ADDITIONS AND DELETIONS The author of this document has added information needed for its completion. The author may also have revised the text of thestandard form and Deletions notes added well as xxxxx standard formavailable fro xxxx.Xx info ion tem th inal AIA An Additions port that rmation as s to the xt is e author and should be reviewed. « »« » « » « » « » This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification. AIA Document A201™–2017, Conditions of the Contract for Construction, is adopted in this document by reference. Do not use with other general conditions unless this document is modified. General for the following Project: (Name, location, and detailed description) «Tule River Tribe Casino & Hotel Project» «Porterville, CA 93257 » «Construction of a new casino of approximately 189,900 SF, hotel of approximately 110,497 SF, and events center of approximately 25,000 SF, with pool and other associated improvements and amenities » « » The Architect: (Name, legal status, address, and other information) «HBG Design Attn: Xxx Xxxxxxxxxx 000 Xxxxxxxx, Xxxxx 000 Xxx Xxxxx, XX 00000 619.858.7888 « » The Owner’s Designated Representative: (Name, address and other information) «Xxxxxx X. Xxxxxxxx Project Executive Summit Project Management (M): 000-000-0000 xxx@xxxxxx-xx.xxx » « » ELECTRONIC COPYING of any portion of this AIA® Document to another electronic file is prohibited and constitutes a violation of copyright laws as set forth in the footer of this document. The Owner, either directly or by and through its designated representative(s), may perform the duties and exercise the rights of Architect in administration of the Contract, the Project and the Work, as provided in the Contract Documents, including without limitation review and acceptance or rejection of Work, processing of applications for payment (progress and final), changes in the Work, Change Orders, and all acts and activities related thereto. Whenever and wherever Owner performs such duties and exercises such rights the term “Owner” or “Owner’s Representative” shall be deemed to be substituted for the term “Architect” wherever it appears in the Contract Documents. Notwithstanding the rm foregoing, the Owner is not a licensed design professional and shall not be required to perfo architect’s license is required. The Owner and Construction Manager agree as follows. any services for which an TABLE OF ARTICLES
Tasks and Deliverables A description of and the schedule for each task and deliverable, illustrated by a Xxxxx chart. Start and completion dates for each task, milestone, and deliverable shall be indicated. Must include deliverables specified in SOW-RFP as well as other deliverables that may be proposed by Contractor.
ADDITIONAL CONSTRUCTIONS The Promoter undertakes that it has no right to make additions or to put up additional structure(s) anywhere in the Project after the building plan has been approved by the competent authority(ies) except for as provided in the Act.
Project Construction Budget The project construction cost allowance specifically stated in writing as the ‘revised’ or ‘current’ ‘Project Construction Budget’ by the Trustees at each applicable phase of plan development.
AGREEMENT ALTERATIONS AND AMENDMENTS This Agreement may be amended by mutual agreement of the parties. Such amendments shall not be binding unless they are in writing and signed by personnel authorized to bind each of the parties.
General Conditions Costs Construction Manager is entitled to receive payment for the actual cost of the allowable General Conditions items incurred after receipt of a Notice to Proceed with Construction from the Owner through Substantial Completion of the Project plus thirty (30) calendar days. Construction Manager is not entitled to reimbursement for General Conditions Costs incurred before receipt of the Notice to Proceed. General Conditions Costs incurred after Substantial Completion must be approved in advance by the Owner. Allowable General Conditions items are identified below and by attached exhibit. These items shall be included in the General Conditions cost amount shown as a line item in the Guaranteed Maximum Price Proposal and as detailed on the schedule of values. Items not specifically included below or in the exhibit will not be allowed as a General Condition costs.
CLOSING COSTS AND ADJUSTMENTS All adjustments are made as of settlement date.
For General Conditions Costs Contractor’s Application for Payment shall be submitted on a Schedule of Values approved by the Owner and include complete copies of all receipts, invoices with check vouchers or other evidence of payment, payrolls, and any and all other evidence which Owner or its designated representatives shall deem necessary to support the amount requested. This information is subject to audit and payment for these costs is dependent on Owner’s receipt of accurate and complete records of all transactions. Owner may reduce the amount requested for General Conditions Costs in any Application for Payment if Owner, in its good faith judgment, determines that the unpaid balance of the General Conditions line item in the Schedule of Values is not sufficient to fund necessary General Conditions Costs for the remainder of the Project.
BUILDER’S RISK FOR CONSTRUCTION RENOVATION PROJECTS If the project is CONSTRUCTION RENOVATION of an existing structure, and the State has already determined that Contractor will not be obligated to obtain and maintain Builder’s Risk insurance, then the following provisions apply:
Prorations and Adjustments The following shall be prorated and adjusted between Seller and Buyer as of the Closing Date, except as otherwise specified:
