Point of Application and Intake Process Sample Clauses

Point of Application and Intake Process. For each person applying for services, SDSI shall be the initial point of application and referral for such person. SDSI shall complete an intake process, which shall include, but is not limited to determination of the person’s intellectual disability and/or developmental disability eligibility as defined in the KDADS/CDDO Eligibility Determination Policy revised April 26, 2004.
Sample 1
AutoNDA by SimpleDocs

Related to Point of Application and Intake Process

  • Order of Application (a) If no Default or Potential Default exists, payments, and prepayments of the Obligation shall be applied first to fees then due, second to accrued interest then due and payable on the Principal Debt, and then to the remaining Obligation in the order and manner as Borrower may direct. (b) If a Default or Potential Default exists, any payment or prepayment (including proceeds from the exercise of any Rights) shall be applied to the Obligation in the following order: (i) to the payment of all fees, expenses, and indemnities for which Administrative Agent has not been paid or reimbursed in accordance with the Loan Papers; (ii) to the ratable payment of all fees, expenses, and indemnities (other than L/C fees set forth in Section 5.3 hereof (collectively, “L/C Fees”)) for which Lenders have not been paid or reimbursed in accordance with the Loan Papers (as used in this clause (ii), a “ratable payment” for any Lender shall be, on any date of determination, that proportion which the portion of the total fees, expenses, and indemnities owed to such Lender bears to the total aggregate fees, expenses, and indemnities owed to all Lenders on such date of determination); (iii) to the ratable payment of accrued and unpaid interest on the Principal Debt and L/C Fees (as used in this clause (iii), “ratable payment” means, for any Lender, on any date of determination, that proportion which the accrued and unpaid interest on the Principal Debt owed to such Lender bears to the total accrued and unpaid interest on the Principal Debt owed to all Lenders); (iv) to the ratable payment of the Principal Debt (as used in this clause (iv), “ratable payment” means for any Lender, on any date of determination, that proportion which the Principal Debt owed to such Lender bears to the Principal Debt owed to all Lenders); (v) to Administrative Agent for the account of the applicable L/C Issuer, to Cash Collateralize that portion of L/C Exposure comprised of the aggregate undrawn amount of L/Cs; (vi) to the payment of the remaining Obligation in the order and manner Required Lenders deem appropriate; and (vii) the balance, if any, after all of the Obligation has been indefeasibly paid in full, to Borrower or as otherwise required by Law. Subject to Section 2.3(c), amounts used to Cash Collateralize the aggregate undrawn amount of L/Cs pursuant to clause (v) above shall be applied to satisfy drawings under such L/Cs as they occur. If any amount remains on deposit as Cash Collateral after all L/Cs have either been fully drawn or expired, such remaining amount shall be applied to the other Obligation, if any, in the order set forth above. Subject to the provisions of Section 14 and provided that Administrative Agent shall not in any event be bound to inquire into or to determine the validity, scope, or priority of any interest or entitlement of any Lender and may suspend all payments or seek appropriate relief (including, without limitation, instructions from Required Lenders, Required Revolver Lenders or Required Term Loan Lenders or an action in the nature of interpleader) in the event of any doubt or dispute as to any apportionment or distribution contemplated hereby, Administrative Agent shall promptly distribute such amounts to each Lender in accordance with the Agreement and the related Loan Papers.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Notifications of Outages and Maintenance In the event that a Registry Operator plans maintenance, it will provide notice to the ICANN emergency operations department, at least, twenty-­‐four (24) hours ahead of that maintenance. ICANN’s emergency operations department will note planned maintenance times, and suspend Emergency Escalation services for the monitored services during the expected maintenance outage period. If Registry Operator declares an outage, as per its contractual obligations with ICANN, on services under a service level agreement and performance requirements, it will notify the ICANN emergency operations department. During that declared outage, ICANN’s emergency operations department will note and suspend emergency escalation services for the monitored services involved.

