Progress of Work. Lessee shall deliver to Lessor such other evidence as Lessor may reasonably request from time to time during the course of the restoration and repair, as to the progress of the work, compliance with the approved plans and specifications, the cost of restoration and repair and the total amount needed to complete the restoration and repair, and showing that there are no liens against the Leased Properties arising in connection with the restoration and repair and that the cost of the restoration and repair at least equals the total amount of Construction Funds then disbursed to Lessee hereunder.
Progress of Work. During the period of construction the contractor shall maintain proportionate progress on the basis of a Programme Chart submitted by the contractor immediately before commencement of works and agreed to by the Employer /Architects. Contractor should also include planning for procurement of scarce material well in advance and reflect the same in the programme chart so that there is no delay in completion of the project.
Progress of Work. The Contractor shall carry out the work as per the programme approved by the department from time to time. He will also not be allowed to proceed with the work in a scattered manner.
Progress of Work. Contractor shall commence the Work as soon as is reasonably possible after execution of this Contract. Contractor shall diligently proceed with the Work to final completion as rapidly as practicable. Contractor shall maintain close communication with Owner at all times to inform Owner of the progress of the Work, and shall notify Owner immediately of any delays in compliance with the time schedule.
Progress of Work a. Contractor shall prosecute the Work in a diligent and continuous manner and in accordance with all applicable notice to proceed, critical path schedule and guaranteed completion date requirements set forth in (or developed and agreed by the parties in accordance with) the Scope of Services.
b. Contractor shall conduct regular meetings to update UTA's Project Manager regarding the progress of the Work including, but not limited to, any unusual conditions or critical path schedule items that could affect or delay the Work. Such meetings shall be held at intervals mutually agreed to between the parties.
c. Contractor shall deliver monthly progress reports and provide all Contract submittals and other deliverables as specified in the Scope of Services.
d. Any drawing or other submittal reviews to be performed by UTA in accordance with the Scope of Services are for the sole benefit of UTA, and shall not relieve Contractor of its responsibility to comply with the Contract requirements.
e. UTA will have the right to inspect, monitor and review any Work performed by Contractor hereunder as deemed necessary by UTA to verify that such Work conforms to the Contract requirements. Any such inspection, monitoring and review performed by UTA is for the sole benefit of UTA, and shall not relieve Contractor of its responsibility to comply with the Contract requirements.
f. UTA shall have the right to reject Work which fails to conform to the requirements of this Contract. Upon receipt of notice of rejection from UTA, Contractor shall (at its sole expense and without entitlement to equitable schedule relief) promptly re-perform, replace or re-execute the Work so as to conform to the Contract requirements.
g. If Contractor fails to promptly remedy rejected Work as provided in Section 4.6, UTA may (without limiting or waiving any rights or remedies it may have) perform necessary corrective action using other contractors or UTA’s own forces. Any costs reasonably incurred by UTA in such corrective action shall be chargeable to Contractor.
Progress of Work. If, in the judgment of Xxxxx, the work of Subcontractor is not proceeding in accordance with the PA, or Subcontractor has breached any provision of this Agreement, Xxxxx may give notice to Subcontractor to cease work and proceed to have the work done in the manner most expedient to Xxxxx including, but not limited to, the supplementation of Subcontractors work force, the termination and replacement of Subcontractors work force or both, as Xxxxx deems appropriate, and charge the cost, including any incidental expenses and those additional costs set out in this Agreement, to Subcontractor. Xxxxx shall be entitled to take possession of and use any materials, equipment, plans, and permits on the job site or intended for the work and use the same for the performance of the work. Subcontractor waives any claim, demand or cause of action, against Xxxxx for the loss of use, misuse, abuse, or conversion of the tools, materials, equipment, plans, or permits, taken or used by Xxxxx in accordance with this Section. In the event Xxxxx is required to complete the work of Subcontractor in accordance with the provisions of this Agreement, Subcontractor agrees to reimburse Xxxxx for all costs and expenses. Xxxxx’x decision to implement or not implement such action shall not constitute any modification or waiver of any of the terms of this Section. Xxxxx shall always retain the full rights and remedies afforded under this Section.
