Obligations by CSCD Contractor Sample Clauses

Open Split View

Download

Share

Cite

Obligations by CSCD Contractor 

Sample 1

Save

Copy

Related to Obligations by CSCD Contractor

• Obligations of the Contractor (i) Subject to and on the terms and conditions of this Agreement, the Contractor shall undertake the survey, investigation, design, engineering, procurement, construction, and maintenance of the Project Highway and observe, fulfil, comply with and perform all its obligations set out in this Agreement or arising hereunder. (ii) The Contractor shall comply with all Applicable Laws and Applicable Permits (including renewals as required) in the performance of its obligations under this Agreement. (iii) Subject to the provisions of Clauses 4.1 (i) and 4.1 (ii), the Contractor shall discharge its obligations in accordance with Good Industry Practice and as a reasonable and prudent person. (iv) The Contractor shall remedy any and all loss, defects, or damage to the Project Highway from the Appointed Date until the end of the Construction Period at the Contractor’s cost, save and except to the extent that any such loss, defect, or damage shall have arisen from any wilful default or neglect of the Authority. (v) The Contractor shall remedy any and all loss, defect or damage to the Project Highway during the Defects Liability Period at the Contractor’s cost to the extent that such loss, defect or damage shall have arisen out of the reasons specified in Clause 17.3. (vi) The Contractor shall remedy any and all loss or damage to the Project Highway during the Maintenance Period at the Contractor’s cost, including those stated in Clause 14.1 (ii), save and except to the extent that any such loss or damage shall have arisen on account of any wilful default or neglect of the Authority or on account of a Force Majeure Event. (vii) The Contractor shall, at its own cost and expense, in addition to and not in derogation of its obligations elsewhere set out in this Agreement: (a) make, or cause to be made, necessary applications to the relevant Government Instrumentalities with such particulars and details as may be required for obtaining Applicable Permits set forth in Schedule-F and obtain and keep in force and effect such Applicable Permits in conformity with the Applicable Laws; (b) procure, as required, the appropriate proprietary rights, licences, agreements and permissions for Materials, methods, processes and systems used or incorporated into the Project Highway; (c) make reasonable efforts to maintain harmony and good industrial relations among the personnel employed byit or its Sub-contractors in connection with the performance of its obligations under this Agreement; (d) ensure and procure that its Sub-contractors comply with all Applicable Permits and Applicable Laws in the performance by them of any of the Contractor’s obligations under this Agreement; (e) not do or omit to do any act, deed or thing which may in any manner violate any provisions of this Agreement; (f) support, cooperate with and facilitate the Authority in the implementation and operation of the Project in accordance with the provisions of this Agreement; (g) ensure that the Contractor and its Sub-contractors comply with the safety and welfare measures for labour in accordance with the Applicable Laws and Good Industry Practice; (h) keep, on Site, a copy of this Agreement, publications named in this Agreement, the Drawings, Documents relating to the Project, and Change of Scope orders and other communications given under this Agreement. The Authority’s Engineer and its authorised personnel shall have the right of access to all these documents at all reasonable times; (i) cooperate with other contractors employed by the Authority and personnel of any public authority; and (j) not interfere unnecessarily or improperly with the convenience of the public, or the access to and use and occupation of all roads and footpaths, irrespective of whether they are public or in the possession of the Authority or of others. (viii) The Contractor shall undertake all necessary superintendence to plan, arrange, direct, manage, inspect and test the Works. The Contractor shall provide all necessary superintendence of the Works for the proper fulfilling of the Contractor's obligations under the Agreement. Such superintendence shall be given by competent person having adequate knowledge of the operations to be carried out (including the methods and techniques required, the hazards likely to be encountered and methods of preventing accidents) for the satisfactory and safe execution of the Works. (ix) The Contractor shall obtain and maintain a project related bank account operational at site where all transactions related to the payment of work will be done. The Contractor shall submit a monthly account statement and a detailed report on utilization of funds transferred to this project related bank account to Authority’s Engineer. Notwithstanding anything contrary to this agreement, the authority, in the interest and to ensure timely completion of the work, reserves the right to audit such bank accounts to ensure that there is no diversion of funds from this project specific account to any other project being implemented by the Contractor. (x) The Contractor shall provide the documents of the Contractor specified in the Agreement, and all Contractors' personnel; Goods, consumables and other things and services, whether of a temporary or permanent nature, required in and for the execution, completion of Works and remedying defects. (xi) The Contractor shall perform the Works in conformity with the Project requirements and other requirements and standards prescribed under or pursuant to the Agreement. (xii) The Contractor shall carry out such work incidental and contingent to the original Scope of the Project to comply with Good Industry Practices. (xiii) The Contractor shall maintain required staff and necessary Contractor’s equipment and materials within the reach of the Site during the Defects Liability Period so that any defects arising are promptly attended.

