Landlord Improvements (a) On the Commencement Date, Landlord will deliver the Leased Premises to Tenant in a broom clean condition, and, along with the lighting, electrical (excluding the UPS system and the diesel generator), mechanical and plumbing fixtures, plumbing systems, dock doors and HVAC servicing the Leased Premises, hot water, doors and plate-glass, will be delivered to Tenant in good condition and repair, as defined in Section 5.05 above.
(b) After receipt of the Letter of Credit and any required building permit, Landlord will commence and diligently pursue to completion, the construction of the improvements to the Leased Premises (the “Landlord Improvements”), in accordance with plans and specifications as shown in Exhibit B, subject to approval by local regulatory authorities (the “Plans”), which Plans are made a part of this Lease by reference. Any changes or modifications to the Plans must be made and accepted by written change order or agreement signed by Landlord and Tenant and will constitute an amendment to this Lease. Any Landlord Improvements made by Landlord are the property of Landlord and must be surrendered to Landlord upon the termination of this Lease without credit to Tenant. Upon completion of any Landlord Improvements and issuance of a final certificate of occupancy (to be applied for by Landlord’s general contractor) and certification from Landlord’s general contractor certifying to Tenant that all Landlord Improvements have been completed in accordance with the Plans (the “General Contractor’s Certificate”), thereafter Landlord shall provide and Tenant shall acknowledge receipt and acceptance of “as-built plans” of all work done in accordance with this Section 6.01.
(c) Landlord shall furnish an allowance of up to $172,800.00 (One hundred seventy-two thousand, eight hundred dollars) (“Landlord Improvement Allowance”) to be credited against the cost of the construction of the Landlord Improvements. If the actual cost of construction of the Landlord Improvements is less than the Landlord Improvement Allowance (“Allowance Overage”), Tenant shall have no right or claim to such difference; provided however, that if there is an Allowance Overage, Landlord, upon submission of supporting documentation by Tenant, will reimburse Tenant for any third party costs of low voltage wiring and laboratory benches for the Leased Premises, but such reimbursement shall not exceed the lesser of the Allowance Overage or 69,120.00 (Sixty-nine thousand, one hundred twenty & xx/100 dollars). If the actual cost of construction of the Landlord Improvements exceeds the Landlord Improvement Allowance, Tenant shall pay such excess cost to Landlord within ten (10) business days after receipt of supporting documentation and the General Contractor’s Certificate,.
(d) Notwithstanding anything contained in Section 6.01 (c) above, within 30 days after the issuance of the General Contractor’s Certificate, Landlord will determine the sum of (i) the actual cost of the Landlord Improvements, plus (ii) if any, the actual costs submitted by Tenant towards the Contingent Allowance, and the product of the calculation shall be rounded to the next $1,000.00 (One Thousand Dollars). If the resultant amount is less than the Landlord Improvement Allowance, Landlord shall reduce the monthly Base Rent by $20.25 (“Base Rent Reduction Factor”) for each whole $1,000.00 (One Thousand Dollars) of such amount effective January 1, 2012. If it is determined that the monthly Base Rent is to be reduced and if Tenant has already paid Base Rent in a pre-reduction amount, Landlord shall give Tenant credit for any such excess payment, and reduction in monthly Base Rent shall be memorialized in an amendment to this Lease. In the event that the monthly Base Rent is reduced in accordance with this Section 6.01(d), there shall be no reduction in the Security Deposit Amount or in the requirements set forth for the Letter of Credit. The following example illustrates the intentions of the parties hereto as to computation of any reduction of the monthly Base Rent: Assumptions:
1. Actual cost of the Landlord Improvements: $100,000.00
2. Actual cost of qualifying costs for Contingent Allowance: $50,500.00 Total cost of Landlord Improvements and Contingent Allowance Costs: ($100,000.00 + $50,500.00) = $150,500.00 Determination of reduction in monthly Base Rent: Total Landlord Improvement Allowance $ 172,800.00 Less total cost of Landlord Improvements and contingent costs 150,500.00 $ 22300.00 Rounded to next $1,000.00 (One Thousand Dollars) $ 23,000.00 Divided by $1,000.00 (One Thousand Dollars) 1,000.00 Base Rent Reduction Factor 20.25 Reduction in monthly Base Rent $ 465.75
(e) In addition to the Landlord Improvements, Landlord, at Landlord’s sole cost and expense, shall have the following additional work performed on the Leased Premises prior to delivery of possession to Tenant, such work to be coordinated with the construction of the Landlord Improvements:
(i) Replace all stained, damaged or missing ceiling tiles,
(ii) Paint all walls in the Leased Premises, the color to be designated by Tenant,
(iii) Replace all vinyl floor tiles in the open laboratory area as shown in Exhibit C,
(iv) Shampoo all carpets in the office areas and hallways and
(v) Any existing water supply or drainage pipes in the open lab area that are not initially utilized by Tenant shall be capped and made reasonably flush with the floor, but such capping shall allow for those pipes to be tapped by Tenant for future use.
