Procurement of Recovered Materials (1) In the performance of this contract, the Contractor shall make maximum use of products containing recovered materials that are EPA-designated items unless the product cannot be acquired
PROCUREMENT OF RECOVERED MATERIAL H-GAC and the Respondent must comply with section 6002 of the Solid Waste Disposal Act, as amended by the Resource Conservation and Recovery Act. The requirements of Section 6002 include: (1) procuring only items designated in guidelines of the Environmental Protection Agency (EPA) at 40 CFR part 247 that contain the highest percentage of recovered materials practicable, consistent with maintaining a satisfactory level of competition, where the purchase price of the item exceeds $10,000 or the value of the quantity acquired during the preceding fiscal year exceeded $10,000; (2) procuring solid waste management services in a manner that maximizes energy and resource recovery; and (3) establishing an affirmative procurement program for procurement of recovered materials identified in the EPA guidelines. Pursuant to the Federal Rule above, as required by the Resource Conservation and Recovery Act of 1976 (42 U.S.C. § 6962(c)(3)(A)(i)), Respondent certifies that the percentage of recovered materials content for EPA-designated items to be delivered or used in the performance of the Contract will be at least the amount required by the applicable contract specifications or other contractual requirements. A RTICLE 40: XXXXXXXX “ANTI-KICKBACK” ACT Contractor shall comply with 18 U.S.C. § 874, 40 U.S.C. § 3145, and the requirements of 29 C.F.R. pt. 3 as may be applicable, which are incorporated by reference into the contract. The contractor or subcontractor shall insert in any subcontracts the clause above and such other clauses as appropriate agency instructions require, and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The prime contractor shall be responsible for the compliance by any subcontractor or lower tier subcontractor with all of these contract clauses. A breach of the contract clauses above may be grounds for termination of the Contract, and for debarment as a contractor and subcontractor as provided in 29 C.F.R. § 5.12.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 2
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract.
Procurement of Small Works Works estimated to cost less than $100,000 equivalent per contract, up to an aggregate amount not to exceed $1,150,000 equivalent, may be procured under lump-sum, fixed-price contracts awarded on the basis of quotations obtained from three (3) qualified domestic contractors in response to a written invitation. The invitation shall include a detailed description of the works, including basic specifications, the required completion date, a basic form of agreement acceptable to the Association, and relevant drawings, where applicable. The award shall be made to the contractor who offers the lowest price quotation for the required work, and who has the experience and resources to complete the contract successfully. Part D: Review by the Association of Procurement Decisions
Musculoskeletal Injury Prevention and Control (a) The Hospital in consultation with the Joint Health and Safety Committee (JHSC) shall develop, establish and put into effect, musculoskeletal prevention and control measures, procedures, practices and training for the health and safety of employees.
ENVIRONMENT, SAFETY AND HEALTH PROTECTION (a) Seller shall perform this Agreement in a manner that ensures adequate protection for workers, the public, and the environment, and shall be accountable for actions of itself and its lower-tier subcontractors, agents and employees. Seller shall exercise a degree of care commensurate with the work and the associated hazards. Seller shall ensure that management of environment, safety and health (ES&H) functions and activities is an integral and visible part of Seller’s work planning and execution process. In the event that Xxxxxx fails to comply with this Agreement, Company may, without prejudice to any other legal or contractual rights, issue an order stopping all or any part of the work; thereafter a start order for resumption of work may be issued at Company’s discretion. Seller shall make no claim for an extension of time or for compensation or damages by reason of or in connection with such work stoppage. In addition, Company may require, in writing, that Seller remove from the work any employee the Company deems unsafe, incompetent, careless, or otherwise objectionable.
Environmentally Preferable Procurement Policy The Environmentally Preferable Procurement Policy, along with a brief policy description, is located on the City’s website at the following link: xxxx://xxx.xxxxxxxxx.xxx/esd/natural-energy-resources/epp.htm. Environmental procurement policies and activities related to the completion of any Work will include, whenever practicable, but are not limited to: The use of recycled and/or recyclable products in daily operations (i.e. 30%, 50%, 100% PCW paper, chlorine process free, triclosan free hand cleaner, etc.); The use of energy-star compliant equipment; The use of alternative fuel and hybrid vehicles, and implementation of protocols aimed at increasing the efficiency of vehicle operation; The implementation of internal waste reduction and reuse protocol(s); and Water and resource conservation activities within facilities, including bans on individual serving bottled water and the use of compostable food service products.
Contract (Rights of Third Parties) Xxx 0000 22.1 No person who is not a party to this Grant Agreement shall have the right to enforce any of its terms.
The Contracts (Rights of Third Parties) Xxx 0000 A person who is not party to this Contract has no right under the Contracts (Rights of Third Parties) Xxx 0000 to enforce any term of this Contract but this does not affect any right or remedy of any person which exists or is available otherwise than pursuant to that Act.
