Agent shall have received a certificate of the Secretary or an Assistant Secretary of New Guarantor as to the incumbency and signature of the officers of New Guarantor executing this Amendment the Guaranty, and any related agreements, instruments, or documents to which New Guarantor is a party, together with evidence of the incumbency of such Secretary or Assistant Secretary; (h) Agent shall have received an incumbency certificate for each Borrower identifying all authorized officers with specimen signatures, certified by the Secretary of such Borrower; (i) Agent shall have received copies of the bylaws and memorandum of association of New Guarantor, together with a certificate of good standing or equivalent certification in the jurisdiction of formation of New Guarantor; (j) Agent shall have received the results of UCC, tax lien, and judgment searches against New Guarantor; (k) Agent shall have received an opinion of counsel of New Guarantor; (l) Agent shall have received updated certificates of insurance naming New Guarantor as an additional insured with respect to liability insurance and lender loss payee with respect to property insurance; (m) Agent shall have received reasonably satisfactory evidence that the Guarantor Restructuring shall be consummated; and (n) No Default or Event of Default shall have occurred and be continuing under the Loan Agreement.
TIME OF COMMENCEMENT AND COMPLETION 2.1 The Contractor shall commence the Work upon the date established in the Notice to Proceed. 2.2 The Contractor shall achieve Final Completion, as defined in Section 105.01, Contract Time, Notice of Contract Execution and Notice to Proceed of the Loudoun County Revisions to the 0000 XXXX Xxxx & Bridge Specifications, Division I - General Provisions, within one hundred and eighty (180) calendar days from the date specified in the Notice to Proceed. This time period shall be designated the Contract Time. The Notice to proceed will be issued approximately than thirty (30) days after the execution of this agreement. The Contractor agrees that the time for completion of the Work as described in the Contract Documents shall govern unless specifically amended in writing by the County, and that no claims for early completion are allowed to be presented by the Contractor to the County. 2.3 The County specifies that time is of the essence under this Contract. Time being of the essence, it is essential to the County that Contract work will be completed within the Contract Time. The County and the Contractor agree that damages for failure to complete the work within the Contract Time are not susceptible to exact determination but that $600 per day is in proportion to the actual loss that the County would suffer from such delay. Therefore, the Contractor will pay the County on demand $600 per day for each and every day beyond the one hundred and eighty (180) calendar days, or modified date of completion, that the County determines that work is not complete, as damages caused by such delay and not as a penalty. The County shall be entitled to offset liquidated damages against any sum owed by the County to the Contractor under this Contract. 2.4 The amount of liquidated damages set forth in Articles 2.3 above shall be assessed cumulatively. This provision for liquidated damages does not bar County's right to enforce other rights and remedies against Contractor, which are otherwise legally enforceable, including but not limited to, specific performance or injunctive relief. 2.5 The Contractor hereby waives any defense as to the validity of any liquidated damages stated in this Agreement as they may appear on grounds that such liquidated damages are void as penalties or are not reasonably related to actual damages.
Failure to Complete If Artist becomes ill, dies, or is otherwise unable or unwilling to complete the Project in accordance with the Agreement, any work already done on the Project will be the City’s property. The City will be entitled to withhold any sums not yet paid to Artist, and may use any such sums toward completion of the Project in any manner the City deems appropriate.
