Claims relating to Intellectual Property Rights 29.1. The Contractor must not infringe any Intellectual Property Rights of any third party in providing the Services or otherwise performing its obligations under the Framework Agreement and must ensure that the provision of the Services and the use or possession of the Deliverables does not infringe such Intellectual Property Rights.
29.2. The Contractor must promptly notify the Authority if any claim or demand is made or action brought against the Contractor for infringement or alleged infringement of any Intellectual Property Right which may affect the use or possession of the Deliverables or which may affect the provision of the Services.
29.3. Where a claim to which this clause applies is made, the Contractor must, at its expense, use its best endeavours to:
29.3.1. modify the Services or Deliverables or substitute alternative Services or Deliverables (in any case without reducing performance or functionality) so as to avoid the infringement or alleged infringement of the Intellectual Property Rights; or
29.3.2. procure the grant of a licence or licences from the pursuer, claimant or complainer, on terms acceptable to the Authority, so as to avoid the infringement or alleged infringement of the Intellectual Property Rights of the pursuer, claimant or complainer.
29.4. The Contractor must not without the consent of the Authority make any admissions which may be prejudicial to the defence or settlement of any claim to which this clause applies.
INDEMNIFICATION RELATING TO THIRD PARTY RIGHTS The Contractor will also indemnify and hold the Authorized Users harmless from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities and costs that may be finally assessed against the Authorized Users in any action for infringement of a United States Letter Patent, or of any copyright, trademark, trade secret or other third party proprietary right except to the extent such claims arise from the Authorized Users gross negligence or willful misconduct, provided that the State shall give Contractor: (i) prompt written notice of any action, claim or threat of infringement suit, or other suit, (ii) the opportunity to take over, settle or defend such action, claim or suit at Contractor's sole expense, and (iii) assistance in the defense of any such action at the expense of Contractor. If usage shall be enjoined for any reason or if Contractor believes that it may be enjoined, Contractor shall have the right, at its own expense and sole discretion to take action in the following order of precedence: (i) to procure for the Authorized User the right to continue Usage (ii) to modify the service or Product so that Usage becomes non-infringing, and is of at least equal quality and performance; or (iii) to replace said service or Product or part(s) thereof, as applicable, with non-infringing service or Product of at least equal quality and performance. If the above remedies are not available, the parties shall terminate the Contract, in whole or in part as necessary and applicable, provided the Authorized User is given a refund for any amounts paid for the period during which Usage was not feasible. The foregoing provisions as to protection from third party rights shall not apply to any infringement occasioned by modification by the Authorized User of any Product without Contractor’s approval. In the event that an action at law or in equity is commenced against the Authorized User arising out of a claim that the Authorized User's use of the service or Product under the Contract infringes any patent, copyright or proprietary right, and Contractor is of the opinion that the allegations in such action in whole or in part are not covered by the indemnification and defense provisions set forth in the Contract, Contractor shall immediately notify the Authorized User and the Office of the Attorney General in writing and shall specify to what extent Contractor believes it is obligated to defend and indemnify under the terms and conditions of the Contract. Contractor shall in such event protect the interests of the Authorized User and secure a continuance to permit the Authorized User to appear and defend its interests in cooperation with Contractor, as is appropriate, including any jurisdictional defenses the Authorized User may have. This constitutes the Authorized User’s sole and exclusive remedy for patent infringement, or for infringement of any other third party proprietary right.
Procedures Relating to Indemnification (a) If a claim or demand is made against an Indemnitee, or an Indemnitee shall otherwise learn of an assertion, by any Person who is not a party to this Agreement (or an Affiliate thereof) as to which an Indemnifying Party may be obligated to provide indemnification pursuant to this Agreement (a "Third Party Claim"), such Indemnitee will notify the Indemnifying Party in writing, and in reasonable detail, of the Third Party Claim reasonably promptly after becoming aware of such Third Party Claim; provided, however, that failure to give such notification will not affect the indemnification provided hereunder except to the extent the Indemnifying Party shall have been actually prejudiced as a result of such failure. Thereafter, the Indemnitee will deliver to the Indemnifying Party, promptly after the Indemnitee's receipt thereof, copies of all material notices and documents (including court papers) received or transmitted by the Indemnitee relating to the Third Party Claim.
