Right to suspend 2.1.1 Network Rail may serve a Suspension Notice where a Train Operator Event of Default has occurred and is continuing.
City’s Right to Suspend for Convenience City may suspend all or any portion of Contractor’s performance under this Contract at its sole option and for its convenience for a reasonable period of time not to exceed six (6) months. City must first give ten (10) days’ written notice to Contractor of such suspension. City will pay to Contractor a sum equivalent to the reasonable value of the goods and/or services satisfactorily provided up to the date of suspension. City may rescind the suspension prior to or at six (6) months by providing Contractor with written notice of the rescission, at which time Contractor would be required to resume performance in compliance with the terms and provisions of this Contract. Contractor will be entitled to an extension of time to complete performance under the Contract equal to the length of the suspension unless otherwise agreed to in writing by the Parties.
Owner’s Right to Suspend Work The Owner reserves the right, with or without the concurrence of the Design Professional, to suspend the Work at any time or from time to time at the Owner's sole discretion, upon giving Contractor five days advanced written notice thereof. If the Owner exercises this right and then resumes the Work covered hereby, Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the suspension and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's suspension, to include compensation based upon the rate for Time Dependent Overhead Costs. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
STATE's Right to Suspend the Operations The STATE and/or the STATE's Authorized Representative has the authority to suspend portions or all of the operations due to causes including, but not limited to:
Right to Subcontract The Carrier at its discretion may subcontract on any terms the whole or any part of the Carriage.
Effect of Attachment or Sequestration of Accounts You shall not be liable for refusing to obey any orders given by or for Me with respect to any account(s) that has or have been subject to an attachment or sequestration in any legal proceeding against Me, and You shall be under no obligation to contest the validity of any such attachment or sequestration.
Suspension and Termination of Procedure 1. The disputing Parties may agree to suspend the work of the Panel at any time for a period not exceeding 12 months following the date of such agreement. In any event, if the work of the Panel has been suspended for more than 12 months, the authority of the Panel shall lapse, unless the disputing Parties agree otherwise. If the authority of the Panel lapses and the disputing Parties have not reached an agreement on the settlement of the dispute, nothing in this Article shall prevent a Party from requesting a new proceeding regarding the same matter. 2. At any time prior to the release of the Panel report, the Parties may agree to terminate the procedures before a Panel by jointly notifying the chair of the Panel on this respect.
APPLICABILITY TO SUBCONTRACTORS Respondent agrees that all contracts it awards pursuant to the contract awarded as a result of this Agreement will be bound by the foregoing terms and conditions.
Authority to Sign If this document is not signed by all of the persons comprising the Supplier, any person who has signed this document warrants to DFMC that it is duly authorised to sign and bind all the persons comprising the Supplier.
Suspension and Termination of Proceedings 1. Where the Parties agree, the arbitral tribunal may suspend its work at any time for a period not exceeding 12 months from the date of such agreement. If the work of the arbitral tribunal has been suspended for more than 12 months, the authority for establishment of the tribunal shall lapse unless the Parties agree otherwise.
