No Construction Loans No Mortgage Loan was made in connection with (i) the construction or rehabilitation of a Mortgage Property or (ii) facilitating the trade-in or exchange of a Mortgaged Property other than a construction-to-permanent loan which has converted to a permanent Mortgage Loan;
Application of Amounts in Trust Accounts (a) For so long as any Notes are outstanding, on each Payment Date, the Indenture Trustee will distribute to the Certificateholders, on a pro rata basis, based on the Percentage Interests thereof, the amounts distributable thereto pursuant to Section 5.06 of the Sale and Servicing Agreement and Section 3.01 of the Indenture. From and after the date on which the Notes of all Classes have been paid in full, the Paying Agent shall distribute to the Certificateholders (i) amounts released to the Trust pursuant to Sections 4.02 and 8.05(b) of the Indenture and Section 5.01(d) of the Sale and Servicing Agreement and (ii) amounts that are distributable to the Certificateholders in accordance with the instructions of the Servicer pursuant to Section 5.06 of the Sale and Servicing Agreement.
(b) On each Payment Date, the Owner Trustee shall send to the Certificateholders the statement provided to the Owner Trustee by the Servicer pursuant to Section 5.09 of the Sale and Servicing Agreement with respect to such Payment Date.
(c) In the event that any withholding tax is imposed on the Trust’s distributions (or allocations of income) to a Certificateholder, such tax shall reduce the amount otherwise distributable to the Certificateholders in accordance with this Section. The Owner Trustee and Paying Agent (and the Indenture Trustee, to the extent the Indenture Trustee is then making distributions to Certificateholders) are hereby authorized and directed to retain from amounts otherwise distributable to the Certificateholders sufficient funds for the payment of any tax that is legally owed by the Trust (but such authorization shall not prevent the Owner Trustee from contesting any such tax in appropriate proceedings, and withholding payment of such tax, if permitted by law, pending the outcome of such proceedings). The amount of any withholding tax imposed with respect to a Certificateholder shall be treated as cash distributed to such Certificateholder at the time it is withheld by the Trust and remitted to the appropriate taxing authority. If there is a possibility that withholding tax is payable with respect to any distribution (such as any distribution to a Non-U.S. Person), in order to comply with applicable law, the Owner Trustee may, in its sole discretion and without liability, withhold such amounts in accordance with this paragraph (c). In the event that a Certificateholder wishes to apply for a refund of any such withholding tax, the Owner Trustee shall reasonably cooperate with such Certificateholder in making such claim so long as such Certificateholder agrees to reimburse the Owner Trustee for any out-of-pocket expenses incurred in connection therewith.
Maintenance of Collateral Accounts Maintain any Collateral Account except pursuant to the terms of Section 6.6(b) hereof.
Audit Rights Period for Construction-Related Accounts and Records Accounts and records related to the design, engineering, procurement, and construction of Connecting Transmission Owner’s Attachment Facilities and System Upgrade Facilities and System Deliverability Upgrades shall be subject to audit for a period of twenty-four months following Connecting Transmission Owner’s issuance of a final invoice in accordance with Article 12.2 of this Agreement.
Application of Funds in the Collection Account The Master Servicer may, from time to time, make, or cause to be made, withdrawals from the Collection Account for the following purposes:
(i) to reimburse itself or any Servicer for Advances made by it or by such Servicer pursuant to Section 5.04 or the applicable Servicing Agreement; provided, however, that the Master Servicer’s right to reimburse itself pursuant to this subclause is limited to amounts received on or in respect of particular Mortgage Loans (including, for this purpose, Liquidation Proceeds and amounts representing Insurance Proceeds with respect to the property subject to the related Mortgage) which represent late recoveries (net of the applicable Servicing Fee and the Master Servicing Fee) of payments of principal or interest respecting which any such Advance was made; provided, further, that following the final liquidation of a Mortgage Loan, the Master Servicer may reimburse itself for previously unreimbursed Advances in excess of Liquidation Proceeds or Insurance Proceeds with respect to such Mortgage Loans from any funds in the Collection Account, it being understood, in the case of any such reimbursement, that the Master Servicer’s or Servicer’s right thereto shall be prior to the rights of the Certificateholders;
(ii) to reimburse itself or any Servicer for any Servicing Advances made by it or by such Servicer that it or such Servicer determines in good faith will not be recoverable from amounts representing late recoveries of payments of principal or interest respecting the particular Mortgage Loan as to which such Servicing Advance was made or from Liquidation Proceeds or Insurance Proceeds with respect to such Mortgage Loan, it being understood, in the case of any such reimbursement, that such Master Servicer’s or Servicer’s right thereto shall be prior to the rights of the Certificateholders;
(iii) to reimburse itself or any Servicer from Liquidation Proceeds for Liquidation Expenses and for amounts expended by it pursuant to Sections 9.20 and 9.22(a) or the applicable Servicing Agreement in good faith in connection with the restoration of damaged property and, to the extent that Liquidation Proceeds after such reimbursement exceed the unpaid principal balance of the related Mortgage Loan, together with accrued and unpaid interest thereon at the applicable Mortgage Rate less the applicable Servicing Fee and the Master Servicing Fee for such Mortgage Loan to the Due Date next succeeding the date of its receipt of such Liquidation Proceeds, to pay to itself out of such excess the amount of any unpaid assumption fees, late payment charges or other Mortgagor charges on the related Mortgage Loan and to retain any excess remaining thereafter as additional servicing compensation, it being understood, in the case of any such reimbursement or payment, that such Master Servicer’s or Servicer’s right thereto shall be prior to the rights of the Certificateholders;
