Peaceful Possession The Authority hereby warrants that: a) The Project Site has been acquired through the due process of law and belongs to and is vested with the Authority and that the Authority has full powers to hold, dispose of and deal with the same consistent, inter alia, with the provisions of this Agreement. b) In the event the Developer is obstructed by any Person claiming any right, title or interest in or over the Project Site or any part thereof, or in the event of any enforcement action including any attachment, distrait, appointment of receiver or liquidator being initiated by any Person claiming to have any interest in/charge or the Project Site or any part thereof, the Authority shall, if called upon by the Developer, defend such claims and proceedings and also keep the Developer indemnified against any consequential loss or damages which the Developer may suffer, on account of any such right, title, interest or charge.
Peaceful Enjoyment Tenant shall, and may peacefully have, hold, and enjoy the Premises, subject to the other terms hereof, provided that Tenant pays the Rent and other sums herein recited to be paid by Tenant and timely performs all of Tenant’s covenants and agreements herein contained. This covenant and any and all other covenants of Landlord shall be binding upon Landlord and its successors only with respect to breaches occurring during its or their respective periods of ownership of the Landlord’s interest hereunder.
Possession and Use of Collateral Subject to the provisions of the Security Documents, the Issuer and the Guarantors shall have the right to remain in possession and retain exclusive control of and to exercise all rights with respect to the Collateral (other than monies or U.S. government obligations deposited pursuant to Article VIII, and other than as set forth in the Security Documents and this Indenture), to operate, manage, develop, lease, use, consume and enjoy the Collateral (other than monies and U.S. government obligations deposited pursuant to Article VIII and other than as set forth in the Security Documents and this Indenture), to alter or repair any Collateral so long as such alterations and repairs do not impair the creation or perfection of the Lien of the Security Documents thereon, and to collect, receive, use, invest and dispose of the reversions, remainders, interest, rents, lease payments, issues, profits, revenues, proceeds and other income thereof.
Lessor's Default It shall be a breach of this Lease if Lessor fails to observe or perform any term, covenant or condition of this Lease on its part to be performed and such failure continues for a period of 30 days after Notice thereof from Lessee, unless such failure cannot with due diligence be cured within a period of 30 days, in which case such failure shall not be deemed a breach if Lessor proceeds within such 30-day period, with due diligence, to cure the failure and thereafter diligently completes the curing thereof. The time within which Lessor shall be obligated to cure any such failure also shall be subject to extension of time due to the occurrence of any Unavoidable Delay. If Lessor does not cure any such failure within the applicable time period as aforesaid, Lessee may declare the existence of a "Lessor Default" by a second Notice to Lessor. Thereafter, Lessee may forthwith cure the same in accordance with the provisions of Article 32, subject to the provisions of the following paragraph. Lessee shall have no right to terminate this Lease for any Lessor Default and no right, for any such Lessor Default, to offset or counterclaim against any Rent or other charges due hereunder. If Lessor shall in good faith dispute the occurrence of any Lessor Default and Lessor, before the expiration of the applicable cure period, shall give Notice thereof to Lessee, setting forth, in reasonable detail, the basis therefor, no Lessor Default shall be deemed to have occurred and Lessor shall have no obligation with respect thereto until final adverse determination thereof, whether through arbitration or otherwise; provided, however, that in the event of any such adverse determination, Lessor shall pay to Lessee interest on any disputed funds at the Base Rate, from the date demand for such funds was made by Lessee until the date of final adverse determination and, thereafter, at the Overdue Rate until paid. If Lessee and Lessor shall fail, in good faith, to resolve any such dispute within ten (10) days after Lessor's Notice of dispute, either may submit the matter for determination by arbitration, but only if such matter is required to be submitted to arbitration pursuant to any provision of this Lease, or otherwise by a court of competent jurisdiction.
Possession and Occupancy The Seller will deliver possession and occupancy of the Property to the Buyer at Closing. The Seller shall provide access to all locks, including keys, remote controls, and any security/access codes, necessary to operate all locks, mailboxes, and security systems.
Possession and Use Contractor may possess, use and reproduce Confidential Information solely for the Purpose. Contractor shall not use the Confidential Information for any other purpose.
Application of Payments and Proceeds Upon Default If an Event of Default has occurred and is continuing, Bank shall have the right to apply in any order any funds in its possession, whether from Borrower account balances, payments, proceeds realized as the result of any collection of Accounts or other disposition of the Collateral, or otherwise, to the Obligations. Bank shall pay any surplus to Borrower by credit to the Designated Deposit Account or to other Persons legally entitled thereto; Borrower shall remain liable to Bank for any deficiency. If Bank, directly or indirectly, enters into a deferred payment or other credit transaction with any purchaser at any sale of Collateral, Bank shall have the option, exercisable at any time, of either reducing the Obligations by the principal amount of the purchase price or deferring the reduction of the Obligations until the actual receipt by Bank of cash therefor.
