Latent Defects Notwithstanding anything to the contrary set forth herein, no acceptance, or deemed acceptance, by City pursuant to this Section shall be applicable with respect to any Latent Defects. An acceptance, or deemed acceptance, by City pursuant to this Section shall not mean that City has accepted, or the other party has been relieved of, responsibility for: (i) compliance with the Laws; (ii) the proper application of construction means or methods; or (iii) correcting any portion of the Project if it later is determined that any portion of the Project is inconsistent with the Final Documents and Drawings.
Liability for defects 5.1 The Customer is required to inspect the delivered Products without undue delay after delivery and to report any defects.
5.2 The delivered Products are deemed to have been approved if XXXX, with regard to obvious defects, obvious shortages or other defects which were or would have been identifiable in the course of an immediate, careful inspection, has not received notifi- cation of the defect within 7 days of delivery of the product, or otherwise – in the case of unclear or hidden defects – within 7 days of the discovery of the defect or the time at which the defect was identifiable to the Customer in the course of normal use of the Product without closer inspection.
5.3 In the event of a justified complaint, the Customer will be entitled to two attempts to rectify defects or make a replacement delivery at XXXX'x discretion free of charge within a reasonable period of time. Shortages will be delivered subsequently. If two attempts to rectify defects or make a replacement delivery within a reasonable period of time are unsuccessful, the Customer will be entitled to the statutory rights, subject to the provisions of clause 7. Subsequent performance will include neither removal of the defective item nor reassembly if XXXX was not originally required to carry out assembly. The expenses required for the purpose of inspection and subsequent performance, in particular transport, travel, labour and material costs (not: removal and assembly costs), insofar as these are not increased because the subject matter of the contract is located at a place other than our Customer's place of performance, will be borne by XXXX if there is actually a defect. Otherwise, XXXX may demand compensation from the Customer for the costs incurred by the unjustified request for rectification of the defect (in particular inspection and transport costs), unless the lack of defectiveness was not identifiable for the Customer. XXXX can refuse to rectify defects or make a replacement delivery if the Customer does not fulfil its payment obligations towards XXXX to an extent that corresponds to the defect-free part of the service provided.
5.4 No warranty will be assumed, in particular, in the following cases: Unsuitable or in- correct use by the Customer or by third parties instructed by the Customer, in particular through the use of insufficiently qualified personnel, faulty assembly or commission- ing, natural wear and tear (wearing parts), faulty or negligent handling, improper maintenance, unsuitable operating materials, defective construction work, unsuitable construction land, chemical, electrochemical or electrical influences, provided XXXX is not responsible for these circumstances.
5.5 XXXX is also not required to provide a warranty insofar as defects of Products are based on defective materials supplied by the Customer or insofar as defects of Products are based on the fact that the Customer has prescribed the execution of the order ac- cording to construction plans of third parties.
5.6 A delivery of used Products agreed with the Customer in the individual case is made to the exclusion of any warranty, unless XXXX has caused the defect intentionally or through gross negligence or has fraudulently concealed the defect.
5.7 The warranty period will be one year from delivery or, where acceptance was stipu- lated, from acceptance. Replaced parts will become our property and must be sent to us at our request. If shipping, assembly or commissioning is delayed through no fault of our own, our liability will expire no later than twelve months after the transfer of risk.
5.8 The right of recovery in accordance with sections 445a, 445b German Civil Code (BGB) is excluded, unless XXXX has caused the defect intentionally or by gross neg- ligence or has fraudulently concealed the defect.
REMEDY OF DEFECTS (a) The BUILDER shall remedy, at its expense, any defects, against which the VESSEL is guaranteed under this Article, by making all necessary repairs or replacements at the SHIPYARD or elsewhere as provided for in (b) hereinbelow. In such case, the VESSEL shall be taken at the BUYER's cost and responsibility to the place selected, ready in all respects for such repairs or replacements and in any event, the BUILDER shall not be responsible for towage, dockage, wharfage, port charges and anything else incurred for the BUYER's getting and keeping the VESSEL ready for such repairing or replacing.