(iv) to reimburse itself or any Servicer for expenses incurred by and recoverable by or reimbursable to it or such Servicer pursuant to Section 9.04, 9.05, 9.06, 9.16 or 9.22(a) or pursuant to the applicable Servicing Agreement, and to reimburse itself for any expenses reimbursable to it pursuant to Section 10.01(c);
(v) to pay to the applicable Person, with respect to each Mortgage Loan or REO Property acquired in respect thereof that has been repurchased by such Person pursuant to this Agreement, all amounts received thereon and not distributed on the date on which the related repurchase was effected;
(vi) subject to Section 5.05, to pay to itself income earned on the investment of funds deposited in the Collection Account;
(vii) to make payments to the Trustee for deposit into the Certificate Account in the amounts and in the manner provided for in Section 4.01(c);
(viii) to make distributions of any Retained Interest to the Retained Interest Holder on each Distribution Date (other than any Retained Interest not deposited into the Collection Account in accordance with Section 4.01(d)(iii));
(ix) to make payment to itself, the Trustee and others pursuant to any provision of this Agreement;
(x) to withdraw funds deposited in error in the Collection Account;
(xi) to clear and terminate the Collection Account pursuant to Section 7.02;
(xii) to reimburse a successor Master Servicer (solely in its capacity as successor Master Servicer), for any fee or advance occasioned by a termination of the Master Servicer, and the assumption of such duties by the Trustee or a successor Master Servicer appointed by the Trustee pursuant to Section 6.14, in each case to the extent not reimbursed by the terminated Master Servicer, it being understood, in the case of any such reimbursement or payment, that the right of the Master Servicer or the Trustee thereto shall be prior to the rights of the Certificateholders; and
(xiii) to reimburse any Servicer for such amounts as are due thereto under the applicable Servicing Agreement and have not been retained by or paid to such Servicer to the extent provided in such Servicing Agreement. If provided in the related Servicing Agreement, each Servicer shall be entitled to retain as additional servicing compensation any Prepayment Interest Excess (to the extent not offset by Prepayment Interest Shortfalls). In the event that the Master Servicer fails on any Deposit Date to remit to the Trustee any amounts required to be so remitted to the Trustee pursuant to subclause (vii) by 12 noon (New York time) on such date, the Master Servicer shall pay the Trustee, for the account of the Trustee, interest calculated at the “prime rate” (as published in the “Money Rates” section of The Wall Street Journal) on such amounts not timely remitted for the period from and including that Deposit Date to but not including the related Distribution Date. In connection with withdrawals pursuant to subclauses (i), (iii), (iv) and (vi) above, the Master Servicer’s or Servicer’s entitlement thereto is limited to collections or other recoveries on the related Mortgage Loan, except as provided herein. The Master Servicer shall therefore keep and maintain a separate accounting for each Mortgage Loan it master services for the purpose of justifying any withdrawal from the Collection Account it maintains pursuant to subclauses (i), (iii), (iv) and (vi) above.
Distribution of Collateral Proceeds In the event that, following the occurrence or during the continuance of any Default or Event of Default, the Administrative Agent or any Lender, as the case may be, receives any monies in connection with the enforcement of any of the Security Documents, or otherwise with respect to the realization upon any of the Collateral, such monies shall be distributed for application as follows:
(a) First, to the payment of, or (as the case may be) the reimbursement of the Administrative Agent, in its capacity as such, for or in respect of all reasonable costs, expenses, disbursements and losses which shall have been incurred or sustained by the Administrative Agent in connection with the collection of such monies by the Administrative Agent, for the exercise, protection or enforcement by the Administrative Agent of all or any of the rights, remedies, powers and privileges of the Administrative Agent under this Credit Agreement or any of the other Loan Documents or in respect of the Collateral or in support of any provision of adequate indemnity to the Administrative Agent against any taxes or liens which by law shall have, or may have, priority over the rights of the Administrative Agent to such monies;
(b) Second, to all other Obligations in such order or preference as the Required Lenders may determine; provided, however, that (i) distributions shall be made (A) pari passu among Obligations with respect to the Administrative Agent’s Fee and all other Obligations and (B) with respect to each type of Obligation owing to the Lenders, such as interest, principal, fees and expenses, among the Lenders pro rata across all Tranches and (ii) the Administrative Agent may in its discretion make proper allowance to take into account any Obligations not then due and payable;
(c) Third, upon payment and satisfaction in full in cash or other provisions for payment in full satisfactory to the Lenders and the Administrative Agent of all of the Obligations, to the payment of any obligations required to be paid pursuant to §9-615 of the UCC of the State of New York; and
(d) Fourth, the excess, if any, shall be returned to the Borrower or to such other Persons as are entitled thereto.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
SECTION 402. Application of Trust Money Subject to the provisions of the last paragraph of Section 1003, all money deposited with the Trustee pursuant to Section 401 shall be held in trust and applied by it, in accordance with the provisions of the Securities and this Indenture, to the payment, either directly or through any Paying Agent (including the Company acting as its own Paying Agent) as the Trustee may determine, to the Persons entitled thereto, of the principal and any premium and interest for whose payment such money has been deposited with the Trustee.
