Maximum Contract Amount 4.4.1. Notwithstanding any other provision of this Agreement, the City’s maximum payment obligation will not exceed ($_) (the “Maximum Contract Amount”). The City is not obligated to execute an agreement or any amendments for any further services, including any services performed by the Contractor beyond that specifically described in Exhibit A. Any services performed beyond those in Exhibit A or performed outside the Term are performed at the Contractor’s risk and without authorization under this Agreement.
CONTRACT PRICE/PRICE LIMITATION/ PAYMENT 5.1 The contract price, method of payment, and terms of payment are identified and more particularly described in EXHIBIT C which is incorporated herein by reference.
CONTRACT AMOUNT Compensation amount(s), when stated in this Bid Specifications, shall not be construed as either the maximum or minimum amount which Department shall be obligated to accept as the result of this Bid Specifications or any Agreement entered into as a result of this Bid Specifications.
PURCHASE PRICE & PAYMENT The total Purchase Price for the Property is the amount of the successful bid for the parcel at public auction.
PRICE & PAYMENT Unless otherwise agreed:
SALES PRICE A. Cash portion of Sales Price payable by Buyer at closing $
Purchase Price Adjustment (a) As soon as reasonably practicable, following each Closing Date, Purchaser shall prepare, or shall cause to be prepared, a Final Closing Statement for each Target Business Segment that is the subject of such Closing and a certificate of the chief financial officer directly overseeing the Target Companies comprising such Target Business Segment certifying that the Final Closing Statement was prepared in accordance with the Agreed Accounting Principles and engage Deloitte and Touche LLP (or such other registered public accounting firm of international reputation which is mutually acceptable to Parent and Purchaser) (the “Accounting Expert”) to (i) audit the Final Closing Statement and issue a report thereon, and (ii) certify in writing to Parent and Purchaser that such audit was conducted in accordance with the terms hereof, and Purchaser shall cause such report and such certificate to be produced no later than 120 days following each Closing Date. The Accounting Expert shall be provided reasonable access to the books, records and other relevant information of the Target Companies, Purchaser, Parent and their respective Representatives, to the extent necessary to complete its audit of the Final Closing Statement, and Purchaser and Parent shall, and shall cause their Representatives (including the Subject Companies) to, make reasonably available their respective personnel directly responsible for and knowledgeable about the information to be used in, and reasonably necessary for the preparation of, such Final Closing Statement and in order to respond to inquiries made by the Accounting Expert, and Purchaser shall cause the Subject Companies to prepare and deliver customary management representation letters as may be requested by the Accounting Expert. Parent shall be provided reasonable access to the books, records and other relevant information of the Target Companies, Purchaser, and their respective Representatives (including the working papers of Parent and the Accounting Expert in connection with the preparation and audit of the applicable Final Closing Statement), and Purchaser and Parent shall, and shall cause their Representatives (including the Subject Companies) to, make reasonably available their respective personnel directly responsible for and knowledgeable about the information to be used in the Final Closing Statement in order to respond to inquiries made by Parent. The Final Closing Statement shall be final and binding and shall be used in determining the Adjustment Amount, absent manifest error. The fees and expenses of the Accounting Expert shall be borne by Parent.
ECONOMIC PRICE ADJUSTMENT is the adjustment to the Aircraft Basic Price (Base Airframe, Engine and Special Features) as calculated pursuant to Exhibit D.
Gross Settlement Amount Except as otherwise provided by Paragraph 8 below, Defendant promises to pay $290,000.00 and no more as the Gross Settlement Amount and to separately pay any and all employer payroll taxes owed on the Wage Portions of the Individual Class Payments. Defendant has no obligation to pay the Gross Settlement Amount (or any payroll taxes) prior to the deadline stated in Paragraph 4.3 of this Agreement. The Administrator will disburse the entire Gross Settlement Amount without asking or requiring Participating Class Members or Aggrieved Employees to submit any claim as a condition of payment. None of the Gross Settlement Amount will revert to Defendant.
Payment Amount Payment for the Services shall be as follows: (choose one) ☐ - $______________________ for the Services (“Payment”). ☐ - At an hourly rate of $____ per hour (“Payment”). ☐ - Other. ______________________________________________ (“Payment”) If the Subcontractor asserts a claim which involves, in whole or in part, acts or omissions which are the responsibility of the Client or another person for whom a claim may be submitted, including but not limited to, claims for failure to pay, an extension of time, impacts, delay damages, or extra work, the Contractor shall present the Subcontractor's claim to the Client or other responsible party provided the Subcontractor presents to Contractor competent supporting evidence and in sufficient time for the Contractor to do so. The Subcontractor shall cooperate fully with the Contractor in any and all steps the Contractor takes in connection with prosecuting such a claim and shall hold harmless and reimburse the Contractor for all expenses, including legal expenses, incurred by the Contractor which arise out of the Contractor's submission of the Subcontractor's claims to the Client or other responsible party(ies). The Subcontractor shall be bound by any adjudication or award in any action or proceeding resolving such a claim.