(vi) Re-caulk all perimeter flashing; install new pads under all gas line blocking; repair any loose or open curb or wall flashing; repack all pitch pans; repair any open joints on gravel guard; repair any loose scupper flashing; clean, prime and install EPDM peel and stick tape to all roof side tilt wall joints; clean all debris from around drains and entire roof; install Xxxxxx 97 asbestos free aluminum coating to entire roof surface
(vii) Repair any existing alligator or pothole areas.
Premises Building Project and Common Areas 1.1 Premises, Building, Project and Common Areas.
Condition of Subleased Premises (a) Subtenant represents that it has made or caused to be made a thorough examination and inspection of the Subleased Premises and is familiar with the condition of every part thereof. Subtenant agrees that, except as expressly provided herein, (i) it enters into this Sublease without relying upon any representations, warranties or promises by Sublandlord, its agents, representatives, employees or any other person in respect of the Building or the Subleased Premises, (ii) no rights, easements or licenses are acquired by Subtenant by implication or otherwise except as expressly set forth herein, (iii) Sublandlord shall deliver the Subleased Premises broom-clean and otherwise in the condition which Sublandlord received the Subleased Premises from Prime Lessor and Sublandlord shall have no obligation to do any work in order to make the Subleased Premises suitable and ready for occupancy and use by Subtenant, and (iv) the Subleased Premises are in satisfactory condition. Notwithstanding the foregoing, Subtenant acknowledges receipt from Prime Lessor of a decommissioning report with respect to the Subleased Premises prepared by Ramboll US Corporation and dated March 17, 2020 (the “Decommissioning Report”) and has accepted the results set forth in the Decommissioning Report. Sublandlord represents and warrants to Subtenant that Sublandlord has not physically occupied the Subleased Premises at any time, including from and after the date of the Decommissioning Report.
(b) Subtenant shall keep and maintain the Subleased Premises, the furniture, fixtures and equipment therein (including, without limitation, all laboratory-specific mechanical equipment) clean and in good order, repair and condition, except for reasonable wear and tear and damage by fire or other casualty or condemnation. To the extent agreed to by Prime Lessor, Subtenant shall be entitled to the benefit of those obligations of Prime Lessor set forth in the Prime Lease as to Prime Lessor’s obligation to maintain Building Systems.
(c) Subtenant shall make no alteration, installation, removal, addition or improvement in or to the Subleased Premises or to any other portion of the Building without the prior written consent of each of Sublandlord and, if required pursuant to the terms of the Prime Lease, Prime Lessor, and then, only in compliance fully with the terms of this Sublease and the Prime Lease. Sublandlord may withhold consent in its sole discretion to any alteration, installation, addition or improvement proposed by Subtenant. Sublandlord may require Subtenant to remove any and all alterations, installations, additions or improvements that Subtenant makes to the Subleased Premises upon the expiration or termination of the Term, and to restore the Subleased Premises to its condition prior to such alterations, installations, additions or improvements.
(d) During the Term of the Sublease, and subject to Prime Lessor’s consent, Subtenant may use 0.90 parking spaces in the Technology Square Garage per 1,000 rentable square feet of the Subleased Premises as allocated to Sublandlord pursuant to Section 10 of the Prime Lease. Such parking use by Subtenant shall, subject to Prime Lessor’s consent, be at the same cost per space as charged to Sublandlord from time to time pursuant to the Prime Lease, and such use by Subtenant shall be in accordance with Section 10 of the Prime Lease as amended from time to time and all published rules and regulations of the Landlord and/or the operator of the Technology Square Garage as to such parking use.
