Interested Party for the purpose of filing a dispute relating to a solicitation, as used in this section, means an actual or prospective bidder or offeror whose direct economic interest would be affected by the award of a Contract or by the failure to award a Contract.
Ownership and Publication of Materials All reports, information, data, and other materials prepared by the Consultant pursuant to this agreement are the property of the City. The City has the exclusive and unrestricted authority to release, publish or otherwise use, in whole or part, information relating thereto. Any re-use without written verification or adaptation by the Consultant for the specific purpose intended will be at the City’s sole risk and without liability or legal exposure to the Consultant. No material produced in whole or in part under this agreement may be copyrighted or patented in the United States or in any other country without the prior written approval of the City.
Confidentiality and Safeguarding of University Records; Press Releases; Public Information Under this Agreement, Contractor may (1) create, (2) receive from or on behalf of University, or (3) have access to, records or record systems (collectively, University Records). Among other things, University Records may contain social security numbers, credit card numbers, or data protected or made confidential or sensitive by Applicable Laws. [Option (Include if University Records are subject to FERPA.): Additional mandatory confidentiality and security compliance requirements with respect to University Records subject to the Family Educational Rights and Privacy Act, 20 United States Code (USC) §1232g (FERPA) are addressed in Section 12.41.] [Option (Include if University is a HIPAA Covered Entity and University Records are subject to HIPAA.): Additional mandatory confidentiality and security compliance requirements with respect to University Records subject to the Health Insurance Portability and Accountability Act and 45 Code of Federal Regulations (CFR) Part 160 and subparts A and E of Part 164 (collectively, HIPAA) are addressed in Section 12.26.] Contractor represents, warrants, and agrees that it will: (1) hold University Records in strict confidence and will not use or disclose University Records except as (a) permitted or required by this Agreement, (b) required by Applicable Laws, or (c) otherwise authorized by University in writing; (2) safeguard University Records according to reasonable administrative, physical and technical standards (such as standards established by the National Institute of Standards and Technology and the Center for Internet Security [Option (Include if Section 12.39 related to Payment Card Industry Data Security Standards is not include in this Agreement.):, as well as the Payment Card Industry Data Security Standards]) that are no less rigorous than the standards by which Contractor protects its own confidential information; (3) continually monitor its operations and take any action necessary to assure that University Records are safeguarded and the confidentiality of University Records is maintained in accordance with all Applicable Laws and the terms of this Agreement; and (4) comply with University Rules regarding access to and use of University’s computer systems, including UTS165 at xxxx://xxx.xxxxxxxx.xxx/board-of-regents/policy-library/policies/uts165-information-resources-use-and-security-policy. At the request of University, Contractor agrees to provide University with a written summary of the procedures Contractor uses to safeguard and maintain the confidentiality of University Records.
Reporting of Unauthorized Disclosure The Contractor shall immediately report to the State any unauthorized disclosure of confidential information.
Updated Information Submission by Developer The updated information submission by the Developer, including manufacturer information, shall occur no later than one hundred eighty (180) Calendar Days prior to the Trial Operation. Developer shall submit a completed copy of the Large Generating Facility data requirements contained in Appendix 1 to the Large Facility Interconnection Procedures. It shall also include any additional information provided to Connecting Transmission Owner for the Interconnection Feasibility Study and Interconnection Facilities Study. Information in this submission shall be the most current Large Generating Facility design or expected performance data. Information submitted for stability models shall be compatible with NYISO standard models. If there is no compatible model, the Developer will work with a consultant mutually agreed to by the Parties to develop and supply a standard model and associated information. If the Developer’s data is different from what was originally provided to Connecting Transmission Owner and NYISO pursuant to an Interconnection Study Agreement among Connecting Transmission Owner, NYISO and Developer and this difference may be reasonably expected to affect the other Parties’ facilities or the New York State Transmission System, but does not require the submission of a new Interconnection Request, then NYISO will conduct appropriate studies to determine the impact on the New York State Transmission System based on the actual data submitted pursuant to this Article 24.3. Such studies will provide an estimate of any additional modifications to the New York State Transmission System, Connecting Transmission Owner’s Attachment Facilities, or System Upgrade Facilities or System Deliverability Upgrades based on the actual data and a good faith estimate of the costs thereof. The Developer shall not begin Trial Operation until such studies are completed. The Developer shall be responsible for the cost of any modifications required by the actual data, including the cost of any required studies.
SUSPENSION BY STATE FOR CONVEVIENCE 14.4.1 The State may, without cause, order the Contractor in writing to suspend, delay or interrupt the Work in whole or in part for such period of time as the State may determine.
