Adjustment Amount (a) Schedule 2.16 sets forth a sample calculation of the Adjustment Amount and the Target Adjustment Amount as of the Balance Sheet Date (the “Sample Closing Statement”), including the asset, liability and other line items and accounting principles used in such calculation, and assuming that all of such asset and liability line items that constitute Mallinckrodt Assets or Mallinckrodt Liabilities under this Agreement will be transferred to Mallinckrodt as of the Distribution.
(b) Within sixty (60) days after the Distribution Date, Mallinckrodt shall cause to be prepared and delivered to Covidien a statement (the “Closing Statement”) setting forth (i) the Adjustment Amount and the calculation of the Adjustment Amount and (ii) the Target Adjustment Amount and the calculation of the Target Adjustment Amount. The Closing Statement shall be prepared in accordance with the Transaction Accounting Principles, including the use of the same line items and line item entries, set forth on and used in the preparation of the Sample Closing Statement; provided, however, that assets newly acquired and liabilities newly incurred following the date of the Sample Closing Statement which cannot be appropriately placed in line items previously used by Mallinckrodt, but that constitute Mallinckrodt Assets or Mallinckrodt Liabilities, will also be included to the extent consistent with the Transaction Accounting Principles.
(c) Within thirty (30) days following receipt by Covidien of the Closing Statement, Covidien shall deliver written notice to Mallinckrodt of any dispute Covidien has with respect to the preparation or content of the Closing Statement (the “Dispute Notice”); provided, however, that if Covidien does not deliver any Dispute Notice to Mallinckrodt within such thirty (30)-day period, the Closing Statement will be final, conclusive and binding on the Parties. Any Dispute Notice shall (i) set forth in reasonable detail the basis for any dispute included therein, the amounts involved and Covidien’s determination of the Adjustment Amount and/or the Target Adjustment Amount (as applicable) and (ii) include only disagreements based on the Adjustment Amount and/or the Target Adjustment Amount (as applicable) not being calculated properly in accordance with this Agreement or containing mathematical errors. Upon receipt by Mallinckrodt of a Dispute Notice, Mallinckrodt and Covidien shall negotiate in good faith to resolve any dispute set forth therein. If Mallinckrodt and Covidien, such good faith effort notwithstanding, fail to resolve any such dispute within fifteen (15) Business Days following receipt by Mallinckrodt of the Dispute Notice (the “Dispute Resolution Period”), then Mallinckrodt and Covidien jointly shall engage, within ten (10) Business Days following the expiration of the Dispute Resolution Period, Ernst & Young LLP or, if Ernst & Young LLP is unavailable or conflicted, another nationally recognized major accounting firm selected jointly by Covidien and Mallinckrodt (the “Independent Accounting Firm”) to resolve any such dispute. If Ernst & Young LLP is unavailable or conflicted and Covidien and Mallinckrodt are unable to agree on the Independent Accounting Firm, then each of Covidien and Mallinckrodt shall select a nationally recognized major accounting firm, and the two (2) firms will mutually select a third nationally recognized major accounting firm to serve as the Independent Accounting Firm. As promptly as practicable, and in any event not more than fifteen (15) days following the engagement of the Independent Accounting Firm, Mallinckrodt and Covidien shall each prepare and submit a presentation detailing each Party’s complete statement of proposed resolution of each issue still in dispute to the Independent Accounting Firm. Mallinckrodt and Covidien shall cause the Independent Accounting Firm to, as soon as practicable after the submission of the presentations described in the immediately preceding sentence and in any event not more than thirty (30) days following such presentations, make a final determination, binding on the Parties, of the appropriate amount of each of the line items that remain in dispute as indicated in the Dispute Notice. With respect to each disputed line item, such determination, if not in accordance with the position of either Covidien or Mallinckrodt, shall not be in excess of the higher, nor less than the lower, of the amounts set forth by Mallinckrodt in the Closing Statement or by Covidien in the Dispute Notice, as applicable. Notwithstanding the foregoing, the scope of the disputes to be resolved by the Independent Accounting Firm shall be limited to whether any determination of the Adjustment Amount and/or the Target Adjustment Amount (as applicable) was properly calculated in accordance with the Transaction Accounting Principles, and the Independent Accounting Firm is not to make any other determination, including any determination as to whether GAAP was followed, to the extent GAAP is inconsistent with the Transaction Accounting Principles. All fees and expenses relating to the work, if any, to be performed by the Independent Accounting Firm shall be borne equally by Covidien and Mallinckrodt. All determinations made by the Independent Accounting Firm, and the Closing Statement, as modified by the Independent Accounting Firm, will be final, conclusive and binding on the Parties, absent fraud or manifest error.