Building Signage 1. Tenant shall be entitled to the greater of: (i) one (1) exclusive tenant identification sign per Building that does not to exceed 75 square feet, or (ii) Tenant’s pro rata share of the maximum exterior signage permitted by applicable Laws that is allocated to the parcel on which the Building is located (the “Building Signage”). The exact location of the Building Signage shall be determined by Tenant, subject to all applicable Laws, any reasonable signage guidelines for the Project established by Landlord that are provided to Tenant prior to installation of the Building Signage, and Landlord’s prior written approval, which approval shall not be unreasonably withheld, conditioned or delayed. Such right to the Building Signage is personal to Tenant and is subject to the following terms and conditions: (a) Tenant shall submit plans and drawings for the Building Signage to Landlord and to the City of San Mateo and to any other public authorities having jurisdiction and shall obtain written approval from Landlord (not to be unreasonably withheld, conditioned or delayed) and, if applicable, each such jurisdiction prior to installation, and shall comply with all applicable Laws; (b) Tenant shall, at Tenant’s sole cost and expense, design, construct and install the Building Signage; (c) the size, color and design of the Building Signage shall be subject to Landlord’s prior written approval; and (d) Tenant shall maintain the Building Signage in good condition and repair, and all costs of maintenance and repair shall be borne by Tenant. Maintenance shall include, without limitation, cleaning and, if the Building Signage is illuminated, relamping at reasonable intervals. Tenant shall be responsible for any electrical energy used in connection with the Building Signage. Notwithstanding the foregoing, Tenant shall not be liable for any fee in connection with Tenant’s right to display the Building Signage in accordance with this Lease. At Landlord’s option, Tenant’s right to the Building Signage may be revoked and terminated upon occurrence of any of the following events: (i) Tenant shall be in default under this Lease beyond any applicable notice and cure periods; (ii) Tenant leases or occupies less than 75% of the Premises, or (iii) this Lease shall terminate or otherwise no longer be in effect.
2. Upon the expiration or earlier termination of this Lease or at such other time that Tenant’s signage rights are terminated pursuant to the terms hereof, if Tenant fails to remove the Building Signage and repair the Building in accordance with the terms of this Lease, Landlord shall cause the Building Signage to be removed from the Building and the Building to be repaired and restored to the condition which existed prior to the installation of the Building Signage (including, if necessary, the replacement of any precast concrete panels), all at the sole cost and expense of Tenant and otherwise in accordance with this Lease, without further notice from Landlord notwithstanding anything to the contrary contained in this Lease. Tenant shall pay all costs and expenses for such removal and restoration within fifteen (15) business days following delivery of an invoice therefor accompanied by reasonable supporting documentation. The rights provided in this Section 36.A shall be non-transferable (except with respect to a Permitted Transferee) unless otherwise agreed by Landlord in writing in its sole discretion.
Tenant’s Repairs Subject to Section 13 hereof, Tenant, at its expense, shall repair, replace and maintain in good condition all portions of the Premises, including, without limitation, entries, doors, ceilings, interior windows, interior walls, and the interior side of demising walls. Such repair and replacement may include capital expenditures and repairs whose benefit may extend beyond the Term. Should Tenant fail to make any such repair or replacement or fail to maintain the Premises, Landlord shall give Tenant notice of such failure. If Tenant fails to commence cure of such failure within 10 days of Landlord’s notice, and thereafter diligently prosecute such cure to completion, Landlord may perform such work and shall be reimbursed by Tenant within 10 days after demand therefor; provided, however, that if such failure by Tenant creates or could create an emergency, Landlord may immediately commence cure of such failure and shall thereafter be entitled to recover the costs of such cure from Tenant. Subject to Sections 17 and 18, Tenant shall bear the full uninsured cost of any repair or replacement to any part of the Project that results from damage caused by Tenant or any Tenant Party and any repair that benefits only the Premises. Notwithstanding anything to the contrary contained in this Lease, as of the Rent Commencement Date, the maintenance and repair obligations for the Premises shall be allocated between Landlord and Tenant as set forth on Exhibit H attached hereto. The maintenance obligations allocated to Tenant pursuant to Exhibit H (the “Tenant Maintenance Obligations”) shall be performed by Tenant at Tenant’s sole cost and expense. The Tenant Maintenance Obligations shall include the procurement and maintenance of contracts, in form and substance reasonably satisfactory to Landlord, with copies to Landlord upon Landlord’s written request, for and with contractors reasonably acceptable to Landlord specializing and experienced in the respective Tenant Maintenance Obligations. Notwithstanding anything to the contrary contained herein, the scope of work of any such contracts entered into by Tenant pursuant to this paragraph shall, at a minimum, comply with manufacturer’s recommended maintenance procedures for the optimal performance of the applicable equipment. Landlord shall, notwithstanding anything to the contrary contained in this Lease, have no obligation to perform any Tenant Maintenance Obligations. The Tenant Maintenance Obligations shall not include the right or obligation on the part of Tenant to make any structural and/or capital repairs or improvements to the Project, and Landlord shall continue, as part of Operating Expenses, to be responsible, as provided in Section 13, for capital repairs and replacements required to be made to the Project. If Tenant fails to maintain any portion of the Premises for which Tenant is responsible as part of the Tenant Maintenance Obligations in a manner reasonably acceptable to Landlord within the requirements of this Lease, Landlord shall have the right, but not the obligation, to provide Tenant with written notice thereof and to assume the Tenant Maintenance Obligations if Tenant does not cure Tenant’s failure within 10 days after receipt of such notice.
