Investment of Funds in the Accounts The Trustee may direct any depository institution maintaining the Certificate Account or the Reserve Account, if any, for the Series and any other segregated Eligible Account, which Eligible Account shall be a Securities Account the contents of which are held for the benefit of Certificateholders of such applicable Series (each, an "Account"), to invest the funds therein at the specific written direction of the Depositor in one or more Eligible Investments bearing interest or sold at a discount, which shall be held to maturity unless payable on demand and which funds shall not be reinvested upon the maturity or demand for payment of such Eligible Investment. If the Depositor does not provide any investment directions by 10:00 a.m. on any Business Day, funds held in any Account will be invested in the Eligible Investments specified in clause (iv) of the definition thereof until receipt of investment directions to the contrary. Investments of such funds shall be invested in Eligible Investments that will mature so that such funds will be available for distribution on the next Distribution Date. Except as otherwise provided in the applicable Supplement, any earnings with respect to such Eligible Investments shall be paid to, and any losses with respect to such Eligible Investments shall be solely for the account of, the Certificateholders in proportion to their interest in the invested funds. In the event amounts on deposit in an Account are at any time invested in an Eligible Investment payable on demand, the Securities Intermediary, on behalf of the Trustee and the Trust, shall:
(i) consistent with any notice required to be given thereunder, demand that payment thereon be made on the last day such Eligible Investment may otherwise mature hereunder in an amount equal to the lesser of (1) all amounts then payable thereunder and (2) the amount required to be withdrawn on such date; and
(ii) demand same day payment of all amounts due thereunder upon a determination by the Trustee that such Eligible Investment would not constitute an Eligible Investment in respect of funds thereafter on deposit in any Account. None of the Trustee, the Depositor or the Securities Intermediary shall in any way be held liable by reason of any insufficiency in any Account resulting from any loss on any Eligible Investment made in accordance with this Trust Agreement.
Operation of the Agreement The Parties recognize that it is impractical in this Agreement to provide for every contingency which may arise during the life of the Agreement, and the Parties hereby agree that it is their intention that this Agreement shall operate fairly as between them, and without detriment to the interest of either of them, and that, if during the term of this Agreement either Party believes that this Agreement is operating unfairly, the Parties will use their best efforts to agree on such action as may be necessary to remove the cause or causes of such unfairness, but failure to agree on any action pursuant to this Clause 8.2 shall not give rise to a dispute subject to arbitration in accordance with Clause 9 hereof.
Operation of the Business Except as set forth on Section 10.1 of the Sentech Disclosure Schedule, as contemplated by this Agreement or as expressly agreed to in writing by Sensec and Ensec, during the period from the date of this Agreement to the Effective Time, Sentech and its Subsidiaries will conduct their operations only in the ordinary course of business consistent with sound financial, operational and regulatory practice, and will take no action which would materially adversely affect their ability to consummate the Transactions. Without limiting the generality of the foregoing, except as otherwise expressly provided in this Agreement or except as disclosed in the Sentech Disclosure Schedule, prior to the Effective Time, neither Sentech nor any of its Subsidiaries will, without the prior written consent of Sensec and Ensec:
(a) amend its Charter Documents or bylaws (or similar organizational documents);
(b) authorize for issuance, issue, sell, deliver, grant any options for, or otherwise agree or commit to issue, sell or deliver any shares of its capital stock or any other securities, other than pursuant to and in accordance with the terms of any Existing Options or Sentech Warrants listed on the Sentech Disclosure Schedule;
(c) recapitalize, split, combine or reclassify any shares of its capital stock; declare, set aside or pay any dividend or other distribution (whether in cash, stock or property or any combination thereof) in respect of its capital stock; or purchase, redeem or otherwise acquire any of its or its Subsidiaries' securities or modify any of the terms of any such securities;
