Failure to Provide Insurance Lessee acknowledges that any failure on its part to obtain or maintain the insurance required herein will expose Lessor to risks and potentially cause Lessor to incur costs not contemplated by this Lease, the extent of which will be extremely difficult to ascertain. Accordingly, for any month or portion thereof that Lessee does not maintain the required insurance and/or does not provide Lessor with the required binders or certificates evidencing the existence of the required insurance, the Base Rent shall be automatically increased, without any requirement for notice to Lessee, by an amount equal to 10% of the then existing Base Rent or $100, whichever is greater. The parties agree that such increase in Base Rent represents fair and reasonable compensation for the additional risk/costs that Lessor will incur by reason of Lessee's failure to maintain the required insurance. Such increase in Base Rent shall in no event constitute a waiver of Lessee's Default or Breach with respect to the failure to maintain such insurance, prevent the exercise of any of the other rights and remedies granted hereunder, nor relieve Lessee of its obligation to maintain the insurance specified in this Lease.
Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
Owner’s Rights B.1.1 The Owner shall have the right to perform work related to the project and to award contracts in connection with the project that are not part of the Consultant’s responsibilities under the AGREEMENT. The consultant shall notify the Owner in writing if any such independent action will in any way compromise the Consultants’ ability to meet their responsibilities under the AGREEMENT.
B.1.2 The Owner reserves the right to approve the consultant’s personnel and to require a replacement satisfactory to the Owner. The Owner reserves the right to have such person replaced if, in the judgment of the Owner, any such person proves unsatisfactory. However, such replacement must fit within the rate/fee structure; in the alternative, the Owner shall have the option for a higher rate person for which the Consultant shall be compensated at the higher rate.
B.1.3 The Owner shall have the right to effect the removal of any of the Consultant’s employees at any time during the duration of the AGREEMENT if that employee is deemed not to be of the level of competence or ability required under the AGREEMENT, or said employee is for any reason found to be unsuitable for the work. In such case, the Consultant shall promptly submit the name and qualifications of a replacement for approval by the Owner.
B.1.4 The Owner shall have the right to assign the administration of any or all contracts related to this project from the Owner to another State Agency, Authority or Commission at any time during the life of the project. In doing so, the Consultant agrees to continue to perform all contractual work under the AGREEMENT. The Consultant shall make no claim against the Owner in the event of such assignment.
B.1.5 The Owner may make changes in the scope of services within the general scope of the AGREEMENT. The Owner may also make changes to the scope of the project which may give rise to changes in the scope of the Consultant services. In such case, the Consultant shall be entitled to an adjustment in fee and in other terms and conditions of the AGREEMENT.
Right to Proceed The Sponsor acknowledges the rights of Holders to institute a Direct Action as set forth in Section 2.8(d) hereto.
Obligation to Provide Information Each party’s obligation to provide information shall be as follows:
(a) TAM shall cause the Subadviser to be kept fully informed at all times with regard to the securities owned by the Fund, its funds available, or to become available, for investment, and generally as to the condition of the Fund’s affairs. TAM shall furnish the Subadviser with such other documents and information with regard to the Fund’s affairs as the Subadviser may from time to time reasonably request.
(b) The Subadviser, at its expense, shall supply the Board, the officers of the Trust and TAM with all information and reports reasonably required by them and reasonably available to the Subadviser relating to the services provided by the Subadviser hereunder, including such information the Fund’s Chief Compliance Officer reasonably believes necessary for compliance with Rule 38a-1 under the 1940 Act.
OWNER’S RIGHT TO CARRY OUT THE WORK If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten (10)-calendar day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner’s expenses and compensation for the Architect’s additional services made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner.
Agreement to Provide Information Intermediary agrees to provide the Fund, upon written request, the taxpayer identification number (“TIN”), the Individual Taxpayer Identification Number (“ITIN”), or other government-issued identifier (“GII”), if known, of any or all Shareholder(s) of the account and the amount, date, name or other identifier of any investment professional(s) associated with the Shareholder(s) or account (if known), and transaction type (purchase, redemption, transfer, or exchange) of every purchase, redemption, transfer, or exchange of Shares held through each account maintained by the Intermediary during the period covered by the request.
Owners Required To Provide Information From the Initial Date and prior to the Restriction Termination Date:
(a) every owner of five percent or more (or such lower percentage as required by the Code or the U.S. Treasury Department regulations promulgated thereunder) of the Outstanding Shares, within 30 days after the end of each taxable year, shall give written notice to the Company stating the name and address of such owner, the number of Shares of each class and series Beneficially Owned and a description of the manner in which such Shares are held. Each such owner shall promptly provide to the Company in writing such additional information as the Company may request in order to determine the effect, if any, of such Beneficial Ownership on the Company’s qualification as a REIT and to ensure compliance with the Ownership Limits; and
(b) each Person who is a Beneficial Owner or Constructive Owner of Shares and each Person (including the Member of record) who is holding Shares for a Beneficial Owner or Constructive Owner shall promptly provide to the Company in writing such information as the Company may request, in good faith, in order to determine the Company’s qualification as a REIT and to comply with the requirements of any taxing authority or governmental authority or to determine such compliance.
Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.
Right to Insure The Company shall have the right to secure, in its own name or otherwise, and at its own expense, life, health, accident or other insurance covering Executive, and Executive shall have no right, title or interest in and to such insurance. Executive shall assist the Company in procuring such insurance by submitting to examinations and by signing such applications and other instruments as may be required by the insurance carriers to which application is made for any such insurance.
