Procedure for Change of Scope 16.2.1 In the event of the Authority determining that a Change of Scope is necessary, it shall issue to the Concessionaire a notice specifying in reasonable detail the works and services contemplated thereunder (the “Change of Scope Notice”).
16.2.2 Upon receipt of a Change of Scope Notice, the Concessionaire shall, with due diligence, provide to the Authority such information as is necessary, together with preliminary Documentation in support of:
(a) the impact, if any, which the Change of Scope is likely to have on the Project Completion Schedule if the works or services are required to be carried out during the Construction Period; and
(b) the options for implementing the proposed Change of Scope and the effect, if any, each such option would have on the costs and time thereof, including a detailed breakdown by work classifications specifying the material and labour costs calculated in accordance with the schedule of rates applicable to the works assigned by the Authority to its contractors, along with the proposed premium/discount on such rates; provided that the cost incurred by the Concessionaire in providing such information shall be reimbursed by the Authority to the extent such cost is certified by the Independent Engineer as reasonable.
16.2.3 Upon receipt of information set forth in Clause 16.2.2, if the Authority decides to proceed with the Change of Scope, it shall convey its preferred option to the Concessionaire, and the Parties shall, with assistance of the Independent Engineer, thereupon make good faith efforts to agree upon the time and costs for implementation thereof. Upon reaching an agreement, the Authority shall issue an order (the “Change of Scope Order”) requiring the Concessionaire to proceed with the performance thereof. In the event that the Parties are unable to agree, the Authority may, by issuing a Change of Scope Order, require the Concessionaire to proceed with the performance thereof pending resolution of the Dispute, or carry out the works in accordance with Clause 16.5.
16.2.4 The provisions of this Agreement, insofar as they relate to Construction Works and Tests, shall apply mutatis mutandis to the works undertaken by the Concessionaire under this Article 16.
Procedure for Offer Subject to the terms hereof, Landlord shall notify Tenant (the “First Offer Notice”) prior to entering into any lease with a third party for the First Offer Space, which notice shall outline the base rent, allowance amounts if any, length of term, and other economic terms on which Landlord would be willing to lease the First Offer Space (as set forth in such proposal) to Tenant (the “Fundamental Terms”). Pursuant to such First Offer Notice, Landlord shall offer to lease to Tenant the applicable First Offer Space on the Fundamental Terms.
Procedure for Claims (1) In the event the Indemnitee is named as a party in any action, claim, suit, proceeding or investigation upon which the Indemnitee intends to base a claim for indemnification hereunder, the Indemnitee shall give the Indemnitor prompt written notice of such action, claim, suit, proceeding or investigation (provided, however, that failure of the Indemnitee to provide such notice shall not relieve the Indemnitor of any liability to the Indemnitee the Indemnitor may have under this Agreement except to the extent that the Indemnitor is materially prejudiced by such failure).
(2) The Indemnitor shall participate in and, assume the defence of any such action, including for certainty any derivative action, claim, suit, proceeding or investigation all at the Indemnitor's expense provided, however, that counsel retained by the Indemnitor shall be satisfactory to the Indemnitee in the exercise of his reasonable judgement. Notwithstanding the Indemnitor's assumption of the defense of such action, claim, suit, proceeding or investigation, the Indemnitee shall have the right to employ separate counsel and to participate in, but not control, the defense of such action, claim, suit, proceeding or investigation, and the Indemnitor shall bear the reasonable fees, costs and expenses of such separate counsel as such fees, costs and expenses are incurred (provided that with respect to any single action, claim, suit, proceeding or investigation, the Indemnitor shall not be required to bear the fees, costs and expenses of more than one such counsel in any single jurisdiction) if (a) the use of counsel chosen by the Indemnitor to represent the Indemnitee would present such counsel with a conflict of interest; (b) the defendants, respondents or other parties in any such action, claim, suit, proceeding or investigation include both the Indemnitee on the one hand and the Indemnitor on the other hand, and the Indemnitee has reasonably concluded that representation of both parties by the same counsel would be inappropriate due to actual or potential differing interests between them (in which case the Indemnitor shall not have the right to direct the defense of such action, claim, suit, proceeding or investigation on behalf of the Indemnitee); (c) the Indemnitor shall not have employed counsel satisfactory to the Indemnitee in the exercise of the Indemnitee's reasonable judgment to represent him, within a reasonable time after notice of the institution of such action, proceeding or investigation; or (d) the Indemnitor authorizes the Indemnitee to employ separate counsel at the Indemnitor's expense.
(3) The Indemnitee shall cooperate with the Indemnitor in the Indemnitor's defense by providing such information and other assistance which the Indemnitor may reasonably request in connection with such defense.
(4) The Indemnitor shall not, without the Indemnitee's prior written consent, settle, compromise, consent to the entry of any judgment in or otherwise seek to terminate any action, claim, suit or proceeding in respect of which indemnification may be sought hereunder (whether or not the Indemnitee is a party thereto) unless such settlement, compromise, consent or termination includes a release of the Indemnitee from any liabilities arising out of such action, claim, suit or proceeding. The Indemnitee shall not, without the Indemnitor's prior written consent, admit liability, settle, compromise, consent to the entry of any judgment in or otherwise seek to terminate any action, claim, suit, investigation or proceeding referred to in the preceding paragraph and the Indemnitee shall not disclose the existence of this Agreement unless required by law, subpoena, court order or upon the advice of counsel.