(d) For purposes of complying with the terms set forth in this Section 2.16, Mallinckrodt and Covidien shall cooperate with and make available to each other and their respective Representatives all information, records, data and working papers, in each case, to the extent related to the Mallinckrodt Assets, Mallinckrodt Liabilities or Mallinckrodt Business, and shall permit access to its facilities and personnel, as may be reasonably required in connection with the preparation and analysis of the Closing Statement and the resolution of any disputes thereunder.
(e) If the Adjustment Amount, as finally determined pursuant to Section 2.16(c), is greater than the Target Adjustment Amount, as finally determined pursuant to Section 2.16(c), by at least $20 million, then Mallinckrodt shall pay or cause to be paid an amount in cash equal to the difference from the first dollar (i.e., without regard to the $20 million threshold) to Covidien by wire transfer of immediately available funds to an account or accounts designated in writing by Covidien to Mallinckrodt. If the Adjustment Amount, as finally determined pursuant to Section 2.16(c), is less than the Target Adjustment Amount, as finally determined pursuant to Section 2.16(c), by at least $20 million, then Covidien shall pay or cause to be paid an amount in cash equal to the difference from the first dollar (i.e., without regard to the $20 million threshold) to Mallinckrodt by wire transfer of immediately available funds to an account or accounts designated in writing by Mallinckrodt to Covidien. Any such payment pursuant to this Section 2.16(e) is to be made within five (5) Business Days of the date on which the Adjustment Amount and the Target Adjustment Amount have been finally determined pursuant to this Section 2.16.
Payment Amount Payment for the Services shall be as follows: (choose one) ☐ - $______________________ for the Services (“Payment”). ☐ - At an hourly rate of $____ per hour (“Payment”). ☐ - Other. ______________________________________________ (“Payment”) If the Subcontractor asserts a claim which involves, in whole or in part, acts or omissions which are the responsibility of the Client or another person for whom a claim may be submitted, including but not limited to, claims for failure to pay, an extension of time, impacts, delay damages, or extra work, the Contractor shall present the Subcontractor's claim to the Client or other responsible party provided the Subcontractor presents to Contractor competent supporting evidence and in sufficient time for the Contractor to do so. The Subcontractor shall cooperate fully with the Contractor in any and all steps the Contractor takes in connection with prosecuting such a claim and shall hold harmless and reimburse the Contractor for all expenses, including legal expenses, incurred by the Contractor which arise out of the Contractor's submission of the Subcontractor's claims to the Client or other responsible party(ies). The Subcontractor shall be bound by any adjudication or award in any action or proceeding resolving such a claim.
Settlement Amount If the Non-Defaulting Party has declared an Early Termination Date pursuant to Section 7.2(b), the Non-Defaulting Party shall have the right to (i) accelerate all amounts owing between the Defaulting Party and the Non-Defaulting Party and to liquidate and terminate the undertakings set forth in this Agreement as between the Defaulting Party and the Non-Defaulting Party; and (ii) withhold any payments due to the Defaulting Party under this Agreement pending payment of the Termination Payment. The Non-Defaulting Party will calculate, in a commercially reasonable manner, the Settlement Amount with respect to the Defaulting Party’s obligations under the Agreement and shall net the Settlement Amount in the manner provided for in Section 7.3(c).
