Procedure for Disbursement of Construction Loan Advances Sample Clauses

Procedure for Disbursement of Construction Loan Advances 
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs

Related to Procedure for Disbursement of Construction Loan Advances

  • Disbursement of Advances (a) Upon receiving any Request for Revolving Credit Advance from Borrowers under Section 2.3 hereof, Agent shall promptly notify each Revolving Credit Lender by wire, telex or telephone (confirmed by wire, telecopy or telex) of the amount of such Advance being requested and the date such Revolving Credit Advance is to be made by each Revolving Credit Lender in an amount equal to its Revolving Credit Percentage of such Advance. Unless such Revolving Credit Lender’s commitment to make Revolving Credit Advances hereunder shall have been suspended or terminated in accordance with this Agreement, each such Revolving Credit Lender shall make available the amount of its Revolving Credit Percentage of each Revolving Credit Advance in immediately available funds to Agent, as follows: (i) for Prime-based Advances, at the office of Agent located at Xxx Xxxxxxx Xxxxxx, Xxxxxxx, Xxxxxxxx 00000, not later than 1:00 p.m. (Detroit time) on the date of such Advance; and (ii) for Eurodollar-based Advances, at the Agent’s Correspondent for the account of the Eurodollar Lending Office of the Agent, not later than 12:00 p.m. (the time of the Agent’s Correspondent) on the date of such Advance. (b) Subject to submission of an executed Request for Revolving Credit Advance by Borrowers without exceptions noted in the compliance certification therein, Agent shall make available to Borrowers the aggregate of the amounts so received by it from the Revolving Credit Lenders in Dollars: (i) for Prime-based Advances, not later than 4:00 p.m. (Detroit time) on the date of such Revolving Credit Advance, by credit to an account of Borrowers maintained with Agent or to such other account or third party as Borrowers may reasonably direct in writing, provided such direction is timely given; and (ii) for Eurodollar-based Advances, not later than 4:00 p.m. (the time of the Agent’s Correspondent) on the date of such Revolving Credit Advance, by credit to an account of Borrowers maintained with Agent’s Correspondent or to such other account or third party as Borrowers may direct, provided such direction is timely given. (c) Agent shall deliver the documents and papers received by it for the account of each Revolving Credit Lender to such Revolving Credit Lender. Unless Agent shall have been notified by any Revolving Credit Lender prior to the date of any proposed Revolving Credit Advance that such Revolving Credit Lender does not intend to make available to Agent such Revolving Credit Lender’s Percentage of such Advance, Agent may assume that such Revolving Credit Lender has made such amount available to Agent on such date, as aforesaid. Agent may, but shall not be obligated to, make available to Borrowers the amount of such payment in reliance on such assumption. If such amount is not in fact made available to Agent by such Revolving Credit Lender, as aforesaid, Agent shall be entitled to recover such amount on demand from such Revolving Credit Lender. If such Revolving Credit Lender does not pay such amount forthwith upon Agent’s demand therefor and the Agent has in fact made a corresponding amount available to Borrowers, the Agent shall promptly notify Borrowers and Borrowers shall pay such amount to Agent, if such notice is delivered to Borrowers prior to 1:00 p.m. (Detroit time) on a Business Day, on the day such notice is received, and otherwise on the next Business Day, and such amount paid by Borrowers shall be applied as a prepayment of the Revolving Credit (without any corresponding reduction in the Revolving Credit Aggregate Commitment), reimbursing Agent for having funded said amounts on behalf of such Revolving Credit Lender. The Borrowers shall retain their claims against such Revolving Credit Lender with respect to the amounts repaid by it to Agent and, if such Revolving Credit Lender subsequently makes such amounts available to Agent, Agent shall promptly make such amounts available to the Borrowers as a Revolving Credit Advance. Agent shall also be entitled to recover from such Revolving Credit Lender or Borrowers, as the case may be, but without duplication, interest on such amount in respect of each day from the date such amount was made available by Agent to Borrowers, to the date such amount is recovered by Agent, at a rate per annum equal to: (i) in the case of such Revolving Credit Lender, for the first two (2) Business Days such amount remains unpaid, the Federal Funds Effective Rate, and thereafter, at the rate of interest then applicable to such Revolving Credit Advances; and (ii) in the case of Borrowers, the rate of interest then applicable to such Advance of the Revolving Credit. Until such Revolving Credit Lender has paid Agent such amount, such Revolving Credit Lender shall have no interest in or rights with respect to such Advance for any purpose whatsoever. The obligation of any Revolving Credit Lender to make any Revolving Credit Advance hereunder shall not be affected by the failure of any other Revolving Credit Lender to make any Advance hereunder, and no Revolving Credit Lender shall have any liability to the Borrowers or any of their respective Subsidiaries, the Agent, any other Revolving Credit Lender, or any other party for another Revolving Credit Lender’s failure to make any loan or Advance hereunder.

