Ownership of Successful Respondent Owned Materials Sample Clauses

Ownership of Successful Respondent Owned Materials. As between the Parties, Successful Respondent shall be the sole and exclusive owner of the (i) Materials and other intellectual property lawfully owned by it or its Affiliates prior to the Effective Date, (ii) Materials and other intellectual property acquired by Successful Respondent or its Affiliates on or after the Effective Date (including any such Materials and intellectual property purchased from DIR pursuant to this Agreement) other than Materials and other intellectual property obtained by Successful Respondent or its Affiliates from third parties specifically for or on behalf of DIR or a DIR Customer, (iii) certain Developed Materials as provided in Sections 14.2(c) and 14.2(d), and (iv) Materials and other intellectual property that are not developed by or on behalf of Successful Respondent pursuant to this Agreement or otherwise paid for by DIR or any DIR Customer under this Agreement (collectively, "Successful Respondent Owned Materials"), including all United States and foreign patent, copyright, trade secret and other intellectual property rights in the Successful Respondent Owned Materials.
Sample 1Sample 2
AutoNDA by SimpleDocs

Related to Ownership of Successful Respondent Owned Materials

  • Presentation of Potential Target Businesses The Company shall cause each of the Initial Shareholders to agree that, in order to minimize potential conflicts of interest which may arise from multiple affiliations, the Initial Shareholders will present to the Company for its consideration, prior to presentation to any other person or company, any suitable opportunity to acquire an operating business, until the earlier of the consummation by the Company of a Business Combination or the liquidation of the Company, subject to any pre-existing fiduciary obligations the Initial Shareholders might have.

  • Procedure for Third Party Claims The obligations and liabilities of each Party with respect to Third-Party Claims shall be subject to the following terms and conditions: (i) Promptly upon receiving a written notice of a Third-Party Claim, the Indemnifying Party may elect, at its sole option, to undertake the defense thereof by outside counsel of its own choosing, which outside counsel shall be reasonably satisfactory to the Indemnified Party, by sending written notice of its election to the Indemnified Party; provided however, that if, in the Indemnified Party’s and the Indemnifying Party’s reasonable judgment, a conflict of interest exists between the Indemnified Party and the Indemnifying Party with respect to such Third-Party Claim, or if the Indemnifying Party elects not to defend or otherwise does not promptly defend such Third-Party Claim, such Indemnified Party shall be entitled to undertake the defense of, and to compromise or settle, such Third-Party Claim on behalf, for the account, and at the risk of the Indemnifying Party, to the extent that the Indemnifying Party is determined to be obligated to indemnify the Indemnified Party under this Agreement with respect to such Third-Party Claim. The written notice of the Third-Party Claim shall contain all material information known to the Indemnified Party with respect to such Third-Party Claim and shall include copies of materials submitted to Indemnified Party by the Third-Party with respect to such Third-Party Claim. (ii) If the Indemnifying Party elects to undertake and diligently pursue the defense of a Third-Party Claim hereunder, the Indemnifying Party shall control all aspects of the defense and settlement of such Third-Party Claim and may settle, compromise or enter into a judgment with respect to such Third-Party Claim; provided that the Indemnifying Party shall not enter into any such settlement, compromise or judgment without the prior written consent of the Indemnified Party if such settlement, compromise or judgment would result in the imposition of any non-monetary liability or obligation on the Indemnified Party. If the Indemnifying Party assumes control of the defense under this Article 9, the Indemnified Party shall fully cooperate with the Indemnifying Party in connection therewith and may employ, at any time, a separate outside counsel to represent it; provided however, that the Indemnified Party shall be solely responsible for the costs and expenses of any such separate outside counsel. If the Indemnified Party undertakes the defense of a Third-Party Claim hereunder, the Indemnified Party shall not settle, compromise, or enter into any judgment with respect to such Third-Party Claim for which it is seeking or shall seek indemnification hereunder without the prior written consent of Indemnifying Party, which written consent shall not be unreasonably withheld, conditioned or delayed. (iii) The Indemnified Party shall provide the Indemnifying Party with access to all reasonably requested records and documents of the Indemnified Party relating to any Third-Party Claim, other than documents for which the Indemnified Party has claimed or shall claim a legal privilege.

