Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
Owner’s Rights B.1.1 The Owner shall have the right to perform work related to the project and to award contracts in connection with the project that are not part of the Consultant’s responsibilities under the AGREEMENT. The consultant shall notify the Owner in writing if any such independent action will in any way compromise the Consultants’ ability to meet their responsibilities under the AGREEMENT. B.1.2 The Owner reserves the right to approve the consultant’s personnel and to require a replacement satisfactory to the Owner. The Owner reserves the right to have such person replaced if, in the judgment of the Owner, any such person proves unsatisfactory. However, such replacement must fit within the rate/fee structure; in the alternative, the Owner shall have the option for a higher rate person for which the Consultant shall be compensated at the higher rate. B.1.3 The Owner shall have the right to effect the removal of any of the Consultant’s employees at any time during the duration of the AGREEMENT if that employee is deemed not to be of the level of competence or ability required under the AGREEMENT, or said employee is for any reason found to be unsuitable for the work. In such case, the Consultant shall promptly submit the name and qualifications of a replacement for approval by the Owner. B.1.4 The Owner shall have the right to assign the administration of any or all contracts related to this project from the Owner to another State Agency, Authority or Commission at any time during the life of the project. In doing so, the Consultant agrees to continue to perform all contractual work under the AGREEMENT. The Consultant shall make no claim against the Owner in the event of such assignment. B.1.5 The Owner may make changes in the scope of services within the general scope of the AGREEMENT. The Owner may also make changes to the scope of the project which may give rise to changes in the scope of the Consultant services. In such case, the Consultant shall be entitled to an adjustment in fee and in other terms and conditions of the AGREEMENT.
OWNER’S RIGHT TO CARRY OUT THE WORK If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten (10)-calendar day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner’s expenses and compensation for the Architect’s additional services made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner.
Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.
Landlord’s Right to Enter Landlord and its agents shall have the right to enter the Leased Premises during normal business hours after giving Tenant reasonable notice and subject to Tenant’s reasonable security measures for the purpose of (i) inspecting the same; (ii) showing the Leased Premises to prospective purchasers, mortgagees or tenants; (iii) making necessary alterations, additions or repairs; and (iv) performing any of Tenant’s obligations when Tenant has failed to do so. Landlord shall have the right to enter the Leased Premises during normal business hours (or as otherwise agreed), subject to Tenant’s reasonable security measures, for purposes of supplying any maintenance or services agreed to be supplied by Landlord. Landlord shall have the right to enter the Outside Areas during normal business hours for purposes of (i) inspecting the exterior of the Building and the Outside Areas; (ii) posting notices of nonresponsibility (and for such purposes Tenant shall provide Landlord at least thirty days’ prior written notice of any work to be performed on the Leased Premises); and (iii) supplying any services to be provided by Landlord. Any entry into the Leased Premises or the Outside Areas obtained by Landlord in accordance with this paragraph shall not under any circumstances be construed or deemed to be a forcible or unlawful entry into, or a detainer of, the Leased Premises, or an eviction, actual or constructive of Tenant from the Leased Premises or any portion thereof.
Lessor’s Right to Inspect Lessee shall permit Lessor and its authorized representatives as frequently as reasonably requested by Lessor to inspect the Leased Property and Lessee’s accounts and records pertaining thereto and make copies thereof, during usual business hours upon reasonable advance Notice, subject only to any business confidentiality requirements reasonably requested by Lessee.
LANDLORD'S RIGHT TO INSPECT Tenant shall permit Landlord and its authorized representatives to inspect the Leased Property, or any portion thereof, during usual business hours upon not less than forty-eight (48) hours’ notice and to make such repairs as Landlord is permitted or required to make pursuant to the terms of this Agreement, provided that any inspection or repair by Landlord or its representatives will not unreasonably interfere with Tenant’s use and operation of the Leased Property and further provided that in the event of an emergency, as determined by Landlord in its reasonable discretion, prior Notice shall not be necessary.