(b) If a Third Party Claim is made against an Indemnitee, the Indemnifying Party will be entitled to participate in or to assume the defense thereof (in either case, at the expense of the Indemnifying Party) with counsel selected by the Indemnifying Party and reasonably satisfactory to the Indemnitee. Should the Indemnifying Party so elect to assume the defense of a Third Party Claim, the Indemnifying Party will not be liable to the Indemnitee for any legal or other expenses subsequently incurred by the Indemnitee in connection with the defense thereof; provided, that if in the Indemnitee's reasonable judgment a conflict of interest exists in respect of such claim or if the Indemnifying Party shall have assumed responsibility for such claim with any reservations or exceptions, such Indemnitee will have the right to employ separate counsel reasonably satisfactory to the Indemnifying Party to represent such Indemnitee and in that event the reasonable fees and expenses of such separate counsel (but not more than one separate counsel for all Indemnitees similarly situated) shall be paid by such Indemnifying Party. If the Indemnifying Party assumes the defense of any Third Party Claim, the Indemnitee will have the right to participate in the defense thereof and to employ counsel, at its own expense, separate from the counsel employed by the Indemnifying Party, it being understood that the Indemnifying Party will control such defense. The Indemnifying Party will be liable for the fees and expenses of counsel employed by the Indemnitee for any period during which the Indemnifying Party has failed to assume the defense thereof. If the Indemnifying Party assumes the defense of any Third Party Claim, the Indemnifying Party will promptly supply to the Indemnitee copies of all material correspondence and documents relating to or in connection with such Third Party Claim and keep the Indemnitee fully informed of all material developments relating to or in connection with such Third Party Claim (including providing to the Indemnitee on request updates and summaries as to the status thereof). If the Indemnifying Party chooses to defend a Third Party Claim, the parties hereto will cooperate in the defense thereof (such cooperation to be at the expense, including reasonable legal fees and expenses, of the Indemnifying Party), which cooperation shall include the retention in accordance with this Agreement and (upon the Indemnifying Party's request) the provision to the Indemnifying Party of records and information which are reasonably relevant to such Third Party Claim, and making employees available on a mutually convenient basis to provide additional information and explanation of any material provided hereunder.
(c) No Indemnifying Party will consent to any settlement, compromise or discharge (including the consent to entry of any judgment) of any Third Party Claim without the Indemnitee's prior written consent (which consent will not be unreasonably withheld); provided, that if the Indemnifying Party assumes the defense of any Third Party Claim, the Indemnitee will agree to any settlement, compromise or discharge of such Third Party Claim which the Indemnifying Party may recommend and which by its terms obligates the Indemnifying Party to pay the full amount of Indemnifiable Losses in connection with such Third Party Claim and unconditionally and irrevocably releases the Indemnitee and its Affiliates completely from all Liability in connection with such Third Party Claim; provided, however, that the Indemnitee may refuse to agree to any such settlement, compromise or discharge (x) that provides for injunctive or other nonmonetary relief affecting the Indemnitee or any of its Affiliates or (y) that, in the reasonable opinion of the Indemnitee, would otherwise materially adversely affect the Indemnitee or any of its Affiliates. Whether or not the Indemnifying Party shall have assumed the defense of a Third Party Claim, the Indemnitee will not (unless required by law) admit any liability with respect to, or settle, compromise or discharge, such Third Party Claim without the Indemnifying Party's prior written consent (which consent will not be unreasonably withheld).
(d) Any claim on account of Indemnifiable Losses which does not involve a Third Party Claim will be asserted by reasonably prompt written notice given by the Indemnitee to the Indemnifying Party from whom such indemnification is sought. The failure by any Indemnitee so to notify the Indemnifying Party will not relieve the Indemnifying Party from any liability which it may have to such Indemnitee under this Agreement, except to the extent that the Indemnifying Party shall have been actually prejudiced by such failure.