Payment Adjustments The Monthly Capitation Payments shall be adjusted for a period not to exceed twenty-four (24) months prior to the Monthly Capitation Payment to reflect corrections to the Enrollee Listing Report. Payments will be adjusted to reflect the automatic enrollment of eligible newborn infants. At such time that Kentucky HEALTH is live, a delivery payment will be paid on the eighth (8th) day of the month for the previous month’s claims. Claims for payment adjustments shall be deemed to have been waived by the Contractor if a payment request is not submitted in writing within twelve (12) months following the month for which an adjustment is requested. Waiver of a claim for payment shall not release the Contractor of its obligations to provide Covered Services pursuant to the Contract. In the event that an Enrollee is eligible and enrolled, but does not appear on the Enrollee Listing Report, the Contractor may submit a payment adjustment request. The Contractor shall submit the request in accordance with Appendix D “Reporting Requirements and Reporting Deliverables” for automated reporting requirements. In the event that an Enrollee is eligible and enrolled and the Contractor believes the Capitation Payment was in error due to underpayment, overpayment, or duplicate payment, the Contractor may submit a payment adjustment request. The Contractor shall submit the request in accordance with Appendix D “Reporting Requirements and Reporting Deliverables” for automated reporting requirements. In the event that an Enrollee does not appear on the Enrollee Listing Report, but the Department has paid the Contractor for an Enrollee, the Department may request and obtain a refund of, or it may recoup from subsequent payments, any payment previously made to the Contractor. In the event an Enrollee appears on the Enrollee Listing Report but is determined to be ineligible, the Department may request and obtain a refund of, or it may recoup from subsequent payments, any payment previously made to the Contractor. In such instances, for each Enrollee that is determined to be ineligible, the Contractor may recover payment from any Provider who rendered services to Enrollee during the period of ineligibility. The entity to which the Enrollee is retroactively added shall assume responsibility for payment of any services provided to Enrollees during the period of adjusted eligibility. For cases involving Enrollee ineligibility due to Fraud, Waste, and Abuse, the Department shall only recoup the Capitation amount and the Contractor shall establish procedures pursuant to Section
Payments from the Gross Settlement Amount Within 14 days after Defendants fund the Gross Settlement Amount, the Administrator will mail checks for all Individual Class Payments, all Individual PAGA Payments, the LWDA PAGA Payment, the Administration Expenses Payment, the Class Counsel Fees Payment, the Class Counsel Litigation Expenses Payment, and the Class Representative Service Payment. Disbursement of the Class Counsel Fees Payment, the Class Counsel Litigation Expenses Payment and the Class Representative Service Payment shall not precede disbursement of Individual Class Payments and Individual PAGA Payments.
4.4.1. The Administrator will issue checks for the Individual Class Payments and/or Individual PAGA Payments and send them to the Class Members via First Class U.S. Mail, postage prepaid. The face of each check shall prominently state the date (not less than 180 days after the date of mailing) when the check will be voided. The Administrator will cancel all checks not cashed by the void date. The Administrator will send checks for Individual Settlement Payments to all Participating Class Members (including those for whom Class Notice was returned undelivered). The Administrator will send checks for Individual PAGA Payments to all Aggrieved Employees including Non-Participating Class Members who qualify as Aggrieved Employees (including those for whom Class Notice was returned undelivered). The Administrator may send Participating Class Members a single check combining the Individual Class Payment and the Individual PAGA Payment. Before mailing any checks, the Settlement Administrator must update the recipients’ mailing addresses using the National Change of Address Database.
4.4.2. The Administrator must conduct a Class Member Address Search for all other Class Members whose checks are retuned undelivered without USPS forwarding address. Within 7 days of receiving a returned check the Administrator must re-mail checks to the USPS forwarding address provided or to an address ascertained through the Class Member Address Search. The Administrator need not take further steps to deliver checks to Class Members whose re-mailed checks are returned as undelivered. The Administrator shall promptly send a replacement check to any Class Member whose original check was lost or misplaced, requested by the Class Member prior to the void date.
