Obligations of the Licensee 5.1.1. The Licensee’s Responsibilities and Duties shall include the following, in addition to and without prejudice to other obligations under this Agreement: a. to obtain due permits, necessary approvals, clearances and sanctions from Maha-Metro and all other competent authorities for all activities or infrastructure facilities including interior decoration, power, water supply, drainage & sewerage, telecommunication, etc.; b. to comply and observe at all times with all Applicable Permits, approvals and Applicable Laws in the performance of its obligations under this Agreement including those being performed by any of its contractors; c. to develop, operate and maintain the Licensed Area at all times in conformity with this Agreement; d. to furnish Maha-Metro with the “As built” Drawings of the Licensed Space(s) within the Moratorium Period; e. to ensure that no structural damage is caused to the existing buildings and other permanent structures at the station as a result of his activities or any of its agents, contractors etc.; f. to take all reasonable steps to protect the environment (both on and off the property business space) and to limit damage and nuisance to people and property resulting from construction and operations, within guidelines specified as per Applicable Laws and Applicable Permits; g. to duly supervise, monitor and control the activities of contractors, agents, etc., if any, under their respective License Agreements as may be necessary; h. to take all responsible precautions for the prevention of accidents on or about the property business space and provide all reasonable assistance and emergency medical aid to accident victims; i. not to permit any person, claiming through or under the Licensee, to create or place any encumbrance or security interest over whole or any part of the Licensed premises and/or other installed assets, or on any rights of the Licensee therein or under this Agreement, save and except as expressly permitted in this Agreement; j. to keep the Licensed Space free from all unnecessary obstruction during execution of works and store the equipment or surplus materials, dispose of such equipment or surplus materials in a manner that causes least inconvenience to the Xxxxx Xxxxxxx, metro commuters or Maha-Metro’s activities. k. at all times, to afford access to the Licensed Property Business Space to the authorised representatives of Maha-Metro, other persons duly authorised by any Governmental Agency having jurisdiction over the business of Licensed Property Business Space, to inspect the Licensed Property Business Space and to investigate any matter within their authority and upon reasonable notice; and l. use non-combustable material in the allotted space for creation/erection/installation of any kind of furniture, fixtures and or partitions within the space. Use of combustable material within the property business space shall not be permitted under any circumstances. m. to comply with the divestment requirements and hand over the Licensed Property Business Space to Maha-Metro upon Termination of the Agreement; 5.1.2. The Licensee shall be solely and primarily responsible to Maha-Metro for observance of all the provisions of this License Agreement on behalf of its employees and representatives and agents and any person acting under or for and on behalf of the Licensee, contractor (s) appointed for the Licensed Space as fully as if they were the acts or defaults of the Licensee, its agents or employees.
Obligations of the Contractor (i) Subject to and on the terms and conditions of this Agreement, the Contractor shall undertake the survey, investigation, design, engineering, procurement, construction, and maintenance of the Project Highway and observe, fulfil, comply with and perform all its obligations set out in this Agreement or arising hereunder. (ii) The Contractor shall comply with all Applicable Laws and Applicable Permits (including renewals as required) in the performance of its obligations under this Agreement. (iii) Subject to the provisions of Clauses 4.1 (i) and 4.1 (ii), the Contractor shall discharge its obligations in accordance with Good Industry Practice and as a reasonable and prudent person. (iv) The Contractor shall remedy any and all loss, defects, or damage to the Project Highway from the Appointed Date until the end of the Construction Period at the Contractor’s cost, save and except to the extent that any such loss, defect, or damage shall have arisen from any wilful default or neglect of the Authority. (v) The Contractor shall remedy any and all loss, defect or damage to the Project Highway during the Defects Liability Period at the Contractor’s cost to the extent that such loss, defect or damage shall have arisen out of the reasons specified in Clause 17.3. (vi) The Contractor shall remedy any and all loss or damage to the Project Highway during the Maintenance Period at the Contractor’s cost, including those stated in Clause 14.1 (ii), save and except to the extent that any such loss or damage shall have arisen on account of any wilful default