(e) In the event of payment in full by an Indemnifying Party to any Indemnitee in connection with any Third Party Claim, such Indemnifying Party will be subrogated to and shall stand in the place of such Indemnitee as to any events or circumstances in respect of which such Indemnitee may have any right or claim relating to such Third Party Claim against any claimant or plaintiff asserting such Third Party Claim or against any other Person. Such Indemnitee will cooperate with such Indemnifying Party in a reasonable manner, and at the cost and expense of such Indemnifying Party, in prosecuting any subrogated right or claim.
Certain Matters Relating to Accounts (a) At any time after the occurrence and during the continuance of an Event of Default and after giving reasonable notice to the Borrower and any other relevant Grantor, the Administrative Agent shall have the right, but not the obligation, to instruct the Collateral Agent to (and upon such instruction, the Collateral Agent shall) make test verifications of the Accounts in any manner and through any medium that the Administrative Agent reasonably considers advisable, and each Grantor shall furnish all such assistance and information as the Collateral Agent may require in connection with such test verifications. The Collateral Agent shall have the absolute right to share any information it gains from such inspection or verification with any Secured Party.
(b) The Collateral Agent hereby authorizes each Grantor to collect such Grantor’s Accounts and the Collateral Agent may curtail or terminate said authority at any time after the occurrence and during the continuance of an Event of Default. If required in writing by the Collateral Agent at any time after the occurrence and during the continuance of an Event of Default, any payments of Accounts, when collected by any Grantor, (i) shall be forthwith (and, in any event, within two Business Days) deposited by such Grantor in the exact form received, duly endorsed by such Grantor to the Collateral Agent if required, in a Collateral Account maintained under the sole dominion and control of and on terms and conditions reasonably satisfactory to the Collateral Agent, subject to withdrawal by the Collateral Agent for the account of the Secured Parties only as provided in Section 5.5 and (ii) until so turned over, shall be held by such Grantor in trust for the Collateral Agent and the Secured Parties, segregated from other funds of such Grantor. Each such deposit of Proceeds of Accounts shall be accompanied by a report identifying in reasonable detail the nature and source of the payments included in the deposit.
(c) At the Collateral Agent’s request at any time after the occurrence and during the continuance of an Event of Default, subject to the terms of the Intercreditor Agreements, each Grantor shall deliver to the Collateral Agent all original and other documents evidencing, and relating to, the agreements and transactions which gave rise to the Accounts, including all original orders, invoices and shipping receipts.
(d) Upon the occurrence and during the continuance of an Event of Default, a Grantor shall not grant any extension of the time of payment of any of the Accounts, compromise, compound or settle the same for less than the full amount thereof, release, wholly or partly, any Person liable for the payment thereof, or allow any credit or discount whatsoever thereon if the Collateral Agent shall have instructed the Grantors not to grant or make any such extension, credit, discount, compromise or settlement under any circumstances during the continuance of such Event of Default.
(e) At the direction of the Collateral Agent, solely upon the occurrence and during the continuance of an Event of Default, subject to the terms of the Intercreditor Agreements, each Grantor shall grant to the Collateral Agent to the extent assignable, a non-exclusive, fully paid-up, royalty-free, worldwide license to use, assign, license or sublicense any of the Intellectual Property included in the Collateral and now owned or hereafter acquired by such Grantor (subject to the rights of any person or entity under any pre-existing Copyright License, Patent License, Trademark License or other agreements). Such license shall include access to all media in which any of the licensed items may be recorded or stored and to all computer programs used for the compilation or printout thereof; provided, however, that nothing in this Section 5.1 shall require any Grantor to grant any license that is prohibited by any rule of law, statute or regulation or is prohibited by, or constitutes a breach of default under or results in the termination of or gives rise to any right of acceleration, modification or cancellation under any contract, license, agreement, instrument or other document evidencing, giving rise to a right to use or theretofore granted with respect to such property, provided, further, that such licenses to be granted hereunder with respect to Trademarks shall be subject to the quality control standards applicable to each such Trademark as in effect as of the date such licenses hereunder are granted.