Application of Collateral Proceeds The proceeds and/or avails of the Collateral, or any part thereof, and the proceeds and the avails of any remedy hereunder (as well as any other amounts of any kind held by Lender, at the time of or received by Lender after the occurrence of an Event of Default hereunder) shall be paid to and applied as follows:
(a) First, to the payment of out-of-pocket costs and expenses, including all amounts expended to preserve the value of the Collateral, of foreclosure or suit, if any, and of such sale and the exercise of any other rights or remedies, and of all proper fees, expenses, liability and advances, including reasonable legal expenses and attorneys’ fees, incurred or made hereunder by Lender, including, without limitation, Lender’s Expenses;
(b) Second, to the payment to Lender of the amount then owing or unpaid on the Loans for any accrued and unpaid interest, the amounts which would have otherwise come due under Section 2.3(b)(ii), if the Loans had been voluntarily prepaid, the principal balance of the Loans, and all other Obligations with respect to the Loans (provided, however, if such proceeds shall be insufficient to pay in full the whole amount so due, owing or unpaid upon the Loans, then to the unpaid interest thereon, then to the amounts which would have otherwise come due under Section 2.3(b)(ii), if the Loans had been voluntarily prepaid, then to the principal balance of the Loans, and then to the payment of other amounts then payable to Lender under any of the Loan Documents); and
(c) Third, to the payment of the surplus, if any, to Borrower, its successors and assigns, or to the Person lawfully entitled to receive the same.
Withdrawals from the Collection Account and Distribution Account (a) The Master Servicer shall, from time to time, make withdrawals from the Collection Account for any of the following purposes or as described in Section 4.04:
(i) to remit to the Trustee for deposit in the Distribution Account the amounts required to be so remitted pursuant to Section 3.10(b) or permitted to be so remitted pursuant to the first sentence of Section 3.10(d);
(ii) subject to Section 3.16(d), to reimburse the Master Servicer for (a) any unreimbursed Advances to the extent of amounts received which represent Late Collections (net of the related Servicing Fees) of Monthly Payments, Liquidation Proceeds and Insurance Proceeds on Mortgage Loans with respect to which such Advances were made in accordance with the provisions of Section 4.04; (b) any unreimbursed Advances with respect to the final liquidation of a Mortgage Loan that are Nonrecoverable Advances, but only to the extent that Late Collections, Liquidation Proceeds and Insurance Proceeds received with respect to such Mortgage Loan are insufficient to reimburse the Master Servicer for such unreimbursed Advances; or (c) subject to Section 4.04(b), any unreimbursed Advances to the extent of funds held in the Collection Account for future distribution that were not included in Available Funds for the preceding Distribution Date;
(iii) subject to Section 3.16(d), to pay the Master Servicer or any Sub-Servicer (a) any unpaid Servicing Fees, (b) any unreimbursed Servicing Advances with respect to each Mortgage Loan, but only to the extent of any Late Collections, Liquidation Proceeds, Insurance Proceeds and condemnation proceeds received with respect to such Mortgage Loan, and (c) any Servicing Advances with respect to the final liquidation of a Mortgage Loan that are Nonrecoverable Advances, but only to the extent that Late Collections, Liquidation Proceeds and Insurance Proceeds received with respect to such Mortgage Loan are insufficient to reimburse the Master Servicer or any Sub-Servicer for Servicing Advances;
(iv) to pay to the Master Servicer as servicing compensation (in addition to the Servicing Fee) on the Master Servicer Remittance Date any interest or investment income earned on funds deposited in the Collection Account;
(v) to pay to the Originator, with respect to each Mortgage Loan that has previously been purchased or replaced pursuant to Section 2.03 or Section 3.16(c) all amounts received thereon subsequent to the date of purchase or substitution, as the case may be;
(vi) to reimburse the Master Servicer for any Advance or Servicing Advance previously made which the Master Servicer has determined to be a Nonrecoverable Advance in accordance with the provisions of Section 4.04;
(vii) to pay, or to reimburse the Master Servicer for Servicing Advances in respect of, expenses incurred in connection with any Mortgage Loan pursuant to Section 3.16(b);
(viii) to reimburse the Master Servicer for expenses incurred by or reimbursable to the Master Servicer pursuant to Section 6.03;
(ix) to reimburse the NIMS Insurer, the Master Servicer (if the Master Servicer is not an Affiliate of the Originator) or the Trustee, as the case may be, for enforcement expenses reasonably incurred in respect of the breach or defect giving rise to the purchase obligation under Section 2.03 of this Agreement that were included in the Purchase Price of the Mortgage Loan, including any expenses arising out of the enforcement of the purchase obligation;