Landlord Repairs Landlord shall maintain, at its expense, the structural soundness of the roof, foundations, and exterior walls of the Site and all common areas within the Site in good repair, reasonable wear and tear and damages caused by Tenant, its agents and contractors excluded; provided, however, that Landlord’s costs of maintenance and repair of the common areas may be included within Site Operating Costs as provided and subject to the limitations thereon set forth in Section 9 above; and provided, further, that Landlord shall also make all such repairs and restorations which may be required as a result of any patent or latent defects in Landlord’s Work pursuant to Landlord’s warranty set forth in Section 6 of Exhibit “B”. The term “walls” as used in this Section shall not include windows, glass or plate glass, doors or overhead doors, special store fronts, dock bumpers, dock plates or levelers, or office entries. Tenant shall promptly give Landlord written notice of any repair required by Landlord pursuant to this Section, after which Landlord shall have a reasonable opportunity to repair; provided, however, that Landlord shall in any event have commenced and diligently pursue all such repairs to completion within thirty (30) days after receipt of Tenant’s written notice therefor; provided, further, that if such repairs are not capable of being completed within said 30-day period, then Landlord shall have such additional period of time as may be reasonably necessary to complete such repairs so long as Landlord commences such repairs within said thirty (30) day period and diligently pursues such repairs to completion. If the repairs required to be made by Landlord materially and adversely affect Tenant’s use of the Premises for its Permitted Use and Tenant’s notice clearly and conspicuously labels the repair a “Critical Repair” and summarizes the requirements of this Section, Landlord shall commence and diligently pursue such repairs to completion within five (5) business days after receipt of the foregoing written notice from Tenant and, if Landlord fails to commence and diligently pursue such repairs within said five (5) business day period, Tenant shall have the right to elect to perform such repairs on behalf of Landlord, the actual, reasonable costs of which shall be reimbursed by Landlord to Tenant within thirty (30) days after Landlord’s receipt of a written invoice or statement therefor from Tenant and, if such costs and expenses are not so reimbursed to Tenant within said 30-day period, Tenant shall have the right to offset the same, together with interest at a per-annum rate equal to the Prime Rate plus ten percent (10%), from the next and subsequent installments of Base Rent payable under this Lease until the foregoing amount is fully offset.
Landlord Work Landlord shall, at Landlord’s sole cost and expense, concurrently with Tenant’s construction of the Tenant Improvements, remove the existing demising wall and construct a Building standard demising wall at the Expansion Premises, which shall include studs, acoustical insulation and dry wall ready for finish on the Tenant side only and any necessary penetrations, fire dampers and sound traps (collectively, the “Demising Wall”), which Demising Wall shall be adjacent to the Expansion Premises as set forth on Exhibit A to this Amendment (collectively, the “Landlord Work”). Tenant may not change or alter the Landlord Work. Landlord shall use commercially reasonable efforts to Substantially Complete the Landlord Work no later than forty-five (45) days after the Expansion Delivery Date. In addition, Landlord shall, at Landlord’s sole cost and expense, to the extent required in order to allow Tenant to obtain a certificate of occupancy, or its legal equivalent, for the Expansion Premises for general office use assuming a normal and customary office occupancy density, cause the Landlord Work and the Building Common Areas (including the Base Building restrooms on the seventh (7th) floor of the Building), to comply with applicable building codes and other governmental laws, ordinances and regulations related to handicap access, which were enacted and enforced as of the date of this Amendment. Because Landlord shall be constructing the Landlord Work concurrently with Tenant’s construction of the Tenant Improvements, there will be a certain “overlap” period pursuant to which both Landlord’s representatives, employees, vendors and contractors and Tenant’s representatives, employees, vendors and contractors may be present and performing work in a portion of the Premises. During any such “overlap” period(s) when both parties and/or their respective employees, vendors, contractors or consultants are concurrently performing work in, or accessing, any portion of the Premises, neither party shall unreasonably interfere with or delay the work of the other party and/or its contractors or consultants, and both parties shall mutually coordinate and cooperate with each other, and shall cause their respective employees, vendors, contractors, and consultants to work in harmony with and to mutually coordinate and cooperate with the other’s employees, vendors, contractors and consultants, respectively, to minimize any interference or delay by either party with respect to the other party’s work. In addition, Landlord shall, and shall cause the other Landlord Parties to, use commercially reasonable efforts to minimize any interference with Tenant’s operations in the Existing Premises. Landlord shall have no obligation to move any furniture or other personal property of Tenant in the performance of Landlord Work. Tenant hereby agrees that the construction of the Landlord Work shall in no way constitute a constructive eviction of Tenant nor entitle Tenant to any abatement of rent. Except as otherwise expressly provided in the Lease (including this Tenant Work Letter), Landlord shall have no responsibility or for any reason be liable to Tenant for any direct or indirect injury to or interference with Tenant’s business arising from the Landlord Work, nor shall Tenant be entitled to any compensation or damages from Landlord for loss of the use of the whole or any part of the Premises or of Tenant’s personal property or improvements resulting from the Landlord Work or Landlord’s actions in connection with the Landlord Work, or for any inconvenience or annoyance occasioned by the Landlord Work or Landlord’s actions in connection with the Landlord Work.