Covenants Relating to Conduct of Business (a) Except for matters set forth in Schedule 4.01 or otherwise expressly permitted by the terms of this Agreement, from the date hereof to the Closing, each Parent Party shall cause its respective Existing Business to be conducted in the usual, regular and ordinary course in substantially the same manner as previously conducted (including with respect to advertising, promotions, capital expenditures and inventory levels) and use all reasonable efforts to keep intact the respective businesses of such Parent Party's Existing Business, keep available the services of their current employees and preserve their relationships with customers, suppliers, licensors, licensees, distributors and others with whom they deal to the end that their respective businesses shall be unimpaired at the Closing. Each Parent Party shall not, and shall not permit any of its Affiliates to, take any action that would, or that could reasonably be expected to, result in any of the conditions set forth in Article V not being satisfied. In addition (and without limiting the generality of the foregoing), except as set forth in Schedule 4.01 or otherwise expressly permitted or required by the terms of this Agreement, each Parent Party shall not, and shall not permit any of its Affiliates to, do any of the following in connection with its Existing Business without the prior written consent of the other Parent Party:
(i) with respect to any of its Contributed Subsidiaries, amend its Organizational Documents, except as is necessary to consummate the Transactions;
(ii) other than sweeping cash in the ordinary course of business consistent with past practice, make any declaration or payment of any dividend or any other distribution in respect of its equity interest in any Contributed Subsidiary;
(iii) with respect to any of its Contributed Subsidiaries, redeem or otherwise acquire any shares of its capital stock or issue any capital stock (except upon the exercise of outstanding options) or any option, warrant or right relating thereto or any securities convertible into or exchangeable for any shares of such capital stock;
(iv) incur or assume any indebtedness for borrowed money or guarantee any such indebtedness in connection with its Existing Business;
(v) permit, allow or suffer any Contributed Assets to become subjected to any Lien of any nature whatsoever, except Permitted Liens;
(vi) cancel any material indebtedness (individually or in the aggregate) or waive any claims or rights of substantial value relating to its Existing Business;
(vii) except for intercompany loans among Contributed Subsidiaries in the ordinary course of business or transactions in the ordinary course, consistent with past practice and not material in amount, pay, loan or advance any amount to, or sell, transfer or lease any of its assets to, or enter into any agreement or arrangement with any of its Affiliates;
(viii) make any change in any method of financial accounting or financial accounting practice or policy of its Existing Business other than those required by generally accepted accounting principles;
(ix) make any change in the methods or timing of collecting receivables or paying payables with respect to its Existing Business;
(x) other than in the ordinary course of business, make or incur any capital expenditure in connection with its Existing Business that is not currently approved in writing or budgeted;
(xi) sell, lease, license or otherwise dispose of any of the assets of its Existing Business, except inventory, programming or other goods or services sold in the ordinary course of business consistent with past practice; or
(xii) authorize any of, or commit or agree to take, whether in writing or otherwise, to do any of, the foregoing actions.
(b) Except as set forth in Schedule 4.01 or otherwise expressly permitted by the terms of this Agreement or any ancillary agreements that may be entered into in connection with the Transactions, USAi shall not, and shall not permit any of its Affiliates to:
(i) adopt or amend any USAi Benefit Arrangement (or any plan or arrangement that would be an USAi Benefit Arrangement if adopted) relating primarily to its Existing Business or enter into, adopt, extend (beyond the Closing Date), renew or amend any collective bargaining agreement or other Contract relating to its Existing Business with any labor organization, union or association, except in each case, in the ordinary course of business and consistent with past practice or as required by Applicable Law; or
(ii) (A) grant to any USAi Business Employee any increase in compensation or benefits, except grants in the ordinary course of business and consistent with past practice or as may be required under agreements in existence on the date of this Agreement or (B) grant new options or restricted stock to any USAi Business Employee except as may be required under agreements in existence on the date of this Agreement.