(b) However, if it is impractical (which shall include, but not be limited to, an emergency) to bring the VESSEL to the SHIPYARD, the BUYER may cause the necessary repairs or replacements to be made elsewhere which is deemed by the BUYER with the consent of the BUILDER which shall not be unreasonably withheld, to be suitable for the purpose, provided that, in such event, the BUILDER may forward or supply replacement parts or materials under the terms described in (c) hereinbelow, unless forwarding or supplying thereof under the terms described in (c) hereinbelow would impair or delay the operation or working schedule of the VESSEL. In the event that the BUYER proposes to cause the necessary repairs or replacements to be made to the VESSEL at any shipyard or works other than the SHIPYARD, the BUYER shall first (but in all events as soon as reasonably possible) give the BUILDER notice by email or facsimile of the time and place such repairs will be made, and if the VESSEL is not thereby delayed, or her operation or working schedule is not thereby impaired, the BUILDER shall have the right to verify by its own representative(s) the nature and extent of the defects complained of. The BUILDER shall, in such case, promptly advise the BUYER by email or facsimile, after such examination has been completed, of its acceptance or rejection of the defects as ones that are covered by the guarantee herein provided. Upon the BUILDER's acceptance of the defects as justifying remedy under this Article, or upon award of the arbitration so determining, the BUILDER shall compensate the BUYER an amount equal to the reasonable cost of making the same repairs or replacements at the SHIPYARD.
(c) In the event that it is necessary for the BUILDER to forward a replacement for a defective part under this guarantee, replacement parts shall be shipped to the BUYER under the C.I.F terms to the BUYER's nominated port. The BUILDER reserves the option to retrieve, at the BUILDER's cost, any of the replaced equipment/parts in case defects are remedied in accordance with the provisions in this Article.
(d) Any dispute under this Article shall be referred to arbitration in accordance with the provisions of Article XIII hereof.
Correction of Defects 35.1 The Engineer shall give notice to the Contractor of any Defects before the end of the Defects Liability Period, which begins at Completion and is defined in the Contract Data. The Defects Liability Period shall be extended for as long as Defects remain to be corrected.
35.2 Every time notice of a Defect is given, the Contractor shall correct the notified Defect within the length of time specified by the Engineer’s notice.
Non-Infringement Warranty Seller warrants that all Goods and Services do not and shall not infringe any patent, trademark, copyright, trade secret or other intellectual property right of a third party.
Product Warranty Seller provides general warranties of fitness and general warranties that the goods are free from defects, for 1 year from acceptance of the goods, except as may otherwise be set forth in the Description/Proposal, or other attached warranty.
Defective Product If Client rejects Products under Section 6.1 and the deviation is determined to have arisen from Patheon’s failure to provide the Manufacturing Services in accordance with the Specifications, cGMPs, or Applicable Laws, Patheon will credit Client’s account for Patheon’s invoice price for the defective Products. If Client previously paid for the defective Products, Patheon will promptly, at Client’s election, either: (i) refund the invoice price for the defective Products; (ii) offset the amount paid against other amounts due to Patheon hereunder; or (iii) replace the Products with conforming Products without Client being liable for payment therefor under Section 3.1, contingent upon the receipt from Client of all Active Materials and Client-Supplied Components required for the manufacture of the replacement Products. For greater certainty, Patheon’s responsibility for any loss of Active Materials in defective Product will be captured and calculated in the Active Materials Yield under Section 2.2.
Quality of Materials and workmanship The Contractor shall ensure that the Construction, Materials and workmanship are in accordance with the requirements specified in this Agreement, Specifications and Standards and Good Industry Practice.