(d) (i) create, incur, assume or permit to exist any long-term debt or any short-term debt for borrowed money other than under existing notes payable, lines of credit or other credit facilities or in the ordinary course of business, or with respect to its Wholly-Owned Subsidiaries in the ordinary course of business; (ii) assume, guarantee, endorse or otherwise become liable or responsible (whether directly, contingently or otherwise) for the obligations of any other Person except its Wholly-Owned Subsidiaries in the ordinary course of business or as otherwise may be contractually required and disclosed in the Sentech Disclosure Schedule; or (iii) make any loans, advances or capital contributions to, or investments in, any other Person except its Wholly-Owned Subsidiaries;
(i) amend any Sentech Benefit Plan or (ii) except in the ordinary course of business consistent with usual practice or established policy (a) increase in any manner the rate of compensation of any of its directors, officers or other employees everywhere, except for increases in the ordinary course of business; (b) pay or agree to pay any bonus, pension, retirement allowance, severance or other employee benefit except as required under currently existing Sentech Benefit Plans disclosed in the Sentech Disclosure Schedule or in the ordinary course of business; or (c) amend, terminate or enter into any employment, consulting, severance, change in control or similar agreements or arrangements with any of its directors, officers or other employees;
(f) enter into any material agreement, commitment or contract, except agreements, commitments or contracts for the purchase, sale or lease of goods or services in the ordinary course of business;
(g) other than in the ordinary course of business, authorize, recommend, propose or announce an intention to authorize, recommend or propose, or enter into any Contract with respect to, any (i) plan of liquidation or dissolution, (ii) acquisition of a material amount of assets or securities, (iii) disposition or Encumbrance of a material amount of assets or securities, (iv) merger or consolidation or (v) material change in its capitalization;
(h) change any material accounting or Tax procedure or practice;
(i) take any action the taking of which, or knowingly omit to take any action the omission of which, would cause any of the representations and warranties herein to fail to be true and correct in all material respects as of the date of such action or omission as though made at and as of the date of such action or omission;
(j) compromise, settle or otherwise modify any material claim or litigation not identified in the Sentech Disclosure Schedule; or
(k) commit or agree to do any of the foregoing.
Administration of the Agreement The Agreement shall be administered by the Board of Directors of the Company or its delegate (the “Administrator”). Subject to the provisions of the Agreement, the Administrator shall have full and final authority in its discretion to take any action with respect to the Agreement including, without limitation, the authority to (i) determine all matters relating to the payments; (ii) establish, amend and rescind rules and regulations for the administration of the Agreement; and (iii) construe and interpret the Agreement, to interpret rules and regulations for administering the Agreement and to make all other determinations deemed necessary or advisable for administering the Agreement. Except to the extent otherwise required under Section 409A of the Internal Revenue Code of 1986, as amended (“Code”), the Administrator shall have the authority, in its sole discretion, to accelerate the date that any Consultation Payments or Separation Payments which were not otherwise vested or earned shall become vested or earned in whole or in part without any obligation to accelerate such date with respect to any other employee. The Administrator also may in its sole discretion determine that Executive’s rights or payments under the Agreement shall be subject to reduction, cancellation, forfeiture or recoupment due to conduct by Executive that is determined by the Administrator to be detrimental to the business or reputation of the Company, including, without limitation, upon termination of employment for cause; violation of policies of the Company; or breach of non-solicitation, noncompetition, confidentiality or other restrictive covenants that apply to the Executive. In addition to action by meeting in accordance with applicable laws, any action of the Administrator with respect to the Agreement may be taken by a written instrument signed by the Administrator (including, where the Board or a committee serves as the Administrator, by written consent signed by all of the members of the Board, or all of the members of a committee, and any such action so taken by written consent shall be as fully effective as if it had been taken by a majority of the members at a meeting duly held and called). No individual shall be liable while acting as Administrator for any action or determination made in good faith with respect to the Agreement, and any such individual shall be entitled to indemnification and reimbursement in the manner provided in the Company’s certificate of incorporation and bylaws and/or under applicable law.