  • Normal order of application Except as any Finance Document may otherwise provide, any sums which are received or recovered by any Creditor Party under or by virtue of any Finance Document shall be applied: (a) FIRST: in or towards satisfaction of any amounts then due and payable under the Finance Documents and the Master Agreement in the following order and proportions: (i) first, in or towards satisfaction pro rata of all amounts then due and payable to the Creditor Parties under the Finance Documents other than those amounts referred to at paragraphs (ii) and (iii) (including, but without limitation, all amounts payable by the Borrower under Clauses 20, 21 and 22 of this Agreement or by the Borrower or any Security Party under any corresponding or similar provision in any other Finance Document or in the Master Agreement); (ii) secondly, in or towards satisfaction pro rata of any and all amounts of interest or default interest payable to the Creditor Parties under the Finance Documents and the Master Agreement (and, for this purpose, the expression “interest” shall include any net amount which the Borrower shall have become liable to pay or deliver under section 2(e) (Obligations) of the Master Agreement but shall have failed to pay or deliver to the relevant Swap Bank at the time of application or distribution under this Clause 17); and (iii) thirdly, in or towards satisfaction pro rata of the Loan and the Swap Exposure of the Swap Bank (in the case of the latter, calculated as at the actual Early Termination Date applying to each particular Designated Transaction, or if no such Early Termination Date shall have occurred, calculated as if an Early Termination Date occurred on the date of application or distribution hereunder); (b) SECONDLY: in retention of an amount equal to any amount not then due and payable under any Finance Document or the Master Agreement but which the Agent, by notice to the Borrower, the Security Parties and the other Creditor Parties, states in its opinion will or may become due and payable in the future and, upon those amounts becoming due and payable, in or towards satisfaction of them in accordance with the provisions of Clause 17.1(a); and

  • Scope of Application Except as otherwise provided in this Agreement, the dispute settlement provisions of this Chapter shall apply with respect to the settlement of all disputes between the Parties regarding the interpretation or application of this Agreement, whenever a Party considers that the other Party has failed to carry out its obligations under this Agreement.

  • Application of Receipts Except as expressly stated to the contrary in any Finance Document, any moneys which the Facility Agent receives or recovers in its capacity as Facility Agent shall be applied by the Facility Agent in accordance with Clause 35.5 (Application of receipts; partial payments).

  • County of Orange Child Support Enforcement Subrecipient certifies it is in full compliance with all applicable federal and state reporting requirements regarding its employees and with all lawfully served Wage and Earnings Assignment Orders and Notices of Assignments and will continue to be in compliance throughout the term of the Contract with the County of Orange. Failure to comply shall constitute a material breach of the Contract and failure to cure such breach within 60 calendar days of notice from the County shall constitute grounds for termination of the Contract.

  • Installation and Use Rights You may install and use any number of copies of the software on your devices.

  • General Application The rules set forth below in this Article VI shall apply for the purposes of determining each Member’s allocable share of the items of income, gain, loss and expense of the Company comprising Net Income or Net Loss for each Fiscal Year, determining special allocations of other items of income, gain, loss and expense, and adjusting the balance of each Member’s Capital Account to reflect the aforementioned general and special allocations. For each Fiscal Year, the special allocations in Section 6.03 hereof shall be made immediately prior to the general allocations of Section 6.02 hereof.

  • SUPERVISION AND CONSTRUCTION PROCEDURES 4.3.1 The Contractor shall supervise and direct the Work, using his / her best skill and attention. The Contractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract. All aspects of the Project shall be subject to the inspection and approval of the State. Contractor guarantees to repair, replace, re-execute or otherwise correct any defect in workmanship, materials, or the like that fails to conform to the requirements of this Contract or that appears during the progress of the Work or within one year of final acceptance by the State. 4.3.2 The Contractor shall be responsible to the State for the acts and omissions of his / her employees, Subcontractors and their agents and employees, and other persons performing any of the Work under a contract with the Contractor. 4.3.3 The Contractor shall not be relieved from his / her obligations to perform the Work in accordance with the Contract Documents either by the activities or duties of the Architect in his / her administration of the Contract, or by inspections, tests or approvals required or performed under Paragraph 7.7 by persons other than the Contractor. 4.3.4 The Contractor shall acquaint himself (herself / itself) with the limits of the property or right- of-way of the State and shall not trespass on other property. The Contractor shall adequately protect the project, adjacent property and the public, and shall be responsible for any damage or injury due to the Contractor’s act or neglect, and shall save the State harmless in respect thereto. 4.3.5 All work shall be done in such a manner as not to interfere with the State’s operating functions. Contractor and his employees shall familiarize themselves and comply with all rules and regulations applicable to the project. 4.3.6 The Contractor shall keep the premises free from liens arising out of or from the Project. Contractor shall obtain and submit waivers of liens with a request for a progress or final payment.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!