Project Tracking Sample Clauses

Project Tracking. The Designated Entity shall provide regular, quarterly construction status reports in writing to Transmission Provider. The reports shall contain, but not be limited to, updates and information specified in the PJM Manuals regarding: (i) current engineering and construction status of the Project; (ii) Project completion percentage, including milestone completion; (iii) current target Project or phase completion date(s); (iv) applicable outage information; and (v) cost expenditures to date and revised projected cost estimates for completion of the Project. Transmission Provider shall use such status reports to post updates regarding the progress of the Project.
AutoNDA by SimpleDocs
Project Tracking. The NPMO will populate, maintain and disseminate a web-accessible monitoring and tracking system. The tracking system will allow Parties, stakeholders and the general public to monitor the progress of a Project, including management of timelines and milestones set out in the NPA. The NPMO Tracker shall not contain or disseminate any confidential information of the Project proponent or the Parties. To the extent possible, the NPMO monitoring and tracking system will cross reference existing tracking systems and public registries established by the relevant environmental assessment/impact review and regulatory boards.
Project Tracking. Provide timely, professional and thorough tracking of SBCCOG projects and funding. Quarterly updates shall be provided to the Steering Committee to include status, schedule and cost variance to planned expenditure. Ensure that all grant fund reporting is completed in a timely and accurate manner.
Project Tracking. The Project Managers will jointly present a monthly Project Status that will supply information on the following: > Budget tracking > Risks factors > Detail Microsoft Project plan > Short term action list > Documentation plan > Communication plan > Issues tracking and resolution plan > Modification policy > Steering Committee meetings > Status meetings and reports > Deliverables and Milestones
Project Tracking. Within 30 days of issuance of this Order, Caltrans shall upload Project information to EcoAtlas using the “Project Tracker” form found at the following website: xxxx://xxxxxx.xxxxxxxx.xxx. Required information includes a Project map that may either be uploaded to EcoAtlas or created within EcoAtlas by using the “draw polygon” tool. Required mitigation monitoring reports shall be uploaded to EcoAtlas by March 1 following the certification January 31 monitoring report due date. To upload monitoring reports into EcoAtlas, use the “Files and Links” tab found on your Project’s EcoAtlas page. (CA Water Code section 13267)

Related to Project Tracking

  • Development of the Project 4.1 TSP's obligations in development of the Project: a. for procuring and maintaining in full force and effect all Consents, Clearances and Permits, required in accordance with Law for development of the Project; b. for financing, constructing, owning and commissioning each of the Element of the Project for the scope of work set out in Schedule 1 of this Agreement in accordance with: i. the Electricity Act and the Rules made thereof; ii. the Grid Code; iii. the CEA Regulations applicable, and as amended from time to time, for Transmission Lines and sub-stations: • the Central Electricity Authority (Technical Standards for Connectivity to the Grid) Regulations, 2007; • Central Electricity Authority (Technical Standards for construction of Electrical Plants and Electric Lines) Regulation, 2010; • Central Electricity Authority (Grid Standard) Regulations, 2010; • Central Electricity Authority (Safety requirements for construction, operation and maintenance of Electrical Plants and Electrical Lines) Regulation, 2011; • Central Electricity Authority (Measures relating to Safety and Electricity Supply) Regulation, 2010; • Central Electricity Authority (Technical Standards for Communication System in Power System Operation) Regulations, 2020. iv. Safety/ security Guidelines laid down by the Government; v. Prudent Utility Practices, relevant Indian Standards and the Law; not later than the Scheduled COD as per Schedule 2 of this Agreement; c. for entering into a Connection Agreement with the concerned parties in accordance with the Grid Code. d. for owning the Project throughout the term of this Agreement free and clear of any encumbrances except those expressly permitted under Article 15 of this Agreement; e. to co-ordinate and liaise with concerned agencies and provide on a timely basis relevant information with regard to the specifications of the Project that may be required for interconnecting the Project with the Interconnection Facilities; f. for providing all assistance to the Arbitrators as they may require for the performance of their duties and responsibilities; g. to provide to the Nodal Agency and CEA, on a monthly basis, progress reports with regard to the Project and its execution (in accordance with prescribed form) to enable the CEA to monitor and co-ordinate the development of the Project matching with the Interconnection Facilities; h. to comply with Ministry of Power order no. 25-11/6/2018 – PG dated 02.07.2020 as well as other Guidelines issued by Govt. of India pertaining to this; i. to procure the products associated with the Transmission System as per provisions of Public Procurement (Preference to Make in India) orders issued by Ministry of Power vide orders No. 11/5/2018 - Coord. dated 28.07.2020 for transmission sector, as amended from time to time read with Department for Promotion of Industry and Internal Trade (DPIIT) orders in this regard (Procuring Entity as defined in above orders shall deemed to have included Selected Bidder and/ or TSP). Also, to comply with Department of Expenditure, Ministry of Finance vide Order (Public Procurement No 1) bearing File No. 6/18/2019- PPD dated 23.07.2020, Order (Public Procurement No 2) bearing File No. 6/18/2019-PPD dated 23.07.2020 and Order (Public Procurement No. 3) bearing File No. 6/18/2019-PPD, dated 24.07.2020, as amended from time to time, regarding public procurement from a bidder of a country, which shares land border with India; j. to submit to Nodal Agency information in the prescribed format [To be devised by Nodal Agency] for ensuring compliance to Article 4.1 i) above. k. to comply with all its obligations undertaken in this Agreement. 4.2 Roles of the Nodal Agency in implementation of the Project: 4.2.1 Subject to the terms and conditions of this Agreement, the Nodal Agency shall be the holder and administrator of this Agreement and shall inter alia: a. appoint an Independent Engineer within 90 days of the Effective Date b. provide letters of recommendation to the concerned Indian Governmental Instrumentality, as may be requested by the TSP from time to time, for obtaining the Consents, Clearances and Permits required for the Project; c. coordinate among TSP and upstream/downstream entities in respect of Interconnection Facilities; and d. monitor the implementation of the Agreement and take appropriate action for breach thereof including revocation of guarantees, cancellation of Agreement, blacklisting etc e. provide all assistance to the Arbitrators as required for the performance of their duties and responsibilities; and f. perform any other responsibility (ies) as specified in this Agreement.