• Obligations of Contractor 5.01 CONTRACTOR agrees to perform all Services in accordance with the terms and conditions of this Agreement and the Proposal. In the event that the terms of the Proposal shall conflict with the terms of this Agreement or contain additional terms that purport to bind the CITY other than the Services to be rendered and the price for the Services, the terms of this Agreement shall govern and said additional or conflicting terms shall be of no force or effect. 5.02 Except as otherwise agreed by the parties, CONTRACTOR will supply all personnel, materials and equipment required to perform the Services. CONTRACTOR shall provide its own offices, telephones, vehicles and computers and set its own work hours. CONTRACTOR will determine the method, details, and means of performing the Services under this Agreement. 5.03 CONTRACTOR shall keep CITY informed as to the progress of the Services by means of regular and frequent consultations. Additionally, when requested by CITY, CONTRACTOR shall prepare written status reports. 5.04 CONTRACTOR is responsible for paying, when due, all income and other taxes, fees and withholding, including withholding state and federal taxes, social security, unemployment and worker’s compensation, incurred as a result of the compensation paid under this Agreement. XXXXXXXXXX agrees to indemnify, defend and hold harmless CITY for any claims, costs, losses, fees, penalties, interest, or damages suffered by CITY resulting from CONTRACTOR’s failure to comply with this provision. 5.05 In the event CONTRACTOR is required to prepare plans, drawings, specifications and/or estimates, the same shall be furnished in conformance with local, state and federal laws, rules and regulations. 5.06 CONTRACTOR represents that it possesses all required licenses necessary or applicable to the performance of Services under this Agreement and the Proposal and shall obtain and keep in full force and effect all permits and approvals required to perform the Services herein. In the event CITY is required to obtain an approval or permit from another governmental entity, CONTRACTOR shall provide all necessary supporting documents to be filed with such entity. 5.07 CONTRACTOR shall be solely responsible for obtaining Employment Eligibility Verification information from CONTRACTOR’s employees, in compliance with the Immigration Reform and Control Act of 1986, Pub. L. 99-603 (8 U.S.C. 1324a), and shall ensure that CONTRACTOR’s employees are eligible to work in the United States. 5.08 In the event that CONTRACTOR employs, contracts with, or otherwise utilizes any CalPERS retirees in completing any of the Services performed hereunder, such instances shall be disclosed in advance to the CITY and shall be subject to the CITY’s advance written approval. 5.09 Drug-free Workplace Certification. By signing this Agreement, the CONTRACTOR hereby certifies under penalty of perjury under the laws of the State of California that the CONTRACTOR will comply with the requirements of the Drug-Free Workplace Act of 1990 (Government Code, Section 8350 et seq.) and will provide a drug- free workplace. 5.10 CONTRACTOR shall comply with all applicable local, state and federal laws, rules, regulations, entitlements and/or permits applicable to, or governing the Services authorized hereunder.

• Claim by Contractor After receipt of the Notice of Termination from the state, the Contractor shall submit any claim for additional costs not covered herein or elsewhere in the Contract within 60 days of the effective termination date, and not thereafter. Should the Contractor fail to submit a claim within the 60-day period, the State may, at its sole discretion, based on information available to it, determine what, if any, compensation is due the Contractor and pay the Contractor the determined amount.

• Contractor Guaranties Contractor shall: (a) Perform fully under the Contract; (b) Guarantee the Goods or Services against defective material or workmanship and to repair any damage or marring occasioned in transit or, at the Client Agency's option, replace them; (c) Furnish adequate protection from damage for all work and to repair damage of any kind, for which its workers are responsible, to the premises, Goods, the Contractor’s work or that of Contractor Parties; (d) With respect to the provision of Services, pay for all permits, licenses and fees and give all required or appropriate notices; (e) Adhere to all Contractual provisions ensuring the confidentiality of Records that the Contractor has access to and are exempt from disclosure under the State’s Freedom of Information Act or other applicable law; and (f) Neither disclaim, exclude nor modify the implied warranties of fitness for a particular purpose or of merchantability.