POSSESSION AND OCCUPATION 3.1 The CONTRACTOR, its agents, servants and subcontractors shall at all times until the Works have been completed and the OWNER has signed and handed to the CONTRACTOR the final completion form, be entitled to enter and be present on the property for construction purposes. The CONTRACTOR shall further be entitled to enter into and be present on the property for purposes of completing minor works and snags listed on the snag list. 3.2 At no time whatsoever shall the OWNER be entitled to make claim, attach or in any way claim possession or retention of any of the CONTRACTOR's tools, equipment or building material and by signature hereof the OWNER waives all or any right which he may have acquired in this regard. 3.3 The OWNER shall be obliged to take occupation and possession of the Works at a date agreed upon between the parties but not later than 14 (fourteen) days after the handover date and it shall be incumbent on the OWNER to monitor progress of the Works in order to enable him to make whatever arrangements which may be necessary or required by him to: 3.3.1 take possession and occupation of the Works; 3.3.2 make payment of all or any amounts which may then still be due by him to the CONTRACTOR. 3.4 Should the OWNER fail to take occupation and possession of the Works as provided in clause 3.3 OR on such other date as may be agreed between the parties in writing – 3.4.1 it shall irrevocably be deemed for all purposes hereunder, that the OWNER has effectively and fully taken occupation and possession of the property and Works as set out in clause 3.3 and that all items on the snag list have been completed and accepted by the OWNER; 3.4.2 the CONTRACTOR shall not be responsible for any damages to the property after the deemed occupation date and the OWNER shall at his own cost provide security for the property against any vandalism and/or theft and/or any other damages thereto. 3.5 The CONTRACTOR shall, within 14 (fourteen) days from the commencement date as defined in clause 1.1.12, inform the OWNER of the estimated occupation date in writing. It is recorded that - 3.5.1 subject to the bond being registered and/or required proof regarding payment arrangements being submitted by the estimated building commencement date, the date on which the OWNER shall be able to occupy the property is estimated to be approximately 150 (one hundred and fifty) days after the commencement date, subject to the provisions of clause 5.6. 3.5.2 should the CONTRACTOR be unable to meet the estimated occupation date defined in clause 1.1.12 and referred to in clause 3.5.1, he shall be obliged to inform the OWNER in writing thereof at least 30 (thirty) days in advance.
Title to Properties; Possession Under Leases (a) Each of the Borrower and the Subsidiaries has valid title in fee simple or equivalent to, or valid leasehold interests in, or easements or other limited property interests in, all its Real Properties (including all Mortgaged Properties) and has valid title to its personal property and assets, in each case, except for Permitted Liens and except for defects in title that do not materially interfere with its ability to conduct its business as currently conducted or to utilize such properties and assets for their intended purposes and except where the failure to have such title would not reasonably be expected to have, individually or in the aggregate, a Material Adverse Effect. All such properties and assets are free and clear of Liens, other than Permitted Liens or Liens arising by operation of law. The Equity Interests of the Borrower owned by Holdings (prior to a Qualified IPO) are free and clear of Liens, other than Liens permitted by Article VIA. (b) The Borrower and each of the Subsidiaries has complied with all material obligations under all leases to which it is a party, except where the failure to comply would not reasonably be expected to have Material Adverse Effect, and all such leases are in full force and effect, except leases in respect of which the failure to be in full force and effect would not reasonably be expected to have a Material Adverse Effect. (c) As of the Closing Date, none of the Borrower and the Subsidiaries has received any written notice of any pending or contemplated condemnation proceeding affecting any material portion of the Mortgaged Properties or any sale or disposition thereof in lieu of condemnation that remains unresolved as of the Closing Date, except as set forth on Schedule 3.07(c). (d) As of the Closing Date, none of the Borrower and its Subsidiaries is obligated under any right of first refusal, option or other contractual right to sell, assign or otherwise Dispose of any Mortgaged Property or any interest therein, except as permitted under Section 6.02 or 6.05 or as would not reasonably be expected to have a Material Adverse Effect. (e) Schedule 1.01(E) lists each Material Real Property owned by any Loan Party as of the Closing Date.
GRANTOR'S RIGHT TO POSSESSION AND TO COLLECT ACCOUNTS Until default and except as otherwise provided below with respect to accounts, Grantor may have possession of the tangible personal property and beneficial use of all the Collateral and may use it in any lawful manner not inconsistent with this Agreement or the Related Documents, provided that Grantor's right to possession and beneficial use shall not apply to any Collateral where possession of the Collateral by Lender is required by law to perfect Lender's security interest in such Collateral. Until otherwise notified by Lender, Grantor may collect any of the Collateral consisting of accounts. At any time and even though no Event of Default exists, Lender may exercise its rights to collect the accounts and to notify account debtors to make payments directly to Lender for application to the Indebtedness. If Lender at any time has possession of any Collateral, whether before or after an Event of Default, Lender shall be deemed to have exercised reasonable care in the custody and preservation of the Collateral if Lender takes such action for that purpose as Grantor shall request or as Lender, in Lender's sole discretion, shall deem appropriate under the circumstances, but failure to honor any request by Grantor shall not of itself be deemed to be a failure to exercise reasonable care. Lender shall not be required to take any steps necessary to preserve any rights in the Collateral against prior parties, nor to protect, preserve or maintain any security interest given to secure the Indebtedness.