Operation of the Property Between June 1, 1998 and the Closing Date, Seller shall (a) lease, operate, manage and enter into contracts with respect to the Property, in the same manner done by Seller prior to the date hereof (provided, however, that without the prior consent of Purchaser, which as to (i) and (ii) shall not be unreasonably delayed, conditioned or withheld, (i) Seller shall not enter into any Service Contract that cannot be terminated with thirty (30) days notice or materially modify any existing Service Contracts to be assumed by Purchaser at Closing, and (ii) after June 1, 1998, Seller shall not materially modify or terminate any existing Tenant Lease or grant any material consents under any existing Tenant Lease (except as otherwise required pursuant to the terms and conditions of such Tenant Lease), or enter into any new Tenant Lease, and (iii) Seller shall not apply any then unapplied Deposits (as reflected on the Rent Roll delivered by Seller to Purchaser pursuant to Schedule 5.3(vii) hereof) under Tenant Leases); and (b) advise Purchaser of the commencement of any litigation, condemnation or other judicial or administrative proceedings affecting the Property of which Seller has current actual knowledge. Notwithstanding anything to the contrary set forth in this Contract, Purchaser acknowledges that after June 1, 1998 and prior to Closing, Seller will enter into contracts for the completion of Tenant improvements under Tenant Leases entered into after June 1, 1998 pursuant to the terms of Section 12.1 hereof (collectively, the "Tenant Finish Contracts"). Purchaser and Seller agree that at Closing, Purchaser shall assume the obligations of Seller under all such Tenant Finish Contracts including, without limitation, the obligations to pay any costs and expenses charged with respect to construction of improvements in the space subject to such Tenant Leases. At Closing, Purchaser shall execute and deliver to the Seller an Assignment, Assumption and Indemnity Agreement in the form attached hereto as Exhibit H and made a part hereof for all purposes.
POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
POSSESSION OF THE APARTMENT PLOT
8.1 Schedule for possession of the said Apartment: The Promoter agrees and understands that timely delivery of possession of the Apartment to the Allottee and the Common Areas to the Association of the Allottees , is the essence of the Agreement. Provided that the Promoter shall be entitled to reasonable extension of time as agreed by and between the Allottee and the Promoter for giving possession of the Apartment on the aforesaid date and the same shall not include the period of extension given by the Authority for registration. The Promoter, based on the approved plans and specifications, assures to hand over possession of the Apartment on …………,with a grace period of twelve months (Completion date) in case the Promoter fails to complete the Project. unless there is a delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity or order, rule, notification of the Government and/or other public or competent authority/court and/or caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, Provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. Promoter will be entitled to give block-wise and phase-wise possession upon obtaining the Completion Certificate/ Partial Completion Certificate of a building block or a particular phase as the case may be irrespective of the fact that construction of other Blocks and/or other phases and/or provision of facilities may be incomplete. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 45 days from that date.After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement. It is clarified that all amounts collected as taxes, charges, levies, cess, assessments and impositions and deposited with the appropriate authorities concerned shall not be returned by the Promoter and the Allottee shall be free to approach the authorities concerned for refund of such taxes, charges, levies, cess, assessments and impositions.
8.2 The right of the Allottee shall remain restricted to the respective Apartment and the properties appurtenant thereto and the Allottee shall have no right, title or interest nor shall claim any right, title or interest of any kind whatsoever over and in respect of any other Apartment or space and/or any other portions of the Project or Complex.
8.3 The Promoter has provided to the Allottee a time schedule for construction progress based on the milestones on which payment is due. The dates provided are only tentative and for the purpose of dealing with contractors and will also make efforts to complete various stages as per the time schedule upto completion of the Project including the provisions of civic infrastructure like water, electricity, sanitation and all other above mentioned internal/external development works but the Promoter knows there will definitely be delays in the timelines provided but the Promoter assures the Allottee that the Project will be completed within the ‘Completion date’ provided in Clause 8.1 above.