• Obligations of Customer Axway’s indemnification obligation is contingent upon the Customer: (a) giving immediate written notice to Axway of any such Infringement Claim; (b) giving Axway control of the defense and related settlement negotiations, provided , however that Axway will obtain the Customer’s prior written consent, which shall not be unreasonably withheld or delayed, if any settlement of such an Infringement Claim requires Customer to admit liability, take or refrain from taking any particular action other than cessation of use of the infringing Services, Product, or Deliverable , and (c) assisting in the defense at Axway’s reasonable request, provided Axway agrees to pay Customer’s reasonable expenses in connection therewith. The Customer may participate in such defense and in any settlement discussions directly or through counsel of the Cus tomer’s choice, at the Customer’s expense, provided such participation does not materially prejudice Axway’s sole control of the defense or cause Axway to incur material additional costs in the conduct of such defense .

• Subcontract Costs Payments made by the Construction Manager to Subcontractors in accordance with the requirements of the subcontracts and this Agreement.

• Obligations of Licensee 2.1 Licensee is responsible for the quality and safety of its products. 2.2 Licensee shall use all reasonable efforts and diligence to exploit the Invention and to proceed with the development, manufacture and sale of Licensed Product and to use commercially reasonable efforts to develop markets for the Licensed Product. 2.3 Licensee will represent the Licensed Product fairly in comparison with competitive products from other suppliers. 2.4 Licensee shall not, on behalf of University, make any representations or give any warranties or guarantees in respect of the Proprietary IPR not expressly authorised in writing by University, provided that such authorization shall not be unreasonably delayed or withheld by University. 2.5 Licensee shall not market the Licensed Product under the name of University, and not in any way create any impression that University is the seller of the Licensed Product. 2.6 Licensee shall take all such steps as are reasonably necessary to protect Intellectual Property Rights in the Invention. 2.7 Licensee shall promptly inform University upon becoming aware of any illegal or unauthorised use of the Invention or any infringement of the Prospective Patent or Proprietary IPR and Intellectual Property Rights therein. 2.8 Licensee shall comply with all laws, regulations and governmental obligations that may from time to time be applicable to the making, use or sale of the Licensed Product in each part of the Territory. 2.9 As between Licensee and University and without limiting any responsibility of an Affiliate or Sub-Licensee, Licensee shall be solely responsible for any claims arising or alleged to arise from loss or injury to persons or property caused or suffered in the course of or as a consequence of the use of the Invention by Licensee, Affiliates and Sub-Licensees or the supply and sale of the Licensed Product by Licensee, Affiliates and Sub-Licensees except where such loss or injury are caused by the gross negligence or wilful misconduct of University. 2.10 Except as expressly set forth under this Agreement, Licensee shall use its best endeavours to keep the Invention confidential and not to reveal to any third party any confidential information of University regarding the Invention until after a non-disclosure agreement has been signed, provided that no such obligation shall apply to any information that has been publicly disclosed through no breach of this Agreement by Licensee, including by publication of the Inventions by the applicable governmental agency, was in the possession of Licensee prior to disclosure by University, is obtained by Licensee from a third party, or is independently developed by Licensee. 2.11 To the extent prohibited by applicable law, Licensee shall not carry out any illegal, deceptive, or unethical practices, whether or not they are to the disparagement of the Invention, Licensed Product or University, or, subject to the foregoing in this Section 2.11, any other practices which may be detrimental to the Invention, Licensed Product, University or to the public interest.

• Contractor Obligations After receipt of the Notice of Termination and except as otherwise directed by the State, the Contractor shall immediately proceed to: a. To the extent specified in the Notice of Termination, stop work under the Contract on the date specified. b. Place no further orders or subcontracts for materials, services, and/or facilities except as may be necessary for completion of such portion(s) of the work under the Contract as is (are) not terminated. c. Terminate and cancel any orders or subcontracts for related to the services, except as may be necessary for completion of such portion(s) of the work under the Contract as is (are) not terminated. d. Transfer to the State all completed or partially completed plans, drawings, information, and other property which, if the Contract had been completed, would be required to be furnished to the State. e. Take other action as may be necessary or as directed by the State for the protection and preservation of the property related to the contract which is in the possession of the contractor and in which the State has or may acquire any interest. f. Make available to the State all cost and other records relevant to a determination of an equitable settlement.

