Pricing Payment Terms Shipment Delivery and Inspection of Goods
Pricing Payment Terms Shipment Delivery and Inspection of Goods Sample Clauses
Related to Pricing Payment Terms Shipment Delivery and Inspection of Goods
DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.
Delivery Location All Goods shall be delivered to the address specified in this Order (the "Delivery Location") during Buyer's normal business hours or as otherwise instructed by Buyer.
Shipment Terms Seller shall ship Goods in the method identified by AGILENT to permit Seller to meet the delivery date(s) identified by AGILENT on the face of this Order (“Delivery Date”). If Seller ships by any other method, Seller shall pay any resulting increase in the cost of freight. Except as specified below, shipments of Goods shall be FCA (as that term is defined in the Incoterms 2010 handbook) Seller's place of shipment/export, and title and risk of loss or damage shall pass from Seller to AGILENT upon Seller's delivery of the Goods to the designated carrier at the place of shipment/export. If AGILENT agrees to pay for applicable freight charges and duties as part of the purchase price, shipment shall be DDP, and title and risk of loss or damage shall pass from Seller to AGILENT upon Seller’s delivery of the Goods to the "Ship To" address identified by AGILENT on the face of this Order.
Inspection of Goods 8.1 The Buyer shall inspect the goods upon delivery. 8.2 Where goods are damaged the Buyer shall notify the Supplier. The Buyer may reject the damaged goods and the following provisions shall apply: 8.2.1 the Supplier shall collect the damaged goods from the Buyer at the Supplier’s expense; 8.2.2 during the period between delivery of the goods to the Buyer and collection by the Supplier, the Buyer shall not be liable for any loss or further damage caused to the damaged goods; 8.2.3 all sums payable by the Buyer in relation to the damaged goods shall cease to become payable; 8.2.4 all sums paid by the Buyer in relation to the damaged goods shall be repaid by the Supplier immediately; 8.2.5 the Buyer shall be entitled to claim damages from the Supplier for any losses caused to the Buyer as a result of the goods being damaged. 8.3 Where there are shortages in the order the Buyer shall notify the Supplier and the following provisions shall apply: 8.3.1 all sums payable by the Buyer in relation to the missing goods shall cease to become payable; 8.3.2 all sums paid by the Buyer in relation to the missing goods shall be repaid by the Supplier immediately; 8.3.3 the Buyer shall be entitled to claim damages from the Supplier for any losses caused to the Buyer as a result of the shortages. 8.4 If the Buyer so requests, the Supplier shall immediately replace damaged goods or supply goods which are missing at the Supplier’s expense or the Buyer shall be entitled to cancel, without notice, the whole or any unexecuted part of the order and the rights referred to in Clause 5.2 shall apply. 8.5 Where there is an excess of goods in relation to the order the Buyer may reject the excess goods by notice in writing to the Supplier and the following provisions shall apply: 8.5.1 the Supplier shall collect the excess goods from the Buyer at the Supplier’s expense; 8.5.2 during the period between delivery of the goods and collection by the Supplier, the Buyer shall not be liable for any loss or damage caused to the excess goods; 8.5.3 no sum shall be due to the Supplier for the excess goods and in the event that sums are paid to the Supplier for the excess goods, the Supplier shall repay such sums to the Buyer immediately. 8.6 The Buyer may accept excess goods by notifying the Supplier of such acceptance and the price of the excess goods shall be payable by the Buyer. 8.7 The Supplier shall repair or replace free of charge, goods damaged or lost in transit upon receiving notice to that effect from the Buyer. 8.8 The Buyer’s signature on any delivery note of the Supplier is evidence of the number of packages received only and not evidence of the correct quantity of goods received or that the goods are in a good condition or of the correct quality.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Price Schedule, Payment Terms and Billing, and Price Adjustments (a) Price Schedule: Price Schedule under this Contract is set forth in Exhibit B.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Country Specific Terms Appendix A contains additional terms and conditions of the Agreement applicable to Participants residing in those countries. In addition, Appendix A also contains information and notices of exchange control and certain other issues of which the Participant should be aware.
DISTRIBUTION OF CONTRACTOR PRICE LIST AND CONTRACT APPENDICES Contractor shall provide Authorized Users with electronic copies of the Contract, including price lists and Appendices, upon request. Contract Updates will be handled as provided in Appendix C – Contract Modification Procedures.
Required Acceptance of Daily Load Deliveries and Notification If the State is harmed by purchaser’s refusal to accept up to 10 truck deliveries of any one sort per day, Purchaser will be in breach of contract and subject to damages as per the D-026.2 and D-027.2 clauses. A truck delivery is all the wood delivered including sorts on super trucks, mule trains and pups brought to the delivery point by a single truck. The Purchaser shall notify the Contract Administrator at least 48 hours in advance if: 1. Purchaser intends to limit the number of truck deliveries accepted on any day to less than that listed above, or 2. Purchaser intends to limit the number of truck deliveries accepted on any day to the number listed above.
