Contract (Rights of Third Parties) Xxx 0000 22.1 No person who is not a party to this Grant Agreement shall have the right to enforce any of its terms.
Default by State If the State, sixty (60) days after receipt of written notice, fails to correct or cure any material breach of this Contract, the Contractor may cancel and terminate this Contract and institute measures to collect monies due up to and including the date of termination.
Use by Others Forest Service shall have the right to use any road constructed by Purchaser under this contract for any and all purposes in connection with the protection and administration of the National Forest. Other parties, in connection with the logging of tributary National Forest timber, may use roads constructed by Purchaser hereunder when Contracting Officer determines that such use will not materially interfere with Purchaser’s Operations. Third party use shall be contin- gent upon Contracting Officer determining, and third party agreeing to pay, a fair share of maintenance cost com- mensurate with such commercial use. (a) Contracting Officer makes appropriate arrange- ments to relieve Purchaser of related maintenance costs commensurate with such other uses and (b) Such other uses will not materially interfere with Purchaser’s Operations. Where Purchaser reconstructs a road having estab- lished use, Purchaser’s use during reconstruction and thereafter shall be such as to reasonably accommodate such established use. Contracting Officer shall ensure that other users do not materially interfere with Purchaser’s right to use such reconstructed road.
OUR LIABILITY FOR FAILURE TO STOP PAYMENT If You order Us to place a stop payment on one of Your pre-authorized payments 3 business days or more before the transfer is scheduled, and We do not do so, We will be liable for losses or damages, to the extent provided by law. TRANSACTION SLIPS. Except for mail-in transactions and certain small-value transactions, You can get a receipt at the time You make any transaction to or from Your Account through the use of Your Card. When an electronic fund transfer has been made during any given month, You will receive a monthly statement to reflect all electronic fund transfers to or from Your Account during that statement period. In any case, You will receive a statement at least quarterly. FEES. We may assess reasonable charges against Your Account for transactions performed at electronic terminals. If so, We will specify any charges for these or other types of electronic transactions, including automatic transfers, on an accompanying pricing document. We will explain the charges to You when You open Your Account. You will be provided with a fee schedule, and other specified information after Your Account is established. Additional fee schedules are available at any of Our office locations. When You use an ATM not owned by Us, You may be charged a fee by the ATM operator, or any network used, and You may be charged a fee for a balance inquiry even if You do not complete a fund transfer.
CUSTOMER REMEDIES 5.1. If the Supplier (a) fails to deliver the Goods and/or the Goods do not comply with any of the undertakings or warranties set out in clause 2 and/or (b) fails to deliver and/or perform the Services in accordance with any of the warranties or undertakings contained in clause 4 and/or by the applicable date(s), the Customer shall, without limiting or affecting other rights or remedies available to it, have one or more of the following rights to: 5.1.1. terminate the Agreement with immediate effect by giving written notice to the Supplier; 5.1.2. reject the Goods (in whole or in part) whether or not title has passed and to return them to the Supplier at the Supplier’s own risk and expense; 5.1.3. require the Supplier to repair or replace the rejected Goods, or to provide a full refund of the price of the rejected Goods; 5.1.4. require Supplier to re-perform, rectify or replace the affected Services and/or Deliverables; 5.1.5. refuse to accept any subsequent performance of the Services and/or delivery of the Goods which the Supplier attempts to make; 5.1.6. recover from the Supplier any costs incurred by the Customer in obtaining substitute goods and/or services from a third party; 5.1.7. require a refund from the Supplier of sums paid in advance for Services that the Supplier has not provided and/or Goods that it has not delivered; and 5.1.8. claim damages for any additional costs, loss or expenses incurred by the Customer which are in any way attributable to the Supplier’s breach. 5.2. Notwithstanding any other rights or remedies available to Customer if the Goods are not delivered by the applicable date, the Customer may, at its option, claim or deduct 3% of the price of the Goods for each week’s delay in delivery, up to a maximum of 15% of the total price of the Goods. In the event such delay continues for six (6) weeks or more, Customer may terminate the Agreement with immediate effect upon given Supplier written notice. 5.3. These Terms shall extend to any substituted or remedial services and/or repaired or replacement goods supplied by the Supplier. 5.4. The Customer’s rights under the Agreement are in addition to its rights and remedies implied by statute and common law.