• Obligations of the Concessionaire 5.1.1 Subject to and on the terms and conditions of this Agreement, the Concessionaire shall, at its own cost and expense, procure finance for and undertake the design, engineering, procurement, construction, operation and maintenance of the Project and observe, fulfil, comply with and perform all its obligations set out in this Agreement or arising hereunder. 5.1.2 The Concessionaire shall comply with all Applicable Laws and Applicable Permits (including renewals as required) in the performance of its obligations under this Agreement. 5.1.3 Subject to the provisions of Clauses 5.1.1 and 5.1.2, the Concessionaire shall discharge its obligations in accordance with Good Industry Practice and as a reasonable and prudent person. 5.1.4 The Concessionaire shall, at its own cost and expense, in addition to and not in derogation of its obligations elsewhere set out in this Agreement carry out the following but not be limited to: (a) make, or cause to be made, necessary applications to the relevant Government Instrumentalities with such particulars and details as may be required for obtaining Applicable Permits (other than those set forth in Clause 4.1.3), and obtain and keep in force and effect such Applicable Permits in conformity with the Applicable Laws; (b) procure, as required, the appropriate proprietary rights, licences, agreements and permissions for materials, methods, processes and systems used or incorporated into the Project; (c) perform and fulfil its obligations under the Financing Agreements; (d) make reasonable efforts to maintain harmony and good industrial relations among the personnel employed by it or its Contractors in connection with the performance of its obligations under this Agreement; (e) make reasonable efforts to facilitate the acquisition of land required for the purposes of the Agreement; (f) ensure and procure that its Contractors comply with all Applicable Permits and Applicable Laws in the performance by them of any of the Concessionaire's obligations under this Agreement; (g) not do or omit to do any act, deed or thing which may in any manner be violative of any of the provisions of this Agreement; (h) support, cooperate with and facilitate the Authority in the implementation and operation of the Project in accordance with the provisions of this Agreement; (i) modify/demolish the existing structures on the Site at its own cost and consequences. The Concessionaire shall ensure that the demolition and construction of the existing structures is also in compliance with the prevailing building bye laws, zoning regulations as prescribed by H&UPD, GoUP, other appropriate authority or any regulatory authority (ASI, TTZ, NGT etc.). XXX policy of GoI and GoUP shall be admissible as and where applicable. The Concessionaire shall be responsible for safe and hassle-free disposal of the scrap from the Site; (j) (deleted) (k) transfer the Bus Terminal and the Commercial Complex to the Authority upon Termination of this Agreement, in accordance with the provisions thereof. (l) develop a centralized covered Bus Terminal with adequate number of bus bays along with RCC yard area, passenger movement spaces, furniture fixtures, electrical fittings, utilities and other related requirements; (m) {where Bus Terminal and workshops/ depots are adjoining, the development of workshops unit with necessary structural provisions and RCC yard, furniture fixtures, electrical fittings with minimum 6 meters of working/ maintenance shed height with no access from and/ to commercial areas as a mandatory requirement. However, Authority shall take separate electricity connection for the workshop area and shall pay for the electricity usage in it}1; (n) construct and maintain public amenities like ablution units etc.; (o) all the passenger amenities, Workshop facilities as well as UPSRTC staff facilities shall be maintained hygienic, neat and clean during the concession period; (p) accesses either through staircases, overbridges or underpasses for movement of pedestrians from one platform to the other in a safe and fully secured manner; (q) a dedicated office for UPSRTC staff with a sufficient usable area along with change rooms and toilets as per the specifications of UPSRTC shall be made available unconditionally and free of cost for the entire concession period on ground and first floors only of the Bus Terminal; (r) all the facilities for plumbing, internal electrification and all the other allied works to render the office functional (partitions excluded); (s) facility for parking adequate number of 4 wheelers, 3 Wheelers and 2 wheelers of passengers and commercial area users. The parking facility for Bus Terminal and for the Commercial Complex shall be segregated. (Refer prevailing Government of Housing and Urban Planning department circulars/ G.O’s); 1 This provision to be used only for Sites where workshops are adjoining the Bus Terminal (t) all the other allied facilities for fire protection, accesses in the form of ramps, protective railings, ventilation system etc.; (u) day to day operation and management of the Project as per this Agreement; and (v) bear the expenses of electricity and water in the Bus Terminal during the Concession Period of Bus Terminal, except electricity and water charges for Authority’s office, workshop, drivers or staff dormitory and electric bus charging which shall be borne by the Authority.

• Obligations of DOE a. In express reliance on the covenants and representations in this Compromise Agreement and to avoid further expenditure of public resources, XXX agrees to accept Respondent’s payment pursuant to section III.2.a in full satisfaction of the penalty authorized by the Act. x. XXX agrees to issue promptly an Adopting Order adopting this Agreement. x. XXX agrees to terminate this enforcement action with prejudice upon Respondent’s completion of its Obligations in accordance with section III.2, above. If Respondent fails to complete its Obligations in accordance with section III.2, above, DOE may notify Respondent that the Agreement is null and void and may seek the maximum penalty in accordance with 10 C.F.R. § 429.120.