  • Disbursement of Advance Proceeds All Advances shall be disbursed from whichever office or other place Agent may designate from time to time and, together with any and all other Obligations of Borrowers to Agent or Lenders, shall be charged to Borrowers' Account on Agent's books. During the Term, Borrowers may use the Revolving Advances by borrowing, prepaying and reborrowing, all in accordance with the terms and conditions hereof. The proceeds of each Revolving Advance requested by Borrowers or deemed to have been requested by Borrowers under Section 2.2(a) hereof shall, with respect to requested Revolving Advances to the extent Lenders make such Revolving Advances, be made available to the applicable Borrower on the day so requested by way of credit to such Borrower's operating account at PNC, or such other bank as Borrowing Agent may designate following notification to Agent, in immediately available federal funds or other immediately available funds or, with respect to Revolving Advances deemed to have been requested by any Borrower, be disbursed to Agent to be applied to the outstanding Obligations giving rise to such deemed request.

  • Disbursement of Loan Proceeds (a) The Trustee, as the agent of the Trust, shall disburse the amounts on deposit in the Project Loan Account to the Borrower upon receipt of a requisition executed by an Authorized Officer of the Borrower, and approved by the Trust, in a form meeting the requirements of Section 5.02(3) of the Bond Resolution. (b) The Trust and Trustee shall not be required to disburse any Loan proceeds to the Borrower under this Loan Agreement, unless: (i) the proceeds of the Trust Bonds shall be available for disbursement, as determined solely by the Trust; (ii) in accordance with the Bond Act, and the Regulations, the Borrower shall have timely applied for, shall have been awarded and, prior to or simultaneously with the Loan Closing, shall have closed a Fund Loan for a portion of the Allowable Costs (as defined in such Regulations) of the Project in an amount not in excess of the amount of Allowable Costs of the Project financed by the Loan from the Trust; (iii) the Borrower shall have on hand moneys to pay for the greater of (A) that portion of the total Costs of the Project that is not eligible to be funded from the Fund Loan or the Loan, or (B) that portion of the total Costs of the Project that exceeds the actual amounts of the loan commitments made by the State and the Trust, respectively, for the Fund Loan and the Loan; and (iv) no Event of Default nor any event that, with the passage of time or service of notice or both, would constitute an Event of Default shall have occurred and be continuing hereunder.

  • Certificates for Reimbursement; Repayment of Outstanding Loans; Borrowing of New Loans A certificate of a Lender or the Issuing Lender setting forth the amount or amounts necessary to compensate such Lender or the Issuing Lender or its holding company, as the case may be, as specified in Sections 5.8.1 [Increased Costs Generally] or 5.

  • Disbursement of Loans Not later than 1:00 p.m. (Chicago time) on the date of any requested advance of a new Borrowing, subject to Section 7 hereof, each Lender shall make available its Loan comprising part of such Borrowing in funds immediately available at the principal office of the Administrative Agent in Chicago, Illinois (or at such other location as the Administrative Agent shall designate). The Administrative Agent shall make the proceeds of each new Borrowing available to the Borrower on the date of such Borrowing as instructed by the Borrower.