LANDLORD'S ACCESS TO PREMISES Landlord reserves and shall at any time upon reasonable notice and in compliance with Tenant’s reasonable security measures have the right to enter the Premises to inspect the same, to supply any service to be provided by Landlord to Tenant hereunder to service and repair HVAC units, water pipes and sprinkler mains, and electrical and telephone risers servicing other parts of the Building, to show said Premises to prospective purchasers or tenants, to alter or repair the Premises or any portion of the Building, and to place “for sale” or “for rent” signs on the Building, all without being deemed guilty of an eviction of Tenant and without abatement of Rent, provided that the business of Tenant shall be interfered with as little as is reasonably practicable. Tenant hereby waives any claim for damages or any inconvenience to or interference with Tenant’s business, any loss of quiet enjoyment of the Premises and any other loss occasioned thereby. For each of the aforesaid purposes, Landlord shall at all times have and retain a key with which to unlock the main door to the Premises but not Tenant’s vaults and safes, and Landlord shall have the right to use any and all means which Landlord may deem proper to open said door in an emergency in order to obtain entry to the Premises, and any entry to the Premises obtained by Landlord by any of said means shall not under any circumstances be construed or deemed to be a forcible or unlawful entry into, or a detainer of the Premises, or any eviction of Tenant from the Premises or any portion thereof. No provision of this Lease shall be construed as obligating Landlord to perform any repairs, alterations or decoration except as otherwise expressly agreed to be performed by Landlord.
Expansion Premises In addition to the Original Premises, commencing on the Expansion Premises Commencement Date (as defined below), Landlord leases to Tenant, and Tenant leases from Landlord, the Expansion Premises.
Landlord’s Repairs Landlord, as an Operating Expense, shall maintain all of the structural, exterior, parking and other Common Areas of the Project, including HVAC, plumbing, fire sprinklers, elevators and all other building systems serving the Premises and other portions of the Project (“Building Systems”), in good repair, reasonable wear and tear and uninsured losses and damages caused by Tenant, or by any of Tenant’s agents, servants, employees, invitees and contractors (collectively, “Tenant Parties”) excluded. Losses and damages caused by Tenant or any Tenant Party shall be repaired by Landlord, to the extent not covered by insurance, at Tenant’s sole cost and expense. Landlord reserves the right to stop Building Systems services when necessary (i) by reason of accident or emergency, or (ii) for planned repairs, alterations or improvements, which are, in the judgment of Landlord, desirable or necessary to be made, until said repairs, alterations or improvements shall have been completed. Landlord shall have no responsibility or liability for failure to supply Building Systems services during any such period of interruption; provided, however, that Landlord shall, except in case of emergency, make a commercially reasonable effort to give Tenant 24 hours advance notice of any planned stoppage of Building Systems services for routine maintenance, repairs, alterations or improvements. Tenant shall promptly give Landlord written notice of any repair required by Landlord pursuant to this Section, after which Landlord shall make a commercially reasonable effort to effect such repair. Landlord shall not be liable for any failure to make any repairs or to perform any maintenance unless such failure shall persist for an unreasonable time after Tenant’s written notice of the need for such repairs or maintenance. Tenant waives its rights under any state or local law to terminate this Lease or to make such repairs at Landlord’s expense and agrees that the parties’ respective rights with respect to such matters shall be solely as set forth herein. Repairs required as the result of fire, earthquake, flood, vandalism, war, or similar cause of damage or destruction shall be controlled by Section 18.
