Defense and Indemnification a. The Contractor hereby agrees to defend, indemnify, reimburse and hold harmless the City, its appointed and elected officials, agents and employees for, from and against all liabilities, claims, judgments, suits or demands for damages to persons or property arising out of, resulting from, or relating to the work performed under this Agreement (“Claims”), unless such Claims have been specifically determined by the trier of fact to be the sole negligence or willful misconduct of the City. This indemnity shall be interpreted in the broadest possible manner to indemnify the City for any acts or omissions of the Contractor or its subcontractors either passive or active, irrespective of fault, including the City’s concurrent negligence whether active or passive, except for the sole negligence or willful misconduct of the City.
Procedures Related to Indemnification In the event that an indemnity obligation arises, Vendor shall pay all amounts set forth in Section 14 and 15 above (including any settlements) and – if it has accepted its indemnity obligation without qualification – control the legal defense to such claim or cause of action, including without limitation attorney selection, strategy, discovery, trial, appeal, and settlement, and TIPS shall, at Vendor’s cost and expense (with respect to reasonable out of pocket costs and expenses incurred by TIPS which shall be reimbursed to TIPS by Vendor), provide all commercially reasonable assistance requested by Vendor. In controlling any defense, Vendor shall ensure that all assertions of governmental immunity and all applicable pleas and defenses shall be promptly asserted.
Indemnification Against Third-Party Claims Each Party (the Indemnifying Party) agrees to indemnify, defend, and hold harmless the other Party (the Indemnified Party) and the other Party’s Subsidiaries, predecessors, successors, Affiliates, and assigns, and all current and former officers, directors, members, shareholders, agents, contractors and employees of all such persons and entities (collectively, with Indemnified Party, the “Indemnitee Group”), from any and all Claims (as hereinafter defined).
Release and Indemnification CLIENT hereby releases TAILGATE GUYS and agrees to indemnify and defend TAILGATE GUYS and save TAILGATE GUYS harmless from and against all suits, actions, damages, liability and expenses in connection with loss of life, body or personal injury or property damage (and each and all of them) arising from or out of any occurrence in and around the Site or any part thereof, or occasioned wholly or in part by any act or omission of CLIENT, its invitees, and guests.
NOTICE OF INDEMNIFICATION CLAIMS If the Town seeks indemnification pursuant to this Article 13.2, it shall notify Competitive Supplier of the existence of a claim, or potential claim as soon as practicable after learning of such claim, or potential claim, describing with reasonable particularity the circumstances giving rise to such claim. Upon written acknowledgment by the Competitive Supplier that it will assume the defense and indemnification of such claim, the Competitive Supplier may assert any defenses which are or would otherwise be available to the Town.
HOLD HARMLESS AND INDEMNIFICATION A. The Consultant shall defend, indemnify, and hold the City, its officers, officials, employees, and volunteers harmless from any and all claims, injuries, damages, losses, or suits including attorney fees, arising out of or resulting from the acts, errors, or omissions of the Consultant in performance of this Agreement, except for injuries and damages caused by the sole negligence of the City.