Progress of Work. Upon request, the City shall provide an update of the status of the construction of the Improvements to the District.
Progress of Work. Consultant shall perform the professional services promptly, diligently and in such manner and sequence as to assure the timely completion of other work dependent thereon and to permit completion of the professional services in a manner to ensure the work is completed on or before the Completion Date set forth above (“Schedule Requirements”). In this regard, Consultant shall at all times furnish and have available such sufficient and satisfactory equipment, materials, supplies and workers to perform the professional services in a prompt and timely manner in accordance with the timelines of this Agreement. In the event Consultant fails to perform the professional services in accordance with the Schedule Requirements, Consultant, at its own expense, shall provide additional equipment, work force, overtime or additional shifts so as to meet and maintain the Schedule Requirements. Consultant will pay all expenses and damages incurred by Owner resulting from the failure of Consultant to meet the Schedule Requirements, or abide by Contractor’s instructions with regard to the Schedule Requirements, to Owner upon demand.
Progress of Work. If, in the judgment of Contractor, the work of Subcontractor is not proceeding in accordance with the Progress Schedule, or Subcontractor has breached any provision of this Agreement, Contractor may, after giving forty-eight (48) hours’ notice to Subcontractor of the same, proceed to have the work done in the manner most expedient to Contractor including, but not limited to, the supplementation of Subcontractor’s work force, the termination and replacement of Subcontractor’s work force, or both, as Contractor deems appropriate, and charge the cost, including any incidental expenses and those additional costs set out in this Agreement, to Subcontractor. Contractor shall be entitled to take possession of and use any materials, tools, equipment, plans, permits and diagrams on the job site or intended for the work and use the same for the performance of the work. Subcontractor waives any claim, demand or cause of action, against Contractor for the loss of use, misuse, abuse, or conversion of the tools, materials, equipment, plans, permits, or diagrams, taken or used by Contractor in accordance with this Section. In the event Contractor is required to complete the Work of Subcontractor in accordance with the provisions of this Agreement, Subcontractor agrees to reimburse Contractor for all costs and expenses plus an additional twenty percent (20%) of costs and expenses as overhead.
Progress of Work. 10.01. Unless otherwise specifically provided, the Contractor shall prosecute its work at such time and sessions, in such order of precedence, and in such manner as shall be most conducive to the economy of the Project; provided, however, that the order and time of prosecution shall be such that the Project shall be Substantially Completed in accordance with this Contract, the plans and specifications, and within the time of completion designated in the schedules agreed upon by the parties.
10.02. Further, the parties shall be subject to the following:
(a) The Contractor shall submit a progress schedule and payment schedule of the work contemplated by this Contract at the initial post-Contract award meeting and subsequent meetings.
(b) City's Representative shall be entitled to make objections to the Contractor's schedule submitted herein. The Contractor shall promptly resubmit a revised schedule to City's Representative.
(c) The Project Superintendent/Manager shall coordinate its activities with City's Representative. If required by the City, the Contractor shall provide a weekly schedule of planned activities, which may be reviewed on a daily basis.
(d) The Contractor shall submit, at such time as may reasonably be requested by City's Representative, additional schedules that shall list the order in which the Contractor proposes to carry on the work with dates at which the Contractor will start the several parts of the work and the estimated dates of completion of the several parts.
(e) The Contractor shall attend additional meetings called by City's Representative upon twenty-four (24) hours written notice unless otherwise agreed in writing by the parties.
(f) When the City is having other work done, either by agreement or by its own force, City's Representative may direct the time and manner of work done under this Contract so that conflicts will be avoided and the various work being done by and for the City shall be coordinated.
(g) In the event that it is determined by the City that the progress of the work is not in accordance with the approved progress and payment schedule, the City may so inform the Contractor and require the Contractor to take such action as is necessary to insure completion of the Project within the time specified.
10.03. The process of approving Contractor’s schedules and updates to Contractor’s schedules shall not constitute a warranty by the City that any non-Contractor milestones or activities will occur as set out in the Co...