or neglect of the Authority or on account of a Force Majeure Event. (vii) The Contractor shall, at its own cost and expense, in addition to and not in derogation of its obligations elsewhere set out in this Agreement: (a) make, or cause to be made, necessary applications to the relevant Government Instrumentalities with such particulars and details as may be required for obtaining Applicable Permits set forth in Schedule-F and obtain and keep in force and effect such Applicable Permits in conformity with the Applicable Laws; (b) procure, as required, the appropriate proprietary rights, licences, agreements and permissions for Materials, methods, processes and systems used or incorporated into the Project Highway; (c) make reasonable efforts to maintain harmony and good industrial relations among the personnel employed byit or its Sub-contractors in connection with the performance of its obligations under this Agreement; (d) ensure and procure that its Sub-contractors comply with all Applicable Permits and Applicable Laws in the performance by them of any of the Contractor’s obligations under this Agreement; (e) not do or omit to do any act, deed or thing which may in any manner violate any provisions of this Agreement; (f) support, cooperate with and facilitate the Authority in the implementation and operation of the Project in accordance with the provisions of this Agreement; (g) ensure that the Contractor and its Sub-contractors comply with the safety and welfare measures for labour in accordance with the Applicable Laws and Good Industry Practice; (h) keep, on Site, a copy of this Agreement, publications named in this Agreement, the Drawings, Documents relating to the Project, and Change of Scope orders and other communications given under this Agreement. The Authority’s Engineer and its authorised personnel shall have the right of access to all these documents at all reasonable times; (i) cooperate with other contractors employed by the Authority and personnel of any public authority; and (j) not interfere unnecessarily or improperly with the convenience of the public, or the access to and use and occupation of all roads and footpaths, irrespective of whether they are public or in the possession of the Authority or of others. (viii) The Contractor shall undertake all necessary superintendence to plan, arrange, direct, manage, inspect and test the Works. The Contractor shall provide all necessary superintendence of the Works for the proper fulfilling of the Contractor's obligations under the Agreement. Such superintendence shall be given by competent person having adequate knowledge of the operations to be carried out (including the methods and techniques required, the hazards likely to be encountered and methods of preventing accidents) for the satisfactory and safe execution of the Works. (ix) The Contractor shall obtain and maintain a project related bank account operational at site where all transactions related to the payment of work will be done. The Contractor shall submit a monthly account statement and a detailed report on utilization of funds transferred to this project related bank account to Authority’s Engineer. Notwithstanding anything contrary to this agreement, the authority, in the interest and to ensure timely completion of the work, reserves the right to audit such bank accounts to ensure that there is no diversion of funds from this project specific account to any other project being implemented by the Contractor. (x) The Contractor shall provide the documents of the Contractor specified in the Agreement, and all Contractors' personnel; Goods, consumables and other things and services, whether of a temporary or permanent nature, required in and for the execution, completion of Works and remedying defects. (xi) The Contractor shall perform the Works in conformity with the Project requirements and other requirements and standards prescribed under or pursuant to the Agreement. (xii) The Contractor shall carry out such work incidental and contingent to the original Scope of the Project to comply with Good Industry Practices. (xiii) The Contractor shall maintain required staff and necessary Contractor’s equipment and materials within the reach of the Site during the Defects Liability Period so that any defects arising are promptly attended.
Obligations of the Consultant Conduct of the Services
Obligations of DOE a. In express reliance on the covenants and representations in this Compromise Agreement and to avoid further expenditure of public resources, XXX agrees to accept Respondent’s payment pursuant to section III.2.a in full satisfaction of the penalty authorized by the Act. x. XXX agrees to issue promptly an Adopting Order adopting this Agreement. x. XXX agrees to terminate this enforcement action with prejudice upon Respondent’s completion of its Obligations in accordance with section III.2, above. If Respondent fails to complete its Obligations in accordance with section III.2, above, DOE may notify Respondent that the Agreement is null and void and may seek the maximum penalty in accordance with 10 C.F.R. § 429.120.