Claimed Infringement Each Party will promptly notify the other Party if a Third Party brings any Action alleging patent infringement by Lian or Landos or any of their respective Affiliates or Sublicensees with respect to the Development, Manufacture or Commercialization of any Licensed Product or Joint Patent Rights (any such Action, an “Infringement Claim”) in the Territory. Lian will have the right, but not the obligation, to control the defense and response to any such Infringement Claim in the Territory with respect to Lian’s activities, at Lian’s sole cost and expense, and Landos will have the right, at its own expense, to be represented in any such Infringement Claim in the Territory by counsel of its own choice. Landos will have the sole right, but not the obligation, to control the defense and response to any such Infringement Claim with respect to Landos’ activities, including any such Infringement Claim in the Territory or outside of the Territory. Upon the request of the Party controlling the response to the Infringement Claim, the other Party will reasonably cooperate with the controlling Party in the reasonable defense of such Infringement Claim. The other Party will have the right to consult with the controlling Party concerning any Infringement Claim and to participate in and be represented by independent counsel in any associated litigation. If the Infringement Claim is brought against both Parties, then each Party will have the right to defend against the Infringement Claim. The Party defending an Infringement Claim under this Section 7.4 (Claimed Infringement) will (a) consult with the other Party as to the strategy for the prosecution of such defense, (b) consider in good faith any comments from the other Party with respect thereto and (c) keep the other Party reasonably informed of any material steps taken and provide copies of all material documents filed, in connection with such defense. The Party controlling the defense against an Infringement Claim will have the right to settle such Infringement Claim on terms deemed reasonably appropriate by such Party, provided, that, neither Party will have the right to settle any Infringement Claim under this Section 7.4 (Claimed Infringement) in a manner that diminishes the rights or interests of the other Party under this Agreement without the consent of such other Party, which consent will not be unreasonably withheld.
Patent Infringement 9.1 If either Party learns of the infringement of a Prospective Patent, in any jurisdiction within the Territory, it shall so inform the other Party in writing, including any evidence of such infringement. University may not notify a third party of the infringement of a Prospective Patent, save for its legal advisers, without first obtaining written consent of Licensee, which consent shall not be unreasonably denied or delayed. Both Parties shall use their reasonable commercial efforts in cooperation with each other to terminate such infringement.
9.2 Licensee shall have the sole right, but not the obligation, to institute, prosecute and control any action, suit or proceeding to enforce the Prospective Patent with respect to infringement of the Prospective Patent and to defend any declaratory judgment with respect thereto, in each case within the Territory (“Action”). University hereby agrees to assist and cooperate with Licensee, at Licensee’s expense (including payment for University’s expert’s time, and other expenses so long as such expenses are properly documented), to enable Licensee to prosecute and maintain such Action. University’s agreement to assist Licensee includes, at Licensee’s reasonable request and when it is required by law, government regulation or court order, University’s agreement to join or to procure its Affiliates to join as a nominal party to achieve sufficient legal standing for Licensee to prosecute and maintain such Action provided that, if University participates in the Action only as a nominal party, University shall have no responsibility (other than to join as a nominal party) nor be liable for any costs or expenses in relation to or arising from such Action. For clarity, such liabilities for costs or expenses shall be the responsibility of Licensee. If Licensee invites University or its Affiliates to take a more active role (other than as a nominal party) in an Action as a co-party, University shall have its sole discretion to decide joining or not and on terms to be agreed with Licensee on a case by case basis. Licensee shall have the right to settle any Action or consent to an adverse judgment thereto, in its sole discretion, except that Licensee may not settle such action by agreeing to the invalidation of a Prospective Patent or any claim therein without University’s prior written consent. Any recovery obtained as a result of an Action, whether by judgment, award, decree or settlement, shall first be applied to reimbursement of Licensee’s expenses in bringing such suit or proceeding (including any attorneys, expert and court fees), and the balance shall be considered to be Net Sales Value, and subject to the royalty payments at [***]% as set forth in Clause 5, and the remaining balance shall be recovered by Licensee as damages.
9.3 Subject to Clause 9.2, if University commences or defends any suit or proceedings on its own account, University shall do so at its own expense. University shall have the right to settle any such action or consent to an adverse judgment thereto, in its sole discretion, except that University may not settle such action that may impair, damage or otherwise adversely affect the licence granted to Licensee under Clause 2.1, Licensee’s use of such licence, any Licensed Product, or any of Licensee’s rights/obligations hereunder, without Licensee’s prior written consent, which consent may not be unreasonably withheld or delayed. Any recovery obtained as a result of such action, whether by judgment, award, decree, or settlement, shall first be applied to reimbursement of University’s expenses in bringing such suit or proceeding (including expert, attorneys and court fees), and the balance shall be distributed between University and Licensee at a ratio of 65:35 in all cases which do not result in a sub-licence to a third party. If a suit or proceedings result in a sub-licence to a third party, then any recovery, whether by judgment, award, decree, or settlement, shall first be applied to reimbursement of University’s expenses in bringing such suit or proceeding (including expert, attorneys and court fees), and the balance to be paid to Licensee, provided that such balance shall be shared between University and Licensee according to the provisions in Clause 5.3 herein.