  • Contract Transition Upon Contract expiration or termination, the Contractor shall ensure a seamless transfer of Contract responsibilities with any subsequent Contractor necessary to transition the Products and services of the Contract. The incumbent Contractor assumes all expenses related to the contract transition.

  • Site Visits ‌ The Commission may visit the School at any time and may, at its discretion, conduct site visits and monitoring. When appropriate, the Commission shall make reasonable efforts to provide notice of visits. Such site visits may include any activities reasonably related to fulfillment of the Commission’s oversight responsibilities including, but not limited to, inspection of the facilities; audit of financial books and records; inspection of records maintained by the School; interviews and observations of the principal, staff, school families, staff of an affiliated nonprofit or educational service provider and community members; and observation of classroom instruction.

  • Development Period The Contractor may commence pre-construction activities like utility shifting, boundary wall construction or any other activity assigned to the Contractor by the Authority to enable construction of the Project Highway immediately after signing of the Agreement, to the extent that such work is ready for execution. The Parties agree that these works may be taken up and completed to the extent feasible by the Contractor, before declaration of the Appointed Date, but no claim against the Authority for delay shall survive during this period and that the undertaking of these works by the Contractor shall not count towards the Scheduled Construction Period of the project which starts counting only from the Appointed Date. No construction activity of the Project Highway shall be undertaken during the development period.

  • Career Development The City and the Union agree that employee career growth can be beneficial to both the City and the affected employee. As such, consistent with training needs identified by the City and the financial resources appropriated therefore by the City, the City shall provide educational and training opportunities for employee career growth. Each employee shall be responsible for utilizing those training and educational opportunities made available by the City or other institutions for the self- development effort needed to achieve personal career goals.

  • Inspection/Testing In order to assess Supplier’s work quality and/or compliance with this Order, upon reasonable notice by Buyer: (a) all goods, materials and services related to the items purchased hereunder, including, raw materials, components, assemblies, work in process, tools and end products shall be subject to inspection and testing by Buyer, its customer, representative or regulatory authorities at all places, including sites where the goods are made or located or the services are performed, whether at Supplier’s premises or elsewhere; and (b) all of Supplier’s facilities, books and records relating to this Order shall be subject to inspection by Buyer or its designee. If specific Buyer and/or Buyer’s customer tests, inspection and/or witness points are included in this Order, the goods shall not be shipped without an inspector’s release or a written waiver of test/inspection/witness with respect to each such point; however, Buyer shall not be permitted to unreasonably delay shipment; and Supplier shall notify Buyer in writing at least twenty (20) days prior to each of Supplier’s scheduled final and, if applicable, intermediate test/inspection/witness points. Supplier agrees to cooperate with such/audit inspection including, completing and returning questionnaires and making available its knowledgeable representatives. Buyer’s failure to inspect or test goods, materials or services or Buyer’s failure to reject or detect defects by inspection or testing shall not relieve Supplier from its warranty obligations or any of its other obligations or responsibilities under this Order. Supplier agrees to provide small business as well as minority and/or women owned business utilization and demographic data upon request.

  • Development Activities The Development activities referred to in item “b” of paragraph 3.1 include: studies and projects of implementation of the Production facilities; drilling and completion of the Producing and injection xxxxx; and installation of equipment and vessels for extraction, collection, Treatment, storage, and transfer of Oil and Gas. The installation referred to in item “c” includes, but is not limited to, offshore platforms, pipelines, Oil and Gas Treatment plants, equipment and facilities for measurement of the inspected Production, wellhead equipment, production pipes, flow lines, tanks, and other facilities exclusively intended for extraction, as well as oil and gas pipelines for Production Outflow and their respective compressor and pumping stations.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!