Obligations of Management Each officer and key employee of the Company is currently devoting substantially all of his or her business time to the conduct of the business of the Company. The Company is not aware that any officer or key employee of the Company is planning to work less than full time at the Company in the future. No officer or key employee is currently working or, to the Company’s knowledge, plans to work for a competitive enterprise, whether or not such officer or key employee is or will be compensated by such enterprise.
Obligations of the Client 4.1. The client undertakes to inform the company in advance (meaning no later than 2 calendar days) about the dispatch of the goods, by entering the shipment into the Xxxxx.xxx software. 4.1.1. In case of non-compliance with subparagraph 3.2.1 of this agreement, the company has the right to refuse the client in accepting and placing his goods at the warehouse. 4.2. To send goods from the warehouse or to carry out other operations, the client is obliged to provide his client number (client ID) and data of the goods.
Obligations of Contractor 5.01 CONTRACTOR agrees to perform all Services in accordance with the terms and conditions of this Agreement and the Proposal. In the event that the terms of the Proposal shall conflict with the terms of this Agreement or contain additional terms that purport to bind the CITY other than the Services to be rendered and the price for the Services, the terms of this Agreement shall govern and said additional or conflicting terms shall be of no force or effect. 5.02 Except as otherwise agreed by the parties, CONTRACTOR will supply all personnel, materials and equipment required to perform the Services. CONTRACTOR shall provide its own offices, telephones, vehicles and computers and set its own work hours. CONTRACTOR will determine the method, details, and means of performing the Services under this Agreement. 5.03 CONTRACTOR shall keep CITY informed as to the progress of the Services by means of regular and frequent consultations. Additionally, when requested by CITY, CONTRACTOR shall prepare written status reports. 5.04 CONTRACTOR is responsible for paying, when due, all income and other taxes, fees and withholding, including withholding state and federal taxes, social security, unemployment and worker’s compensation, incurred as a result of the compensation paid under this Agreement. XXXXXXXXXX agrees to indemnify, defend and hold harmless CITY for any claims, costs, losses, fees, penalties, interest, or damages suffered by CITY resulting from CONTRACTOR’s failure to comply with this provision. 5.05 In the event CONTRACTOR is required to prepare plans, drawings, specifications and/or estimates, the same shall be furnished in conformance with local, state and federal laws, rules and regulations. 5.06 CONTRACTOR represents that it possesses all required licenses necessary or applicable to the performance of Services under this Agreement and the Proposal and shall obtain and keep in full force and effect all permits and approvals required to perform the Services herein. In the event CITY is required to obtain an approval or permit from another governmental entity, CONTRACTOR shall provide all necessary supporting documents to be filed with such entity. 5.07 CONTRACTOR shall be solely responsible for obtaining Employment Eligibility Verification information from CONTRACTOR’s employees, in compliance with the Immigration Reform and Control Act of 1986, Pub. L. 99-603 (8 U.S.C. 1324a), and shall ensure that CONTRACTOR’s employees are eligible to work in the United States. 5.08 In the event that CONTRACTOR employs, contracts with, or otherwise utilizes any CalPERS retirees in completing any of the Services performed hereunder, such instances shall be disclosed in advance to the CITY and shall be subject to the CITY’s advance written approval. 5.09 Drug-free Workplace Certification. By signing this Agreement, the CONTRACTOR hereby certifies under penalty of perjury under the laws of the State of California that the CONTRACTOR will comply with the requirements of the Drug-Free Workplace Act of 1990 (Government Code, Section 8350 et seq.) and will provide a drug- free workplace. 5.10 CONTRACTOR shall comply with all applicable local, state and federal laws, rules, regulations, entitlements and/or permits applicable to, or governing the Services authorized hereunder.
OBLIGATIONS OF THE LESSEE The Lessee shall keep the premises in a clean, sanitary, neat and presentable condition. The Lessee shall be responsible for the repairs, outside of ordinary wear and tear, of any part of the Premises that do not affect the structural parts of the building or structure in which it is located or those that are generally considered as minor repair (“Minor Repairs”) including but not limited to replacing light bulbs, cleaning or repairs of windows, doors, toilets and similar appurtenances. The Lessee shall, at its sole expense restore, repair and/or rectify any damage, outside of ordinary wear and tear, to the Premises caused by the Lessee or others that the lessee permits into the Premises that are not covered or compensable by any insurance.
