Packet Delivery SLA. The Packet Delivery SLA is based on the percentage of packets that are able to traverse the Service. If packets are completely unable to traverse Service (packet delivery is 0%) “
Packet Delivery SLA Sample Clauses
Related to Packet Delivery SLA
Delivery Schedule The Goods specified in the List of Goods are required to be delivered within the acceptable time range (after the earliest and before the final date, both dates inclusive) specified in Section V, Schedule of Requirements. No credit will be given to deliveries before the earliest date, and Tenders offering delivery after the final date shall be treated as non-responsive. Within this acceptable period, an adjustment of [insert the adjustment factor], will be added, for evaluation purposes only, to the Tender price of Tenders offering deliveries later than the “Earliest Delivery Date” specified in Section V, Schedule of Requirements.
PRODUCT DELIVERY Delivery must be made as ordered to the address specified on the Purchase Order and in accordance with the terms of the Contract or Contract Award Notice. Unless otherwise specified in the Bid Documents, delivery shall be made within thirty calendar days after receipt of a Purchase Order by the Contractor. The decision of the Commissioner as to compliance with delivery terms shall be final. The burden of proof for delay in receipt of Purchase Order shall rest with the Contractor. In all instances of a potential or actual delay in delivery, the Contractor shall immediately notify the Commissioner and the Authorized User, and confirm in writing the explanation of the delay, and take appropriate action to avoid any subsequent late deliveries. Any extension of time for delivery must be requested in writing by the Contractor and approved in writing by the Authorized User. Failure to meet such delivery time schedule may be grounds for cancellation of the order or, in the Commissioner’s discretion, the Contract.
DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.
DELIVERY SCHEDULES In accordance with the "Non-State Agencies Participation in Centralized Contracts” and “Extension of Use” clauses herein, this Contract is extended to local governments, political subdivisions and others authorized by law as well as State agencies. The Delivery Schedules (based on Requirement Letter RL182) are available as a guide to indicate proposed delivery points and estimated annual requirements. Delivery Schedules may be revised or clarified as necessary. Any specific questions regarding the site conditions should be directed to the end-user at the telephone number shown on the Delivery Schedule. The Delivery Schedules are available upon request. Contractors shall be obligated to deliver under the Contract to any State agency which places a purchase order under the Contract, whether or not such delivery location is identified in the Delivery Schedules. Any political subdivision or other non-State entity which has not filed a requirement with OGS as of the date of the bid opening shall be eligible to receive deliveries at Contractor's option only, upon placement of a valid purchase order to the Contractor's address as indicated in the award. Contracts created by OGS in response to receipt of Filed Requirements are considered to be binding. At Contractor's request, Contractor will be advised in writing regarding political subdivisions or other Non-State entities which have filed on a timely basis but do not appear on the Delivery Schedule. Where “Standby” is indicated in the Delivery Schedule, this reflects those facilities which normally use a fuel supply (i.e. natural gas) other than fuel oil and will only use fuel oil when alternate fuel is unavailable.
Purchase Order Number NETAPP's purchase order number must appear on all invoices, packing lists and bills of lading and shall appear on each package, container or envelope on each shipment made pursuant to such purchase order.
Delivery Location All Goods shall be delivered to the address specified in this Order (the "Delivery Location") during Buyer's normal business hours or as otherwise instructed by Buyer.
How to Obtain Warranty Service The Warranty Holder must inspect the Flooring for Manufacturing Defects caused by improper milling, grading, staining, and coating, and report any such defects to Cali Bamboo, prior to installation of the Flooring. To obtain warranty service, the Warranty Holder must contact Cali Bamboo’s Customer Experience Department: xxxxxxxxxxxxxxx@xxxxxxxxxx.xxx/ 000- 000-0000. Warranty claims must be received within 30 calendar days after the Warranty Holder identifies the Manufacturing Defect or other basis for a warranty claim. To be covered under this Cali Bamboo limited warranty, the Warranty Holder must provide documentation of sales order and proof that the Flooring was properly installed in accordance with the Installation Guide (defined below). Cali Bamboo reserves the right to retain a certified and independent National Wood Flooring Association inspector (“NWFA Inspector”) to verify the Warranty Holder’s warranty claims. The determination of the NWFA Inspector regarding the warranty claim is not binding on either Cali Bamboo or on the Warranty Holder. A determination that does not verify the warranty claim shall not affect the Warranty Holder’s right to submit its claim to arbitration in accordance with the terms of the Arbitration Agreement (as defined in Cali Bamboo’s Terms and Conditions of Purchase). The performance of the inspection, however, if requested by Xxxx Xxxxxx and assuming that Xxxx Xxxxxx advances the full cost of the inspection as described above, is a requirement for the Warranty Holder to submit a warranty claim to arbitration under the Arbitration Agreement. For specific instructions on how to obtain warranty service for defective Flooring, visit the Cali Bamboo website xxxxx://xxx.xxxxxxxxxx.xxx/flooring-warranty/. This limited warranty covers Flooring that is both (i) installed with strict adherence to Cali Bamboo’s Odyssey Engineered flooring installation guide found online at xxxxx://xxx.xxxxxxxxxx.xxx/flooring-installation/ (the “Installation Guide”) and
Service Specification The Parties have agreed upon the scope and specification of the Services provided under this Service Agreement in the Service Specification.
Delivery Notice Notice of the Aircraft's Delivery Date, given by the Lessee as provided in Section 3.01 of the Participation Agreement and including any notice with respect to a postponed Delivery Date given by the Lessee pursuant to Section 3.05(c) of the Participation Agreement.
Contract Deliverables The Contractor shall provide information technology staff augmentation services, including comprehensive management of staff, as set forth in this Contract. The term “staff” refers to the temporary staff provided by the Contractor to render information technology services identified by Customers, but that staff shall not be deemed an employee of the State or deemed to be entitled to any benefits associated with such employment. Contracts resulting from this solicitation should not be structured as fixed-price agreements or used for any services requiring authorization for payment of milestone tasks. Contractor shall only provide information technology staff augmentation services for those Job Titles awarded to the Contractor and shall be paid on an hourly basis. The Department’s intent is for Contractor’s information technology staff to provide services closely related to those described in the Job Family Descriptions document. Detailed scopes of work, specific requirements of the work to be performed, and any requirements of staff shall be provided by the Customer in a Request for Quote. The Contractor shall possess the professional and technical staff necessary to allocate, outsource, and manage qualified information technology staff to perform the services requested by the Customer. The Contractor shall provide Customers with staff who must have sufficient skill and experience to perform the services assigned to them. All of the information technology staff augmentation services to be furnished by the Contractor under the Contract shall meet the professional standards and quality that prevails among information technology professionals in the same discipline and of similar knowledge and skill engaged in related work throughout Florida under the same or similar circumstances. The Contractor shall provide, at its own expense, training necessary for keeping Contractor’s staff abreast of industry advances and for maintaining proficiency in equipment and systems that are available on the commercial market. The Contractor shall be responsible for the administration and maintenance of all employment and payroll records, payroll processing, remittance of payroll and taxes, and all administrative tasks required by state and federal law associated with payment of staff. The Contractor shall, at its own expense, be responsible for adhering to the Contract background screening requirements, testing, evaluations, advertising, recruitment, and disciplinary actions of Contractor’s information technology staff. The Contractor shall maintain during the term of the Contract all licenses, permits, qualifications, insurance and approvals of whatever nature that are legally required to perform the information technology staff augmentation services.