  • Definition of Hazardous Materials For purposes of this Lease, the term “Hazardous Material” or “Hazardous Materials” shall mean any hazardous or toxic substance, material, product, byproduct, or waste, which is or shall become regulated by any governmental entity, including, without limitation, the County acting in its governmental capacity, the State of California or the United States government.

  • Convicted, Discriminatory, Antitrust Violator, and Suspended Vendor Lists In accordance with sections 287.133, 287.134, and 287.137, F.S., the Contractor is hereby informed of the provisions of sections 287.133(2)(a), 287.134(2)(a), and 287.137(2)(a), F.S. For purposes of this Contract, a person or affiliate who is on the Convicted Vendor List, the Discriminatory Vendor List, or the Antitrust Violator Vendor List may not perform work as a contractor, supplier, subcontractor, or consultant under the Contract. The Contractor must notify the Department if it or any of its suppliers, subcontractors, or consultants have been placed on the Convicted Vendor List, the Discriminatory Vendor List, or the Antitrust Violator Vendor List during the term of the Contract. In accordance with section 287.1351, F.S., a vendor placed on the Suspended Vendor List may not enter into or renew a contract to provide any goods or services to an agency after its placement on the Suspended Vendor List. A firm or individual placed on the Suspended Vendor List pursuant to section 287.1351, F.S., the Convicted Vendor List pursuant to section 287.133, F.S., the Antitrust Violator Vendor List pursuant to section 287.137, F.S., or the Discriminatory Vendor List pursuant to section 287.134, F.S., is immediately disqualified from Contract eligibility.

  • Procedures for Third Party Claims In the case of any claim for indemnification arising from a claim of a third-party other than an Infringement Claim subject to Section 13.3 above (a “Third-Party Claim”), a party seeking indemnification hereunder (each an “Indemnified Party”) shall give prompt written notice, following such Indemnified Party’s receipt of such claim or demand, to the party from which indemnity is sought (each an “Indemnifying Party”) of any claim or demand of which such Indemnified Party has knowledge and as to which it may request indemnification hereunder; provided, however, that failure to give such notice will not affect such Indemnified Party’s rights hereunder unless, and then solely to the extent that, the rights of the Indemnifying Parties from whom indemnity is sought are prejudiced as a result of such failure. The Indemnifying Party shall have the right (and if it elects to exercise such right, shall do so within twenty (20) days after receiving such notice from the Indemnified Party) to defend and to direct the defense against any such claim or demand, in its name or in the name of the Indemnified Party, as the case may be, at the expense of the Indemnifying Party, and with counsel selected by the Indemnifying Party; provided, that the Indemnifying Party shall be entitled to assume control of the defense of such action only if the Indemnifying Party acknowledges in writing its indemnity obligations and assumes and holds the Indemnified Party harmless from and against all Losses resulting from such Third-Party Claim; and provided further that the Indemnifying Party shall not be entitled to assume control of such defense if (i) the Indemnifying Party shall not have notified the Indemnified Party of its exercise of its right to defend such Third-Party claim within such twenty (20) day period; (ii) such claim or demand seeks an injunction or other equitable relief against the Indemnified Party, (iii) the Indemnified Party shall have reasonably concluded that (x) there is a conflict of interest between the Indemnified Party and the Indemnifying Party in the conduct of the defense of such claim or demand or (y) the Indemnified Party has one or more defenses not available to the Indemnifying Party, (iv) such claim relates to or arises in connection with any criminal proceeding, action, indictment, allegation or investigation, or (v) the appropriate court rules that the Indemnifying Party failed or is failing to vigorously prosecute or defend such Third-Party Claim. Notwithstanding anything in this Agreement to the contrary, the Indemnified Party shall, at the expense of the Indemnifying Party, cooperate with the Indemnifying Party, and keep the Indemnifying Party fully informed, in the defense of such claim or demand. The Indemnified Party shall have the right to participate in the defense of any claim or demand with counsel employed at its own expense; provided, however, that, in the case of any claim or demand described in clause (i) or (ii) of the second preceding sentence or as to which the Indemnifying Party shall not in fact have employed counsel to assume the defense of such claim or demand, the reasonable fees and disbursements of such counsel shall be at the expense of the Indemnifying Party. The Indemnifying Party shall have no indemnification obligations with respect to any such claim or demand which shall be settled by the Indemnified Party without the prior written consent of the Indemnifying Party, which consent shall not be unreasonably withheld, delayed or conditioned. The Indemnifying Party shall not settle any such claim without the prior written consent of the Indemnified Party (which consent shall not be unreasonably withheld, delayed or conditioned if such settlement is accompanied by a document releasing the Indemnified Party from all liability with respect to the matter in controversy that is binding, valid and enforceable against all applicable Parties). Notwithstanding the foregoing, if the Indemnified Party fails to object to the settlement within five (5) Business Days of receipt of a written notice from the Indemnifying Party containing the terms and condition of such settlement, the Indemnified Party shall be deemed to have consented to the settlement.