Obligations of Licensee 2.1 Licensee is responsible for the quality and safety of its products. 2.2 Licensee shall use all reasonable efforts and diligence to exploit the Invention and to proceed with the development, manufacture and sale of Licensed Product and to use commercially reasonable efforts to develop markets for the Licensed Product. 2.3 Licensee will represent the Licensed Product fairly in comparison with competitive products from other suppliers. 2.4 Licensee shall not, on behalf of University, make any representations or give any warranties or guarantees in respect of the Proprietary IPR not expressly authorised in writing by University, provided that such authorization shall not be unreasonably delayed or withheld by University. 2.5 Licensee shall not market the Licensed Product under the name of University, and not in any way create any impression that University is the seller of the Licensed Product. 2.6 Licensee shall take all such steps as are reasonably necessary to protect Intellectual Property Rights in the Invention. 2.7 Licensee shall promptly inform University upon becoming aware of any illegal or unauthorised use of the Invention or any infringement of the Prospective Patent or Proprietary IPR and Intellectual Property Rights therein. 2.8 Licensee shall comply with all laws, regulations and governmental obligations that may from time to time be applicable to the making, use or sale of the Licensed Product in each part of the Territory. 2.9 As between Licensee and University and without limiting any responsibility of an Affiliate or Sub-Licensee, Licensee shall be solely responsible for any claims arising or alleged to arise from loss or injury to persons or property caused or suffered in the course of or as a consequence of the use of the Invention by Licensee, Affiliates and Sub-Licensees or the supply and sale of the Licensed Product by Licensee, Affiliates and Sub-Licensees except where such loss or injury are caused by the gross negligence or wilful misconduct of University. 2.10 Except as expressly set forth under this Agreement, Licensee shall use its best endeavours to keep the Invention confidential and not to reveal to any third party any confidential information of University regarding the Invention until after a non-disclosure agreement has been signed, provided that no such obligation shall apply to any information that has been publicly disclosed through no breach of this Agreement by Licensee, including by publication of the Inventions by the applicable governmental agency, was in the possession of Licensee prior to disclosure by University, is obtained by Licensee from a third party, or is independently developed by Licensee. 2.11 To the extent prohibited by applicable law, Licensee shall not carry out any illegal, deceptive, or unethical practices, whether or not they are to the disparagement of the Invention, Licensed Product or University, or, subject to the foregoing in this Section 2.11, any other practices which may be detrimental to the Invention, Licensed Product, University or to the public interest.
Obligations of Both Parties Obligations of Party A: 1. Party A undertakes that the products that it provides have been authorized by the General Administration of Quality Supervision, Inspection and Quarantine of the PRC. 2. In order to enhance Party B’s reputation, Party A hereby authorizes Party B to use the Ninetowns trade name in its company name, provided, however, that Party B shall not use such trade name to engage in business activities that are not related to the business as contemplated hereunder. 3. Party A undertakes that during the term of this agreement, it will obtain Party B’s prior consent before developing other franchisees within the franchised area. 4. Party A shall provide Party B with marketing and training materials in connection with the franchised products. 5. Party A shall provide Party B with technical support services. 6. Upgrade services. Obligations of Party B: 1. Party B is responsible for distribution of Party A’s products, after-sale services and technical support in the franchised area. 2. Party B undertakes that it will comply with relevant state and industrial laws and regulations through its sales activities. 3. Party B undertakes that it will not be any third party’s franchisee for any other product that competes with Party A’s products in the franchised area during the term of this agreement. 4. Party B undertakes that the products that it sells are the official versions of Party A’s products, and Party B undertakes that it will not engage in any form of counterfeit activities. 5. Party B undertakes that it will provide users with after-sales service and technical support in accordance with Party A’s service standards and service contents. 6. Party B undertakes that it will make payments to Party A within the prescribed time limit. 7. Party B undertakes that the sales data delivered by Party B to Party A monthly, i.e. the monthly sales report, will be true and accurate.