Incorporation of Solicitation The TIPS Solicitation, whether a Request for Proposals, the Request for Competitive Sealed Proposals or Request for Qualifications solicitation, the Vendor’s response to same and all associated documents and forms made part of the solicitation process, including any addenda, that resulted in the execution of this agreement are hereby incorporated by reference into this agreement as if copied verbatim. SECTION HEADERS OR TITLES THE SECTON HEADERS OR TITLES WITHIN THIS DOCUMENT ARE MERELY GUIDES FOR CONVENIENCE AND ARE NOT FOR CLASSIFICATION OR LIMITING OF THE RESPONSIBILITES OF THE PARTIES TO THIS DOCUMENT. NEW STATUTORY REQUIREMENT EFFETIVE SEPTEMBER 1, 2017. You certify that your company (1) does not boycott Israel; and (2) will not boycott Israel during the term of the Agreement. Texas governmental entities are prohibited from doing business with companies that fail to certify to this condition as required by Texas Government Code Sec. 2270. You certify that your company is not listed on and we do not do business with companies that are on the Texas Comptroller of Public Accounts list of Designated Foreign Terrorists Organizations per Texas Gov't Code 2270.0153 found at xxxxx://xxxxxxxxxxx.xxxxx.xxx/purchasing/docs/foreign-terrorist.pdf You certify that pursuant to Texas Business and Commerce Code Chapter 272, as revised September 1, 2017, any construction contract or agreement as defined in the Statute with a TIPS, Education Service Center Region 8 or a Texas TIPS Member subject to the Statute shall include a Choice of Law provision providing that this agreement shall be subject to and interpreted by the Laws of the State of Texas without regard to any conflict of laws principles for any action shall be in a court of competent jurisdiction in Texas and any arbitration shall be in the State of Texas. Pursuant to the Texas Business and Commerce Code, as amended by the 85th Texas Legislature, this Construction Agreement for Job Order Contract services is, in the event of a dispute between the parties, subject to interpretation according to the Laws of the state of Texas only, without regard to any conflict of laws principles. Venue for any alternative dispute resolution procedure or process shall be in the state of Texas. If the dispute is litigated, venue and jurisdiction shall be in a court of competent jurisdiction in the state of Texas. Pursuant to 85th Texas Legislative H.B. 3270, as it applies to Texas Education Code § 22.0834 et seq, the Vendor shall comply with all relevant sections related to student contact, background checks, fingerprinting and other related requirements. It is the intent of TIPS to award to reliable, high performance vendors to supply products and services to government and educational agencies. It is the experience of TIPS that the following procedures provide TIPS, the Vendor, and the participating agency the necessary support to facilitate a mutually beneficial relationship. The specific procedures will be negotiated with the successful vendor.
No Physical Presence of Quorum and Participation by Audio or Video; Disaster Declaration The ability of the Board to meet in person with a quorum physically present at its meeting location may be affected by the Governor or the Director of the Ill. Dept. of Public Health issuing a disaster declaration related to a public health emergency. The Board President or, if the office is vacant or the President is absent or unable to perform the office’s duties, the Vice President determines that an in- person meeting or a meeting conducted under the Quorum and Participation by Audio or Video Means subhead above, is not practical or prudent because of the disaster declaration; if neither the President nor Vice President are present or able to perform this determination, the Superintendent shall serve as the duly authorized designee for purposes of making this determination. The individual who makes this determination for the Board shall put it in writing, include it on the Board’s published notice and agenda for the audio or video meeting and in the meeting minutes, and ensure that the Board meets every OMA requirement for the Board to meet by video or audio conference without the physical presence of a quorum.
Limitations on Re-Disclosure The Provider shall not re-disclose Student Data to any other party or affiliate without the express written permission of the LEA or pursuant to court order, unless such disclosure is otherwise permitted under SOPPA, ISSRA, FERPA, and MHDDCA. Provider will not sell or rent Student Data. In the event another party, including law enforcement or a government entity, contacts the Provider with a request or subpoena for Student Data in the possession of the Provider, the Provider shall redirect the other party to seek the data directly from the LEA. In the event the Provider is compelled to produce Student Data to another party in compliance with a court order, Provider shall notify the LEA at least five (5) school days in advance of the court ordered disclosure and, upon request, provide the LEA with a copy of the court order requiring such disclosure.
Public Access to Nonprofit Records and Meetings If Contractor receives a cumulative total per year of at least $250,000 in City funds or City-administered funds and is a non-profit organization as defined in Chapter 12L of the San Francisco Administrative Code, Contractor must comply with the City’s Public Access to Nonprofit Records and Meetings requirements, as set forth in Chapter 12L of the San Francisco Administrative Code, including the remedies provided therein.
