Common use of Project Amendments Clause in Contracts

Project Amendments. Project Amendments may be requested by the Sub-Grantee/Sub-Recipient, in FDEM Grants Management System, on both small and large projects, to: 1) New Time Extension; a) Requests for Time Extensions within the Grantee/Sub-Recipient’s authority b) Requests for Time Extensions not within the Grantee/Sub-Recipient’s authority 2) New Project Amendment; a) Requests for Alternate Projects; and/or b) Requests for Improved Projects; and/or c) Requests for Mitigation Opportunities; and/or d) Requests for Revised Scope of Work; and/or e) Significant Cost Variance (>20%); and/or f) Use of Eligible Excess Funds 3) New Project Appeal a) Applicant Appeal i) Request First Appeal; and/or ii) Request Second Appeal; and/or iii) Request Appeal via Arbitration b) Project Appeal

Appears in 6 contracts

Samples: Subaward and Grant Agreement, Subaward and Grant Agreement, Subaward and Grant Agreement

AutoNDA by SimpleDocs
Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!