Procedure for taking possession - The Promoter, upon obtaining the occupancy certificate* from the competent authority shall offer in writing the possession of the [Apartment/Plot], to the Allottee in terms of this Agreement to be taken within two months from the date of issue of occupancy certificate. [Provided that, in the absence of local law, the conveyance deed in favour of the allottee shall be carried out by the promoter within 3 months from the date of issue of occupancy certificate]. The Promoter agrees and undertakes to indemnify the Allottee in case of failure of fulfilment of any of the provisions, formalities, documentation on part of the Promoter. The Allottee, after taking possession, agree(s) to pay the maintenance charges as determined by the Promoter/association of allottees, as the case may be after the issuance of the completion certificate for the project. The promoter shall hand over the occupancy certificate of the apartment/plot, as the case may be, to the allottee at the time of conveyance of the same.
Procedure for Third Party Claims The obligations and liabilities of each Party with respect to Third-Party Claims shall be subject to the following terms and conditions:
(i) Promptly upon receiving a written notice of a Third-Party Claim, the Indemnifying Party may elect, at its sole option, to undertake the defense thereof by outside counsel of its own choosing, which outside counsel shall be reasonably satisfactory to the Indemnified Party, by sending written notice of its election to the Indemnified Party; provided however, that if, in the Indemnified Party’s and the Indemnifying Party’s reasonable judgment, a conflict of interest exists between the Indemnified Party and the Indemnifying Party with respect to such Third-Party Claim, or if the Indemnifying Party elects not to defend or otherwise does not promptly defend such Third-Party Claim, such Indemnified Party shall be entitled to undertake the defense of, and to compromise or settle, such Third-Party Claim on behalf, for the account, and at the risk of the Indemnifying Party, to the extent that the Indemnifying Party is determined to be obligated to indemnify the Indemnified Party under this Agreement with respect to such Third-Party Claim. The written notice of the Third-Party Claim shall contain all material information known to the Indemnified Party with respect to such Third-Party Claim and shall include copies of materials submitted to Indemnified Party by the Third-Party with respect to such Third-Party Claim.
(ii) If the Indemnifying Party elects to undertake and diligently pursue the defense of a Third-Party Claim hereunder, the Indemnifying Party shall control all aspects of the defense and settlement of such Third-Party Claim and may settle, compromise or enter into a judgment with respect to such Third-Party Claim; provided that the Indemnifying Party shall not enter into any such settlement, compromise or judgment without the prior written consent of the Indemnified Party if such settlement, compromise or judgment would result in the imposition of any non-monetary liability or obligation on the Indemnified Party. If the Indemnifying Party assumes control of the defense under this Article 9, the Indemnified Party shall fully cooperate with the Indemnifying Party in connection therewith and may employ, at any time, a separate outside counsel to represent it; provided however, that the Indemnified Party shall be solely responsible for the costs and expenses of any such separate outside counsel. If the Indemnified Party undertakes the defense of a Third-Party Claim hereunder, the Indemnified Party shall not settle, compromise, or enter into any judgment with respect to such Third-Party Claim for which it is seeking or shall seek indemnification hereunder without the prior written consent of Indemnifying Party, which written consent shall not be unreasonably withheld, conditioned or delayed.
(iii) The Indemnified Party shall provide the Indemnifying Party with access to all reasonably requested records and documents of the Indemnified Party relating to any Third-Party Claim, other than documents for which the Indemnified Party has claimed or shall claim a legal privilege.
Procedure for Closing If Buyer shall not timely elect to terminate this Contract under Section 13.2 above, or if the loss, damage or condemnation is not substantial, Seller agrees to pay to Buyer at the Closing all insurance proceeds or condemnation awards which Seller has received as a result of the same, plus an amount equal to the insurance deductible, and assign to Buyer all insurance proceeds and condemnation awards payable as a result of the same, in which event the Closing shall occur without Seller replacing or repairing such damage. In the case of damage or casualty, at Buyer’s election, Seller shall repair and restore the Property to its condition immediately prior to such damage or casualty and shall assign to Buyer all excess insurance proceeds.
Procedure for Rebate The Association represents to the Board that an internal rebate procedure has been established in accordance with Section 4117.09(C) of the Revised Code and that a procedure for challenging the amount of the representation fee has been established and will be given to each member of the bargaining unit who does not join the Association and that such procedure and notice shall be in compliance with all applicable state and federal laws and the Constitutions of the United States and the State of Ohio.
GRIEVANCE PROCEDURE AND ARBITRATION 8.01 Any employee or the Union has the right to lodge a grievance with respect to any matter arising out of the interpretation, application or alleged violation of this Agreement.