Borrower’s Right to Cure Notwithstanding anything to the contrary contained in Section 8.01, for purposes of determining whether an Event of Default has occurred under any financial covenant set forth in Section 7.11, any equity contribution (in the form of Qualified Capital Stock or other equity having terms reasonably acceptable to the Administrative Agent) made to Holdings after the last day of any Fiscal Quarter and on or prior to the day that is seven (7) Business Days after the day on which financial statements are required to be delivered for that Fiscal Quarter will, at the request of Holdings by delivery to the Administrative Agent of a notice that it intends to exercise the cure rights under this Section 8.04 and referencing that it is a notice of intent to cure under this Section 8.04 (a “Notice of Intent to Cure”), be included in the calculation of Consolidated EBITDA for the purposes of determining compliance with the financial covenants set forth in Section 7.11 at the end of such Fiscal Quarter and any subsequent period that includes such Fiscal Quarter (any such equity contribution, a “Specified Equity Contribution”); provided that (a) Holdings shall not be permitted to so request that a Specified Equity Contribution be included in the calculation of Consolidated EBITDA with respect to any Fiscal Quarter unless, after giving effect to such requested Specified Equity Contribution, there will be a period of at least two (2) consecutive Fiscal Quarters in the Relevant Four Fiscal Quarter Period in which no Specified Equity Contribution has been made, (b) no more than two (2) Specified Equity Contributions may be made in the Relevant Four Fiscal Quarter Period, (c) no more than four (4) Specified Equity Contributions may be made in the aggregate during the term of this Agreement, (d) the amount of the Specified Equity Contribution shall be no greater than the amount required to cause Holdings to be in compliance with the financial covenants set forth in Section 7.11 for the Relevant Four Fiscal Quarter Period, (e) except for calculations of Excess Cash Flow for the purposes of Section 2.05(b)(i) only (in which case, Specified Equity Contributions will be included in the calculation of Excess Cash Flow for the Fiscal Year during which the Fiscal Quarter giving rise to the respective Specified Equity Contribution occurred), all Specified Equity Contributions will be disregarded for all other purposes under the Loan Documents (including, without limitation, calculating Consolidated EBITDA for purposes of determining basket levels, Retained Excess Cash Flow Amount, Applicable Fee Rate, Applicable Rate, Consolidated Total Lease Adjusted Leverage Ratio and other items governed by reference to Consolidated EBITDA, and for purposes of the Restricted Payment covenant in Section 7.06(f) and the Investment covenant in Section 7.03(o)), (f) the proceeds of all Specified Equity Contributions will be contributed to the Borrower as proceeds of Qualified Capital Stock or other equity having terms reasonably acceptable to the Administrative Agent, (g) if the proceeds of the Specified Equity Contribution are used to repay Indebtedness, such Indebtedness shall not be deemed to have been repaid for purposes of calculating any financial covenant set forth in Section 7.11 or for purposes of calculating the Consolidated Total Lease Adjusted Leverage Ratio, in each case for the Relevant Four Fiscal Quarter Period, and (h) upon the Administrative Agent’s receipt of a Notice of Intent to Cure, until the fifteenth Business Day after the day on which financial statements are required to be delivered for that Fiscal Quarter to which such Notice of Intent to Cure relates, none of the Administrative Agent or any Lender shall exercise the right to accelerate the Loans or terminate the Commitments and none of the Administrative Agent, or any other Lender or Secured Party shall exercise any right to foreclose on or take possession of the Collateral solely on the basis of an Event of Default having occurred and being continuing under Section 7.11, but shall not be restricted from doing any of the foregoing with respect to any other Event of Default and each other Default or Event of Default that may exist at such time shall continue to exist and shall not be affected by the exercise of the cure of rights hereunder; provided, that until timely receipt of the Specified Equity Contribution, an Event of Default shall be deemed to exist for all other purposes of the Loan Documents.
HHS Right to Use Contractor agrees that HHS has the right to use, produce, and distribute copies of and to disclose to HHS employees, agents, and contractors and other governmental entities all or part of this Contract or any related Solicitation Response as HHS deems necessary to complete the procurement process or comply with state or federal laws.
BUYER’S RIGHT TO CANCEL If after completion of an appraisal by a licensed appraiser, Buyer receives written notice from the Lender or the appraiser that the Property has appraised for less than the Purchase Price (a “Notice of Appraised Value”), Buyer may cancel the REPC by providing written notice to Seller (with a copy of the Notice of Appraised Value) no later than the Financing & Appraisal Deadline referenced in Section 24(c); whereupon the Xxxxxxx Money Deposit shall be released to Buyer without the requirement of further written authorization from Seller.