(c) Each Parent Party shall promptly advise the other Parent Party in writing of the occurrence of any matter or event that is material to the business, assets, financial condition, or results of operations of its Existing Business, taken as a whole.
(d) Notwithstanding any other provision of this Agreement, following the date hereof, each Parent Party shall manage its cash (including any sweeps thereof), payables and receivables relating to its Existing Business in each case in the ordinary course of business and consistent with past practice.
Representations Relating to Documents and Legal Compliance Borrower represents and warrants to Silicon as follows: All statements made and all unpaid balances appearing in all invoices, instruments and other documents evidencing the Receivables are and shall be true and correct and all such invoices, instruments and other documents and all of Borrower's books and records are and shall be genuine and in all respects what they purport to be, and all signatories and endorsers have the capacity to contract. All sales and other transactions underlying or giving rise to each Receivable shall fully comply with all applicable laws and governmental rules and regulations. All signatures and endorsements on all documents, instruments, and agreements relating to all Receivables are and shall be genuine, and all such documents, instruments and agreements are and shall be legally enforceable in accordance with their terms.
Schedules and Documents Relating to Accounts Borrower shall deliver to Bank transaction reports and schedules of collections, as provided in Section 6.2, on Bank’s standard forms; provided, however, that Borrower’s failure to execute and deliver the same shall not affect or limit Bank’s Lien and other rights in all of Borrower’s Accounts, nor shall Bank’s failure to advance or lend against a specific Account affect or limit Bank’s Lien and other rights therein. If requested by Bank, Borrower shall furnish Bank with copies (or, at Bank’s request, originals) of all contracts, orders, invoices, and other similar documents, and all shipping instructions, delivery receipts, bills of lading, and other evidence of delivery, for any goods the sale or disposition of which gave rise to such Accounts. In addition, Borrower shall deliver to Bank, on its request, the originals of all instruments, chattel paper, security agreements, guarantees and other documents and property evidencing or securing any Accounts, in the same form as received, with all necessary indorsements, and copies of all credit memos.
INDEMNIFICATION RELATING TO INFRINGEMENT The Contractor will also defend, indemnify and hold the Authorized Users harmless from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities and costs in any action for infringement of a patent, copyright, trademark, trade secret or other proprietary right provided: a) such claim arises solely out of the Products as supplied by the Contractor, and not out of any modification to the Products made by Authorized User or by someone other than Contractor at the direction of the Authorized User without Contractor’s approval, or by reason of an off-the-shelf component; and b) Authorized User gives Contractor prompt written notice of any such action, claim suit or threat of suit alleging infringement. The Authorized User shall give Contractor the opportunity to take over, settle or defend such action, claim or suit at Contractor's sole expense, and to provide assistance in the defense of any such action, claim or suit at the expense of Contractor. Such indemnity shall only be applicable in the event of claims, judgments, liabilities and/or costs that may be finally assessed against Authorized User in any action for infringement of a patent, or of any copyright, trademark, trade secret or other third party proprietary right except to the extent such claims, judgments, liabilities and/or costs arise solely from the Authorized Users negligent act, failure to act, gross negligence or willful misconduct. If usage of a Product shall be enjoined for any reason or if Contractor believes that it may be enjoined, Contractor shall have the right, at its own expense and sole discretion to take action in the following order of precedence: (i) to procure for the Authorized User the right to continue usage (ii) to modify the service or Product so that usage becomes non-infringing, and is of at least equal quality and performance; or (iii) to replace such Product or parts thereof, as applicable, with non-infringing Product of at least equal quality and performance. If the above remedies are not available, the parties shall terminate the Contract, in whole or in part as necessary and applicable, provided that the Authorized User is given a refund for any amounts paid for the period during which usage was not feasible. In the event that an action at law or in equity is commenced against the Authorized User arising out of a claim that the Authorized User's use of the Product under the Contract infringes any patent, copyright, trademark, trade secret or proprietary right, and Contractor is of the opinion that the allegations in such action in whole or in part are not covered by the indemnification and defense provisions set forth in the Contract, Contractor shall immediately notify the Authorized User and the Office of the Attorney General in writing and shall specify to what extent Contractor believes it is obligated to defend and indemnify under the terms and conditions of the Contract and to what extent it is not so obligated to defend and indemnify. Contractor shall in such event protect the interests of the Authorized User and seek to secure a continuance to permit the Authorized User to appear and defend their interests in cooperation with Contractor, as is appropriate, including any jurisdictional defenses the Authorized User may have. This constitutes the Authorized User’s sole and exclusive remedy for patent infringement, or for infringement of any other third party proprietary right.