4.4.3. For any Class Member whose Individual Class Payment check or Individual PAGA Payment check is uncashed and cancelled after the void date, the Administrator shall transmit the funds represented by such checks to the California Controller's Unclaimed Property Fund in the name of the Class Member thereby leaving no "unpaid residue" subject to the requirements of California Code of Civil Procedure Section 384, subd. (b).
4.4.4. The payment of Individual Class Payments and Individual PAGA Payments shall not obligate Defendants to confer any additional benefits or make any additional payments to Class Members (such as 401(k) contributions or bonuses) beyond those specified in this Agreement.
True-Up Adjustments From time to time, until the Retirement of the Recovery Bonds, the Servicer shall identify the need for True-Up Adjustments and shall take all reasonable action to obtain and implement such True-Up Adjustments, all in accordance with the following:
Distributions Payable in Cash; Redemption Payments In the event that the Board of the Investment Company shall declare a distribution payable in cash, the Investment Company shall deliver to FTIS written notice of such declaration signed on behalf of the Investment Company by an officer thereof, upon which FTIS shall be entitled to rely for all purposes, certifying (i) the amount per share to be distributed, (ii) the record and payment dates for the distribution, and (iii) that all appropriate action has been taken to effect such distribution. Once the amount and validity of any dividend or redemption payments to shareholders have been determined, the Investment Company shall transfer the payment amounts from the Investment Company's accounts to an account or accounts held in the name of FTIS, as paying agent for the shareholders, in accordance with any applicable laws or regulations, and FTIS shall promptly cause payments to be made to the shareholders.
Payments of Post-Closing Adjustment Except as otherwise provided herein, any payment of the Post-Closing Adjustment, together with interest calculated as set forth below, shall (A) be due (x) within five (5) Business Days of acceptance of the applicable Closing Working Capital Statement or (y) if there are Disputed Amounts, then within five (5) Business Days of the resolution described in clause (v) above; and (B) be paid by wire transfer of immediately available funds to such account(s) as is directed by Buyer or Sellers, as the case may be.
Payment and Year-End Adjustment Amounts accrued pursuant to this Agreement shall be payable to the Adviser as of the last day of each month. If necessary, on or before the last day of the first month of each fiscal year, an adjustment payment shall be made by the appropriate party in order that the actual Fund Operating Expenses of a Fund for the prior fiscal year (including any reimbursement payments hereunder with respect to such fiscal year) do not exceed the Maximum Annual Operating Expense Limit.
Payment of Settlement Amount (1) Within thirty (30) days of the Execution Date, the Settling Defendants shall pay the Settlement Amount to Siskinds LLP for deposit into the Trust Account. The Settlement Amount shall be converted into Canadian currency upon deposit into the Trust Account.
(2) The Settling Defendants shall deposit the Settlement Amount into the Trust Account by wire transfer. Siskinds LLP shall provide the necessary wire transfer information to Counsel for the Settling Defendants with reasonable advance notice so that the Settling Defendants have a reasonable period of time to comply with section 3.1(1) of this Settlement Agreement.
(3) The Settlement Amount and other consideration to be provided in accordance with the terms of this Settlement Agreement shall be provided in full satisfaction of the Released Claims against the Releasees.
(4) The Settlement Amount shall be all-inclusive of all amounts, including without limitation, interest, costs, Class Counsel Fees and Class Counsel Disbursements.
(5) The Releasees shall have no obligation to pay any amount in addition to the Settlement Amount, for any reason, pursuant to or in furtherance of this Settlement Agreement or the Proceedings or any Other Actions.
(6) Once a Claims Administrator has been appointed, Siskinds LLP shall transfer control of the Trust Account to the Claims Administrator.
(7) Siskinds LLP and the Claims Administrator shall maintain the Trust Account as provided for in this Settlement Agreement. While in control of the Trust Account, Siskinds LLP and the Claims Administrator shall not pay out all or part of the monies in the Trust Account, except in accordance with this Settlement Agreement, or in accordance with an order of the Courts obtained after notice to the Parties.