Condition of the Business (a) Notwithstanding anything contained in this Agreement to the contrary, Purchaser acknowledges and agrees that Seller is not making any representations or warranties whatsoever, express or implied, beyond those expressly given by Seller in Article V hereof (as modified by the Seller Schedules as supplemented or amended), and Purchaser acknowledges and agrees that, except for the representations and warranties contained therein, the Purchased Assets and the Business are being transferred on a “where is” and, as to condition, “as is” basis. Any claims Purchaser may have for breach of representation or warranty shall be based solely on the representations and warranties of Seller set forth in Article V hereof (as modified by the Seller Schedules as supplemented or amended). Purchaser further represents that neither Seller nor any of its Affiliates nor any other Person has made any representation or warranty, express or implied, regarding Seller, the Purchased Assets, the Business or the transactions contemplated by this Agreement or as to the accuracy or completeness of any information not expressly set forth in this Agreement and neither Purchaser nor any of its Affiliates has relied on any such express or implied representation or warranty. Purchaser further agrees that none of Seller, any of its Affiliates or any other Person will have or be subject to any liability to Purchaser or any other Person resulting from the distribution to Purchaser or its representatives or Purchaser’s use of, any such information, including any confidential memoranda distributed on behalf of Seller relating to the Business or other publications or data room information provided to Purchaser or its representatives, or any other document or information in any form provided to Purchaser or its representatives in connection with the sale of the Business and the transactions contemplated hereby. Purchaser acknowledges that it has conducted to its satisfaction, its own independent investigation of the Business and, in making the determination to proceed with the transactions contemplated by this Agreement, Purchaser has relied on the results of its own independent investigation.
Construction of the Agreement The Agreement sets forth the entire understanding between two sophisticated business entities with legal counsel as to its subject and supersedes all prior agreements, conditions, warranties, representations, arrangements and communications, including purchase orders issued by Client, whether oral or written, and whether with or by Accenture, any of its affiliates, or any of their employees, officers, directors, agents or shareholders. Each party acknowledges that it entered into the Agreement solely based on the agreements and representations contained herein, and has not relied upon any representations, warranties, promises, or inducements of any kind, whether oral or written, and from any source. If a court of competent jurisdiction finds any term of the Agreement to be invalid, illegal or otherwise unenforceable, such term or provision will not affect the other terms of this Agreement and will be deemed modified to the extent necessary, in the court’s opinion, to render such term enforceable while preserving to the fullest extent permissible the intent and agreements of the parties set forth in this Agreement. No waiver or modification of any provision of the Agreement will be effective unless it is in writing and signed by the party against which it is sought to be enforced. The delay or failure by either party to exercise or enforce any of its rights under this Agreement is not a waiver of that party’s right to later enforce those rights, nor will any single or partial exercise of any such right preclude any other or further exercise of these rights or any other right. There are no third-party beneficiaries to the Agreement. In the event of a conflict between these GTC and an Order Form, the Order Form controls for purposes of that Order Form only.
The Account 1. AEME is fully authorized to manage and operate the Card Account and to debit all Charges, Transactions made on the Card or any Supplementary Card, fees and other amounts for all of which the Cardmember shall be liable. The Cardmember irrevocably undertakes and promises to pay to AEME all Charges and amounts debited to or outstanding on the Card Account including Charges incurred on any Supplementary Card whether or not a record of the Charge or Transaction has been issued and or signed at the Service Establishment.
2. Except for what is provided under Clauses 9 and 14 of this Agreement, the Cardmember acknowledges and agrees that all Charges debited at any time by AEME to his or her Card Account are true and accurate. The Cardmember also acknowledges that all records and data maintained by AEME on microfilm or in any printed or electronic form in connection with the Transactions, Charges, Card or Card Account are true, accurate and complete and may be used in any court of law as conclusive evidence which may not be disputed or challenged in any manner.
3. AEME may, at its ultimate discretion, refuse any request for authorization and may decline any Transaction including Cash Withdrawals regardless of the reason and without giving any notice to the Cardmember. Also, AEME may not be liable to provide or process authorization for any Transaction due to technical failures or any other reason of similar nature. In both circumstances and in any other similar situation, AEME is not liable whether directly or indirectly for any damages of any nature including monetary, liquidated, punitive or consequential damages which the Cardmember may sustain as a result of any unsuccessful, uncompleted or declined Transaction.
4. Xxxxxxxxxx promises to pay AEME for debits made on his Account for purchases and all other amounts owed to AEME under the Terms and Conditions of this Agreement.
5. If the Cardmember is on direct debit with a bank, the bank will also receive a monthly summary of Charges and will use the summary to directly debit the Cardmember account.