Standard of Care; Uncontrollable Events; Limitation of Liability SMC shall use reasonable professional diligence to ensure the accuracy of all services performed under this Agreement, but shall not be liable to the Company for any action taken or omitted by SMC in the absence of bad faith, willful misfeasance, negligence or reckless disregard by it of its obligations and duties. The duties of SMC shall be confined to those expressly set forth herein, and no implied duties are assumed by or may be asserted against SMC hereunder. SMC shall maintain adequate and reliable computer and other equipment necessary or appropriate to carry out its obligations under this Agreement. Upon the Company's reasonable request, SMC shall provide supplemental information concerning the aspects of its disaster recovery and business continuity plan that are relevant to the services provided hereunder. Notwithstanding the foregoing or any other provision of this Agreement, SMC assumes no responsibility hereunder, and shall not be liable for, any damage, loss of data, delay or any other loss whatsoever caused by events beyond its reasonable control. Events beyond SMC's reasonable control include, without limitation, force majeure events. Force majeure events include natural disasters, actions or decrees of governmental bodies, and communication lines failures that are not the fault of either party. In the event of force majeure, computer or other equipment failures or other events beyond its reasonable control, SMC shall follow applicable procedures in its disaster recovery and business continuity plan and use all commercially reasonable efforts to minimize any service interruption. SMC shall provide the Company, at such times as the Company may reasonably require, copies of reports rendered by independent public accountants on the internal controls and procedures of SMC relating to the services provided by SMC under this Agreement. Notwithstanding anything in this Agreement to the contrary, in no event shall SMC, its affiliates or any of its or their directors, officers, employees, agents or subcontractors be liable for exemplary, punitive, special, incidental, indirect or consequential damages, or lost profits, each of which is hereby excluded by agreement of the parties regardless of whether such damages were foreseeable or whether either party or any entity has been advised of the possibility of such damages.
Covenants Relating to Rule 144 For so long as the Company is subject to the reporting requirements of Section 13 or 15 of the Securities Act, the Company covenants that it will file the reports required to be filed by it under the Securities Act and Section 13(a) or 15(d) of the Exchange Act and the rules and regulations adopted by the Commission thereunder. If the Company ceases to be so required to file such reports, the Company covenants that it will upon the request of any Holder of Registrable Securities (a) make publicly available such information as is necessary to permit sales pursuant to Rule 144 under the Securities Act, (b) deliver such information to a prospective purchaser as is necessary to permit sales pursuant to Rule 144A under the Securities Act and it will take such further action as any Holder of Registrable Securities may reasonably request, and (c) take such further action that is reasonable in the circumstances, in each case, to the extent required, from time to time, to enable such Holder to sell its Registrable Securities without registration under the Securities Act within the limitation of the exemptions provided by (i) Rule 144 under the Securities Act, as such Rule may be amended from time to time, (ii) Rule 144A under the Securities Act, as such rule may be amended from time to time, or (iii) any similar rules or regulations hereafter adopted by the Commission. Upon the request of any Holder of Registrable Securities, the Company will deliver to such Holder a written statement as to whether it has complied with such requirements and of the Securities Act and the Exchange Act (at any time after it has become subject to the reporting requirements of the Exchange Act), a copy of the most recent annual and quarterly report(s) of the Company, and such other reports, documents or stockholder communications of the Company, and take such further actions consistent with this Section 8(a), as a Holder may reasonably request in availing itself of any rule or regulation of the Commission allowing a Holder to sell any such Registrable Securities without registration.