  • Notification of Advances, Interest Rates, Prepayments and Commitment Reductions Promptly after receipt thereof, the Agent will notify each Lender of the contents of each Aggregate Commitment reduction notice, Borrowing Notice, Conversion/Continuation Notice, and repayment notice received by it hereunder. The Agent will notify each Lender of the interest rate applicable to each Eurodollar Advance promptly upon determination of such interest rate and will give each Lender prompt notice of each change in the Alternate Base Rate.

  • Advances; Reimbursement of Advances (a) From time to time, (i) pursuant to terms of the Servicing Agreement, the Lead Servicer and/or the related Trustee may be obligated to make (1) Property Advances with respect to the Mortgage Loan or the Mortgaged Property and (2) P&I Advances with respect to the Lead Note and (ii) pursuant to the terms of the Non-Lead Servicing Agreement, the related Non-Lead Master Servicer and/or the related Trustee may be obligated to make P&I Advances with respect to the Non-Lead Note. The Lead Servicer and/or the related Trustee will not be required to make any P&I Advance with respect to the Non-Lead Note and the related Non-Lead Master Servicer and/or the related Trustee will not be required to make any P&I Advance with respect to any Lead Note or any Property Advance. The Lead Servicer, the Non-Lead Master Servicer and any Trustee will be entitled to interest on any Advance made in the manner and from the sources provided in the Note A-1 PSA and the Note A-2 PSA, as applicable. (b) The Lead Servicer and the related Trustee, as applicable, will be entitled to reimbursement for a Property Advance, first from the Collection Account established with respect to the Mortgage Loan, and then, if such Property Advance is a Nonrecoverable Advance, if such funds on deposit in the Collection Account are insufficient, from general collections of the Lead Securitization as provided in the Servicing Agreement. (c) To the extent amounts on deposit in the Collection Account with respect to the Mortgage Loan are insufficient to reimburse the Lead Servicer for any Property Advance and/or interest thereon and the Lead Servicer or the related Trustee, as applicable, obtains funds from general collections of the Lead Securitization as a reimbursement for a Property Advance or interest thereon, the Non-Lead Note Holder (including any Securitization into which the Non-Lead Note is deposited) shall be required to, promptly following notice from the Lead Servicer, pay to the Lead Securitization for its pro rata share of such Property Advance and/or interest thereon at the Reimbursement Rate. In addition, the Non-Lead Note Holder (including any Securitization into which the Non-Lead Note is deposited) shall promptly reimburse the Lead Servicer or the related Trustee for the Non-Lead Note Holder’s pro rata share of any fees, costs or expenses incurred in connection with the servicing and administration of the Mortgage Loan as to which the Lead Securitization or any of the parties thereto are entitled to be reimbursed pursuant to the terms of the Servicing Agreement (to the extent amounts on deposit in the Collection Account with respect to the Mortgage Loan are insufficient for reimbursement of such amounts). (d) The parties to each of the Note A-1 PSA and the Note A-2 PSA shall each be entitled to make their own recoverability determination with respect to a P&I Advance based on the information that they have on hand and in accordance with the Note A-1 PSA and the Note A-2 PSA, as applicable. (e) If the Lead Servicer or the related Trustee elects to defer the reimbursement of a Property Advance in accordance with the terms of the Servicing Agreement, the Lead Servicer or the related Trustee shall also defer its reimbursement of the Non-Lead Note share from the Non-Lead Note Holder.

  • Construction Loan Subject to the terms and conditions of this Agreement and in reliance upon the representations and warranties set forth in this Agreement, the Lender has agreed to lend to Borrower and Borrower has agreed to borrow from Lender the lesser of: (i) $27,000,000.00; or (ii) 55% of the Project Costs. Such amount shall be loaned by Lender pursuant to the terms and conditions set forth in this Agreement and the First Supplement to this Agreement.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • No Construction Loans No Mortgage Loan was made in connection with (i) the construction or rehabilitation of a Mortgage Property or (ii) facilitating the trade-in or exchange of a Mortgaged Property other than a construction-to-permanent loan which has converted to a permanent Mortgage Loan;

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!