PRODUCT DELIVERY Delivery must be made as ordered to the address specified on the Purchase Order and in accordance with the terms of the Contract or Contract Award Notice. Unless otherwise specified in the Bid Documents, delivery shall be made within thirty calendar days after receipt of a Purchase Order by the Contractor. The decision of the Commissioner as to compliance with delivery terms shall be final. The burden of proof for delay in receipt of Purchase Order shall rest with the Contractor. In all instances of a potential or actual delay in delivery, the Contractor shall immediately notify the Commissioner and the Authorized User, and confirm in writing the explanation of the delay, and take appropriate action to avoid any subsequent late deliveries. Any extension of time for delivery must be requested in writing by the Contractor and approved in writing by the Authorized User. Failure to meet such delivery time schedule may be grounds for cancellation of the order or, in the Commissioner’s discretion, the Contract.
Delivery time 7.1. The delivery time shall start as soon as the contract is entered into, all official formalities have been completed, payments due with the order have been made, any agreed securities given and the main technical points settled. The delivery time shall be deemed to be observed if by that time XXXXXX has sent a notice to the customer informing him that the supplies are ready for dispatch.
Delivery Date Warranties begin on the date of delivery, or on the date of installation if installed by us. If you schedule or delay such installation by us more than thirty (30) days after delivery, your warranty period will begin on the 31st day after delivery.
Notification of Delivery Destination Prior to final acceptance of contract requirements by STATE, PURCHASER shall notify STATE, in a form and manner prescribed by STATE, of the delivery destination of all timber purchased under this contract. STATE may hold PURCHASER's performance bond until satisfactory delivery destination information has been received. Notice of Transfer of State Timber. Prior to selling, trading, exchanging, or otherwise conveying unprocessed timber sold under this contract to any other person, PURCHASER must first obtain a certification of the person's eligibility to purchase unprocessed State timber, and their intent to comply with the terms and conditions contained in OAR 629-031-0005 through 629-031-0045. The certification shall be made in a form and manner prescribed by STATE, and shall be forwarded to STATE upon completion of the transaction. Obtaining the certification shall not relieve PURCHASER of the responsibility to provide STATE with an accounting of the delivery destination of that timber.
Shipping must be Freight On Board Destination to the delivery location designated on the Customer purchase order The Contractor will retain title and control of all goods until delivery is completed and the Customer has accepted the delivery. All risk of transportation and all related charges are the responsibility of the Contractor. The Customer will notify the Contractor and H-GAC promptly of any damaged goods and will assist the Contractor in arranging for inspection. The Contractor must file all claims for visible or concealed damage. Unless otherwise stated in the Agreement, deliveries must consist only of new and unused merchandise.
Recall Notice Notice of Recall or available position may be made in person or by U.S. Mail, return receipt requested. It is the responsibility of each laid off employee notify the Sheriff of his/her current address.
Grant Completion Deadline The grant completion deadline is the end date of this Agreement set forth in Section 2 above. The Grant Completion Deadline is the date when all grant and matching funds have been paid out or incurred in accordance with the work described in the Scope of Work, detailed in the Estimated Project Budget. If the Grantee finds it necessary to request an extension of the Grant Completion Deadline, an Amendment to the Agreement must be executed as per Section 7, and the stipulations in Section 15 must be met.
STOP WORK NOTICE The City may issue an immediate Stop Work Notice in the event the Contractor is observed performing in a manner that is in violation of Federal, State, or local guidelines, or in a manner that is determined by the City to be unsafe to either life or property. Upon notification, the Contractor will cease all work until notified by the City that the violation or unsafe condition has been corrected. The Contractor shall be liable for all costs incurred by the City as a result of the issuance of such Stop Work Notice.
CAFA Notice Pursuant to 28 U.S.C. § 1715, not later than ten (10) days after the Agreement is filed with the Court, the Settlement Administrator shall cause to be served upon the Attorneys General of each U.S. State in which Settlement Class members reside, the Attorney General of the United States, and other required government officials, notice of the proposed settlement as required by law, subject to Paragraph 5.1 below.
Non Delivery C15.1 Where the Goods, having been placed in transit, fail to be delivered to the Authority on the due date for delivery, the Authority shall, (provided that the Authority has been advised in writing of the dispatch of the Goods), within ten (10) Working Days of the notified date of delivery, give notice to the Contractor that the Goods have not been delivered and may request the Contractor free of charge to deliver substitute Goods within the timescales specified by the Authority or terminate the Contract in accordance with clause C13.4 (Delivery).