  • Use of Hazardous Materials Tenant shall not cause or permit any Hazardous Materials to be used, stored, discharged, released or disposed of in the Premises or cause any Hazardous Materials to be used, stored, discharged, released or disposed of in, from, under or about, the Property, or any other land or improvements in the vicinity of the Property, excepting only the types and minor quantities of Hazardous Materials which are normally used in connection with Tenant’s permitted use, operation and maintenance of the Premises and then only in strict accordance with all Legal Requirements, including all Environmental Laws (“Permitted Substances”). Tenant shall, at its own expense, procure, maintain in effect and comply with all conditions of any and all permits, licenses, and other governmental and regulatory approvals required for Tenant’s use of Hazardous Materials at the Premises, including, without limitation, discharge of appropriately treated materials or wastes into or through any sanitary sewer serving the Building. Tenant shall in all respects handle, treat, deal with and manage any and all Tenant’s Hazardous Materials in total conformity with all Environmental Laws and prudent industry practices regarding management of such Hazardous Materials. Without limiting the foregoing, if any Tenant’s Hazardous Materials result in contamination of the Building, or any soil or groundwater in, under or about the Property in each case to the extent the presence of same amounts to a violation of any Legal Requirement or poses a threat to human health or safety, Tenant, at its expense, shall promptly take all actions necessary to return the Building and/or the Property, to the condition existing prior to the appearance of the Tenant’s Hazardous Material, subject to Landlord’s right to approve Tenant’s proposed remediation method. On or prior to the Termination Date, Tenant shall cause all Tenant’s Hazardous Materials in, on, under or about the Building to be removed in accordance with and in compliance with all Legal Requirements. Tenant shall promptly notify Landlord and obtain Landlord’s written approval before taking any remedial action in response to the presence of any Tenant’s Hazardous Materials or entering into any settlement agreement, consent decree or other compromise with respect to any claims relating to Tenant’s Hazardous Materials.

  • Definition of a Grievance A grievance is defined as a dispute or disagreement as to the interpretation or application of the specific terms and conditions of this AGREEMENT.

  • Timely and Sustained Response Interconnection Customer shall ensure that the Small Generating Facility’s real power response to sustained frequency deviations outside of the deadband setting is automatically provided and shall begin immediately after frequency deviates outside of the deadband, and to the extent the Small Generating Facility has operating capability in the direction needed to correct the frequency deviation. Interconnection Customer shall not block or otherwise inhibit the ability of the governor or equivalent controls to respond and shall ensure that the response is not inhibited, except under certain operational constraints including, but not limited to, ambient temperature limitations, physical energy limitations, outages of mechanical equipment, or regulatory requirements. The Small Generating Facility shall sustain the real power response at least until system frequency returns to a value within the deadband setting of the governor or equivalent controls. An Applicable Reliability Standard with equivalent or more stringent requirements shall supersede the above requirements.

  • Ownership of Merger Sub; No Prior Activities (a) Merger Sub was formed solely for the purpose of engaging in the transactions contemplated by this Agreement. (b) Except for obligations or liabilities incurred in connection with its incorporation or organization and the transactions contemplated by this Agreement, Merger Sub has not and will not prior to the Closing Date have incurred, directly or indirectly, through any Subsidiary or affiliate, any obligations or liabilities or engaged in any business activities of any type or kind whatsoever or entered into any agreements or arrangements with any Person.

  • Reactive Power and Primary Frequency Response 9.6.1 Power Factor Design Criteria

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!