8.02 At the time formal discipline is imposed or at any stage of the grievance procedure, including the complaint stage, a nurse is entitled to be represented by her/his union representative. In the case of suspension or discharge, the Employer shall notify the nurse of this right in advance. The Employer also agrees, as a good labour relations practice, it will also notify the Bargaining Unit.
8.03 It is the intent of the parties that complaints of employees shall be adjusted as quickly as possible, and it is understood that the Union has no grievance concerning an individual nurse until the Director of Care or her/his designate has been given an opportunity of adjusting the complaint. Such complaint shall be discussed with the Director of Care within fifteen (15) working days after the circumstances giving rise to it have occurred. This discussion may include consultation, advice and assistance from others. If there is no settlement within nine (9) working days, it shall then be taken up as a grievance within nine (9) working days in the following manner and sequence: The Union may present the grievance to the Administrator, or her/his designate, who shall render her/his decision within five (5) working days after the presentation of the grievance to her/him. The parties may, if they so desire, meet to discuss the grievance at a time and place suitable to both parties. If the decision is unsatisfactory, then the grievance may be presented in the following manner: Within ten (10) working days after the decision is given at Step No. 1, the aggrieved employee, and/or the Grievance Committee shall meet with a committee appointed by the Board of Directors of the Manor to consider the grievance. At this stage the employee and/or the Grievance Committee may be accompanied by a representative of the Union. The decision of the committee of the Board of Directors will be rendered in writing to the Labour Relations Officer and the bargaining unit representative within ten (10) working days following such a meeting.
GRIEVANCE PROCEDURE & ARBITRATION It is the mutual desire of the parties hereto that complaints of employees shall be adjusted as quickly as possible. If an employee has a complaint related to an alleged violation of the Collective Agreement may at option discuss it with immediate supervisor within three (3) days after the circumstances giving rise to the complaint (grieved action) have occurred or have or ought to have reasonably come to the attention of the employee. The Supervisor shall give a response to the complaint within three (3) days. These discussions will not establish precedent. Failing settlement, or failing a response to the complaint, it may be taken up as a grievance in the following manner and sequence: Procedure: Any employee or group of employees, for whom the Union is the bargaining agent, may refer grievances to the appropriate Union Xxxxxxx covered under this Collective Agreement. Grievances must be filed within fifteen (15) working days of grieved act or except where both parties agree to an extension of time. There is no grievance until an employee has reported complaint to the Supervisor. The grievance form shall contain a statement giving particulars of the grieved action, a statement as to the remedy sought and the provisions of the Agreement alleged to have been breached, provided that this does not preclude the or Employer from relying upon other provisions of the Agreement. Step Grievance form is completed in duplicate and signed by the employee and Union Xxxxxxx, presented to the Supervisor by the Union Xxxxxxx and (at their option). Both copies are to be returned by the Supervisor with signed comments to the Union Xxxxxxx within three (3) working days. Once a grievance has been filed no Supervisor or Employer Official shall discuss said grievance with the grieved employee except in the presence of a Xxxxxxx or Union Official. Step If satisfaction is not obtained in Step the Union Xxxxxxx, within five (5) working days, may refer the grievance to the Department Manager or designate, who will meet and discuss the grievance with the Union Xxxxxxx, (at their option) and the Human Resources Consultant then render a decision in writing on the prescribed forms within five
Procedure for Arbitration (1) The parties hereby agree that any controversy, dispute or claim arising out of, or relating to, this Agreement, or breach of this Agreement, including disputes concerning termination of this Agreement, shall be settled by arbitration in San Mateo, California. This agreement to arbitrate shall be specifically enforceable. Judgment upon any award rendered by an arbitrator may be entered in any court having jurisdiction.
(2) Any demand for arbitration must be served on the other party within forty-five (45) days of the act or omission giving rise to the controversy, dispute or claim.
(3) There shall be one impartial arbitrator chosen by the parties from a list procured from the California Mediation and Conciliation Service.
(4) The arbitrator shall not extend, modify or suspend any of the terms of this Agreement.
(5) The decision of the Arbitrator within the scope of the submission shall be final and binding on all parties, and any right to judicial action on any matter subject to arbitration hereunder is hereby waived (unless otherwise provided by applicable law), except suit to enforce this arbitration award.
(6) Executive agrees that such arbitration shall be the exclusive forum for any controversy, dispute or claim arising out of or relating to this Agreement, or breach or termination of this Agreement. Executive further expressly agrees that in arbitration his exclusive remedy shall be a money award not to exceed the amount of wages he would have earned under this Agreement but for the alleged violation and the Executive shall not be entitled to any other remedy, at law or in equity, including but not limited to reinstatement, other money damages, punitive damages and/or injunctive relief.
(7) Each party shall pay such party's own attorney or other representative, and the expenses of such party's witnesses and all other expenses connected with his case. Other costs of the arbitration, including the cost of any record or transcript of the arbitration, administrative fees, arbitrator's fees, and all other fees and costs, shall be borne by the Corporation; provided, however, that at the discretion of the Arbitrator, and upon a preponderance of the evidence that one of the parties has engaged in malice, fraud or oppression relating to the termination of the Executive's employment, reasonable attorney's fees and costs may be awarded to the other party.