City’s Remedies In addition to any other remedies the City may have upon Developer and/or Developer’s contractor for the failure to provide and maintain insurance or policy endorsements to the extent and within the time required, the City shall have the right, to order Developer to stop work, and/or withhold any payment(s), which become due until Developer and/or Developer’s contractor demonstrates compliance with the requirements.
Contracts (Rights of Third Parties) Xxx 0000 No term of this Agreement is enforceable under the Contracts (Rights of Third Parties) Xxx 0000 by a person who is not a party to this Agreement.
TERMINATION BY MPS - BREACH BY CONTRACTOR If Contractor fails to fulfill its obligations under this Contract in a timely or proper manner, or violates any of its provisions, MPS shall thereupon have the right to terminate it by giving five (5) days written notice before the effective date of termination of the Contract, specifying the alleged violations, and effective date of termination. The Contract shall not be terminated if, upon receipt of the notice, Contractor promptly cures the alleged violation with five (5) days. In the event of termination, MPS will only be liable for services rendered through the date of termination and not for the uncompleted portion, or for any materials or services purchased or paid for by Contractor for use in completing the Contract.
Failure to Pursue Remedies The failure of any party to seek redress for violation of, or to insist upon the strict performance of, any provision of this Agreement shall not prevent a subsequent act, which would have originally constituted a violation, from having the effect of an original violation.
Tenant’s Remedies Notwithstanding any other provision of this Lease, if any default hereunder by Landlord is not cured within the applicable cure period provided in Paragraph 20(c) or any other applicable cure period provided in this Lease (including any Mortgagee’s additional cure period), Tenant’s exclusive remedies shall be (i) an action for specific performance, or (ii) an action for actual damages. Notwithstanding any other provision of this Lease, the liability of Landlord to Tenant for any breach or default by Landlord under the terms of this Lease, or for any other matter related to this Lease or to the Premises or Project, shall be limited to Tenant’s actual direct, but not consequential, damages therefor, and any judgment against Landlord in connection therewith shall be recoverable only from the interest of Landlord in the Buildings. Tenant hereby waives any claim for damages for any disturbance, loss of business, nuisance, injury or inconvenience to or interference with Tenant’s business, any loss of occupancy or quiet enjoyment of the Premises, and any other loss arising from Landlord’s entry and acts pursuant to Paragraph 18 or otherwise with respect to any act, omission or breach of Landlord. Without limiting the preceding sentence, in no event shall Landlord be liable to Tenant for any consequential damages, including, without limitation, any losses arising from any interruption of Tenant’s business, or for lost profits, or for charges or expenses which continue but would have been earned if the business had gone on without interruption, or for any other loss, claim, cost, expense or damage which would be covered by a standard policy of business interruption insurance. Landlord, or if Landlord is a partnership its partners whether general or limited, or if Landlord is a corporation its directors, officers or shareholders, or if Landlord is a limited liability company its members or managers, shall never be personally liable for any such judgment. Any lien obtained to enforce such judgment and any levy of execution thereon shall be subject and subordinate to any Mortgage (excluding any Mortgage which was created as part of an effort to defraud creditors, i.e., a fraudulent conveyance); provided, however that any such judgment and any such levy of execution thereon shall not be subject or subordinated to any Mortgage that is created or recorded in the official records of the county in which the Project is located after the date of the judgment giving rise to such lien. Landlord’s interest in the Buildings shall include any insurance proceeds received by Landlord which are not controlled by any Mortgagee or other lender. Tenant hereby waives the benefit of any Laws granting it (A) the right to perform Landlord’s obligations, or (B) the right to terminate this Lease or withhold Rent on account of any Landlord default, including, without limitation, Sections 1932(1), 1941 and 1942 of the California Civil Code.