Indemnification Claims (a) In the event that any of the Parties are entitled, or seek to assert rights, to indemnification under this Article VI, the Party or Parties seeking indemnification (the “Indemnified Parties”) shall give written notification to the other Party or Parties (the “Indemnifying Parties”) of the commencement of any suit or proceeding relating to a third party claim for which indemnification pursuant to this Article VI may be sought. Such notification shall be given within 20 Business Days after receipt by the Indemnified Parties of notice of such suit or proceeding, and shall describe in reasonable detail (to the extent known by the Indemnified Parties) the facts constituting the basis for such suit or proceeding and the amount of the claimed damages; provided, however, that no delay on the part of the Indemnified Parties in notifying the Indemnifying Parties shall relieve the Indemnifying Parties of any liability or obligation hereunder except to the extent of any damage or liability caused by or arising out of such failure. Within 20 days after delivery of such notification, the Indemnifying Parties may, upon written notice thereof to the Indemnified Parties seeking indemnification, assume control of the defense of such suit or proceeding with counsel reasonably satisfactory to the Indemnified Party seeking indemnification; provided that the Indemnifying Parties may not assume control of the defense of a suit or proceeding involving criminal liability or in which equitable relief is sought against the Indemnified Party seeking indemnification. If the Indemnifying Parties do not so assume control of such defense, the Indemnified Parties seeking indemnification shall control such defense. The Party not controlling such defense (the “Non-Controlling Party”) may participate therein at its own expense; provided that if the Indemnifying Parties assumes control of such defense and the Indemnified Parties seeking indemnification reasonably concludes that the Indemnifying Parties and the Indemnified Parties seeking indemnification have conflicting interests or different defenses available with respect to such suit or proceeding, the reasonable fees and expenses of counsel to the Indemnified Parties shall be considered “Damages” for purposes of this Agreement. The Party or Parties controlling such defense (the “Controlling Party”) shall keep the Non-Controlling Party advised of the status of such suit or proceeding and the defense thereof and shall consider in good faith recommendations made by the Non-Controlling Party with respect thereto. The Non-Controlling Party shall furnish the Controlling Party with such information as it may have with respect to such suit or proceeding (including copies of any summons, complaint or other pleading which may have been served on such party and any written claim, demand, invoice, billing or other document evidencing or asserting the same) and shall otherwise cooperate with and assist the Controlling Party as reasonably needed in the defense of such suit or proceeding at the sole cost and expense of the Indemnifying Parties under Section 6.1 or 6.2, which cost and expense shall be considered “Damages” for purposes of this Agreement. The Indemnifying Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnified Parties, which shall not be unreasonably withheld or delayed; provided that the consent of the Indemnified Parties shall not be required if the Indemnifying Parties agrees in writing to pay any amounts payable pursuant to such settlement or judgment and such settlement or judgment includes a complete release of the Indemnified Parties from further liability and has no other materially adverse effect on the Indemnified Parties. The Indemnified Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnifying Parties, which shall not be unreasonably withheld or delayed.
Indemnification Procedure Any person obligated to provide indemnification under this Article VIII ("Indemnifying Party" for the purpose of this Section 8.3) will not be liable under the indemnification provisions of this Article VIII with respect to any claim made against a party entitled to indemnification under this Article VIII ("Indemnified Party" for the purpose of this Section 8.3) unless such Indemnified Party will have notified the Indemnifying Party in writing within a reasonable time after the summons or other first legal process giving information of the nature of the claim will have been served upon such Indemnified Party (or after such party will have received notice of such service on any designated agent), but failure to notify the Indemnifying Party of any such claim will not relieve the Indemnifying Party from any liability which it may have to the Indemnified Party against whom such action is brought otherwise than on account of the indemnification provision of this Article VIII, except to the extent that the failure to notify results in the failure of actual notice to the Indemnifying Party and such Indemnifying Party is damaged solely as a result of failure to give such notice. In case any such action is brought against the Indemnified Party, the Indemnifying Party will be entitled to participate, at its own expense, in the defense thereof. The Indemnifying Party also will be entitled to assume the defense thereof, with counsel satisfactory to the party named in the action. After notice from the Indemnifying Party to the Indemnified Party of the Indemnifying Party's election to assume the defense thereof, the Indemnified Party will bear the fees and expenses of any additional counsel retained by it, and the Indemnifying Party will not be liable to such party under this Agreement for any legal or other expenses subsequently incurred by such party independently in connection with the defense thereof other than reasonable costs of investigation, unless: (a) the Indemnifying Party and the Indemnified Party will have mutually agreed to the retention of such counsel; or (b) the named parties to any such proceeding (including any impleaded parties) include both the Indemnifying Party and the Indemnified Party and representation of both parties by the same counsel would be inappropriate due to actual or potential differing interests between them. The Indemnifying Party will not be liable for any settlement of any proceeding effected without its written consent but if settled with such consent or if there is a final judgment for the plaintiff, the Indemnifying Party agrees to indemnify the Indemnified Party from and against any loss or liability by reason of such settlement or judgment. A successor by law of the parties to this Agreement will be entitled to the benefits of the indemnification contained in this Article VIII. The indemnification provisions contained in this Article VIII will survive any termination of this Agreement.
Procedure for Claiming Indemnity 14.2.1 Third party claims
SECTION 11 – INDEMNIFICATION 11.1 Employee shall use due care in the performance of his obligations under the Agreement. If an action or proceeding is brought against Employee arising out of the performance of his duties, then:
